Tender Addendum Bill Nr.

2
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1
TINGKAT BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT
PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK
PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN
BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SUMMARY OF TENDER - MAIN TENDER "A"

SW No Description Amount (RM)

1 Preliminaries 300,000.00

2 Factory (Block 1) 10,770,393.25

3 Link Bridge (Block 1) 193,457.44

4A Guard House (Type C) 88,718.55

4B Refuse Chamber 38,537.35

5 External Works Within Boundary (All Provisional) 1,700,893.41

Provisional Sum

- Weighing Bridge 1,000,000.00

- External Equipment and IETS 1,000,000.00

Total for MAIN TENDER "A" : 15,092,000.00

Performance Incentives : 308,000.00
Grand Total Before Deduction of Performance Incentives : 15,400,000.00

* Works to be carried out and completed within the Employer's overall fixed completion period of SEVEN (7) MONTHS

TENDERER :……………………………………………………………………

( Name of Firm in Block Letters )

Signature : ……………………………….....

Name : ……………………………………..

In the capacity of : ……………………..……

Date : ……………..…..

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SOT/1(Add2)
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

GENERALLY

A GENERAL INFORMATION

All directions, obligations and instructions in this General Conditions and Preliminaries (the
Preliminaries) are directed at the Contractor unless otherwise specifically stated to the otherwise.
The Contractor shall ensure that all such directions, obligations and instructions are complied with
whether by himself or his servants, agents, workmen or and subContractors. These requirements
form part of the Contractor's obligation and responsibility under this Contract.

The Contractor is deemed to have included or allowed for compliance with all requirements herein in
the Contract Sum, regardless of whether or not specific stipulations on such inclusion have been
made in the Clauses herein.

B PRICING OF PRELIMINARIES AND PAYMENT

The prices inserted herein shall be for full compliance with the intent of each item and apply to the whole of the
Works under this contract.

Within two (2) weeks from the contract commencement date, the Contractor shall provide a detailed breakdown of
their pricing into the following categories:
a. mobilisation costs, i.e. costs incurred at the outset of the contract;
b. time related costs, i.e. costs applied equally over the contract duration;
c. removal costs, i.e. costs incurred at the tail-end of the contract ; and
d. other lump sum items, or one-off payable costs shall be identified, and the
amount and time upon which payment falls due shall be identified

The detailed breakdown and mode of payment, after rationalisation, and upon agreement and acceptance by the
Architect/S.O shall form the basis for the valuation of Preliminaries under interim certificates.

The Architect/S.O shall have the right to withhold payment, in whole or in part, or to totally omit
any items covered under the preliminaries which the Contractor has failed to provide, or which are
inadequately provided. The contract sum shall be accordingly adjusted for any such reductions or
omissions which the Architect/S.O deem necessary due to the non-compliance by the Contractor.
This is without prejudice to any rights and remedies which the Employer may possess under or in
connection with the contract.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/1
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION

A SCOPE OF WORK

The Contract comprises generally the supply of all labours, materials, tools, plant, equipment and everything
else necessary including temporary works of any nature, for the proper execution, completion and
maintenance of the Works in conforming with the Drawings, this Specification and the Conditions of Contract.

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : -

I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG PEJABAT DI ARAS MEZZANINE
II) 1 UNIT GUDANG 1 TINGKAT
III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT
IV) 2 BLOK ASRAMA PEKERJA 3 TINGKAT
V) 1 UNIT STESEN SUIS UTAMA (SSU)
VI) 4 UNIT PONDOK PENGAWAL
VII) KOLAM TAKUNGAN AIR
VIII) LOJI RAWATAN KUMBAHAN
DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA
LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PACKAGE 1 - FACTORY AND WAREHOUSE

The following works are EXCLUDED in this contract, separately appointed by the Employer:-
1) Piling Works - undertaken by Piling Contractor
2) External Equipment - to be awarded under separate package
3) Infrastructure Works - to be awarded under separate package
4) Mechanical and Electrical Works - to be undertaken by Specialist Contractors
4) Furniture and fixture - to be direct purchased by the Employer

All Works shall be executed in accordance with the Specification and Contracts Documents and to the satisfaction
of the Architect/S.O.

The complete scope of works can be gauged from the tender drawings.

The Contractor is to allow in their tenders for all contingencies they deem they may require in order to comply
with the sectional completion programme and must provide for multiple gangs and suitable construction techniques
and equipment.

B ALTERNATIVE TENDERS

Provision has been made in the Summary of Tender to these Schedule of Works for the submission of TWO (2)
ALTERNATIVE TENDERS:-

a. MAIN TENDER "A"

Based on the Works to be completed within Employer's fixed completion time of SEVEN (7) months as prescribed
in the following Clause.

b. ALTERNATIVE TENDER "B"

Based on the Works to be completed within the Contractor's own stipulated time as prescribed in the following
Clause.

The award of the tender to the Contractors will be solely at the discretion of the Employer.

The Employer reserves the right to accept or reject any Tenders.

No claim for any loss and/or expense whatsoeve shall be entertained in the event the Employer carries out all or
part of the above said works.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/2
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION ... (Cont'd)

A COMPLETION

Time for completion of this Contract is important and completion within the contracted period is essential.

The Contractor shall be charged Liquidated and Ascertained Damages, at the rates stipulated in the
Appendix to the condition of Contract, if the time for completion of any at the rates stipulated in
the Appendix to the condition of Contract, if the phase is exceeded and no extension of time has
been granted by the Architect/S.O.

B SEQUENCE OF CONSTRUCTION

It is a condition of this Contract that the works are to be carried out and completed in the sequence
and sections. The sequencing of sectioned completion, priority for area for completion, lines of
division of sectional completion and the extend of the works are to be determined by the
Architect/S.O.

The Contractor shall make every endeavour to programme the sequence of works to comply with the
sectional completion and to ensure proper execution of the works for the completion of the building
work construction.

C EMPLOYER RESERVES RIGHT TO VARY PROGRAMME

The right is reserved to the Employer to require that the sequence of construction of the various
sections to be varied from the order stated in the tender and no claims will be considered on this
account.

D CO-ORDINATION WITH OTHER CONTRACTORS EMPLOYED ON THE SITE

The Contractor shall work in close co-ordination and liaison with other Contractors appointed by the
Employer who may, at one time or the other, during the currency of this Contract, be operating
around and in the vicinity of the site. The Contractor shall take account of the work programme of
these other Contractors in the planning and programming of the Contract works.

The Contractor shall, in particular, liaise with these other Contractors on matters of shared access,
common security, keeping roads, accessways and drains free of debris and mud. The Contractor
shall co-ordinate all related work to minimise obstructions and hindrances. The Contractor shall
agree and share the cost of maintenance of all roads and accessways, or other common facilities.

Within one week of the Architect so instructing, the Contractor shall remove all materials and rubbish
that are in the working areas of these other Contractors in order that their works are not impeded.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/3
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION ... (Cont'd)

A SITE LOCATION

The site is located at Lot 213, 214, 215, 216, 217 & 218, Pekan Bukit Changgang, Daerah Kuala Langat,
Selangor Darul Ehsan.

The Contractor is to refer to the Key Plan for the exact location, dimensions and area of the site and he must
accept the site "as found on the date of possession".

B VISIT TO SITE

The Contractor shall visit the site of the works and shall by independent inquiry and observation ascertain the
following in connection with the works:-
a. the nature, character and extent of the works
b. local conditions
c. the means of access to and from and within the site of the works
d. the extent of working space available
e. the conditions affecting labour and materials
f. the conditions affecting the storage of materials, the positioning of shed, stores, site offices,
temporary buildings
g. the character of the soil or strata and the nature of subsoil upon which the works are to be executed. The
Contractor is to bore trial holes at their own expenses if they deem it necessary.
h. all other information which may in any way be relevant or necessary to enable the Contractor to estimate
accurately the cost of the works.

No claims made on the ground of failure to visit the site and/or of want of any of the aforesaid
matters or other like information which might financially affect the Contract, will be considered.

C SITE POSSESSION

In giving the Contractor possession of the Site, it shall not to be deemed that he is to have
extensive possession but only a limited possession. Such possession will enable him to perform
the works comprised in this Contract. The Employer may at any time take possession of any portion
of the ground or intended site of the works for the purpose of carrying on any other work, or for any
purpose whatsoever. The site may be handed over in parts but without any compensation. No
extension of time will be granted to the Contractor in complying with the above requirements.

D SITE INSPECTION

Immediately after taking possession of the site and before commencing any work, the Contractor shall
check actual levels and dimensions against those shown on the the Contractor shall be held to accept
all levels and drawings and immediately inform the Architect/S.O in the event of any alleged
discrepancy. If no communication has reached the Architect/S.O., the Contractor shall be held to
accept all levels and dimensions and no claims for extra payments in this connection will be entertained.

The Contractor shall allow for the assistance of a Licensed Land Surveyor to carry out a site survey before
work commences, and to assist in establishing boundaries and setting out the works as required by the
Architect/S.O and shall cause copies of the survey drawings to be distributed to the Employer and his
Consultants.

The licensed Land Surveyor shall carry out another site survey to confirm the final levels upon
completion of the formation levels to indicate achievement of levels upon completion and to complete
'As Built' setting out levels and formation levels including providing all pegs, templates, instruments
and labour necessary for so doing and as required by the Architect/S.O for checking the work. Five (5)
sets of the endorsed 'As Built' drawings shall be submitted to the Architect/S.O for reference.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/4
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION ... (Cont'd)

A EXISTING SERVICES

The Contractor shall take all necessary steps to ascertain the exact positions of existing cables, pipes,
ducts, sewers, service mains and the like, and shall uphold, protect and maintain the same during
excavations and make good or pay for making good all damage or loss arising out of such damage.

The information given or shown on any drawings are for guidance only and does not relieve the
Contractor from any responsibilities should the information given or shown be incorrect.

In cases where the services are to be temporarily terminated or diverted, the Contractor shall give the necessary
notices to the appropriate Authorities and arrange for the work to be carried out and pay all charges in connection
therewith.

B ADJOINING PROPERTIES

The adjoining sites include various buildings and structures and care must be taken to ensure that
no vibrations or other disturbances shall affect the adjointing buildings and structures during the
course of work.

The adjoining sites include various structures under construction and care must be taken to ensure
that no vibration or other disturbances shall affect such construction works during the course of
building operations.

Ensure that the security of adjacent property is not lessened due to work activities. Take measures
to prevent trespass from adjoining properties.

Damages or other disturbances caused to the adjoining buildings and structures shall be made good
to the satisfaction of the Architect/S.O. Pay for any compensation claimed.

Make every effort to reduce noise, vibration, dust or any other interference that may be caused
by the Works. Install as directed by the Architect/S.O, and without additional cost, duct sheets,
temporary screens, etc. and adopt measures necessary for the mitigation of noise, vibration, dust, etc.

C SCHEDULE OF EXISTING CONDITIONS / DILAPIDATION REPORT 3,000.00

Prior to commencement of the Works, the Contractor shall arrange for a joint survey and
inspection of the site, neighbouring properties , footpaths, roads, fences and other fittings,
fitments and structures, including carrying out verticality checks. This shall be carried out together
with the owners of adjoining buildings and structures, Employer's Representative(s), Architect,
Engineer, other work-related Contractors, and the Insurance Company from which the relevant
insurance policies are taken.

Photographs shall be taken, dated and referenced with notes of their existing conditions, with
special features highlighted and annotated and included in a report to be submitted to the
Architect. Two (2) sets of the report shall be submitted to the Architect/S.O and one (1) copy
provided to the Insurance Company.

TO COLLECTION : RM 3,000.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/5
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION ... (Cont'd)

A UNSPECIFIED ITEMS

Ensure that any and all materials , goods and components which are left to the choice of the Contractor
are of good quality, fit for their intended purpose and in compliance with good engineering and building
practice.

Unless specific requirements, performance criteria, etc are indicated, self-finished and
decorative materials shall be subject to the selection and approval of the Architect/S.O.

B APPROVED EQUIVALENT

Where the term "approved equivalent" is appended to specification clauses or descriptions in the
Schedule of Works for materials or components to be incorporated into the works, it shall mean
materials and components of equal or better quality, standards, manufacture and capable of
performing in all respects to specified requirements, subject always to the approval of the
Architect/S.O.

Where equivalents are offered, the Contractor shall submit relevant details with their tenders.

C FIX ONLY ITEMS

The word “Fix Only”, where used in the Specifications and Schedule of Works in connection with any material or
goods supplied by Nominated Suppliers shall be understood to include for :-

a. Cost of labour and supervision, including on-costs such as but not restricted to :
(i) ovetime and non-productive time
(ii) incentive and bonus payment
(iii) travelling time and expenses
(iv) annual and public holidays
(v) disbursements arising from Employment, Health, Safety or Welfare Laws and Regulations, CIDB Act, etc.

b. cost of mechanical and non-mechanical plant, equipment and tools including operator, fuel, oil and
maintenance

c. taking delivery of materials, assisting in unloading, handling including double handling, storage on or off-site,
paying all storage costs, protecting and returning package.

d. laying out materials on site for selection and approval by the Architect/S.O before laying and/or fixing.

e. movement and installation, hoisting, cutting, fitting and fixing materials in final position including all sundry
items

f. co-ordinating interfacing details and providing all details of pre-drilling and building penetrations.

g. all cutting, assembling, hoisting fitting and fixing materials in final position, including allowances for breakage
and wastage

h. protection of completed and partially completed works

i. site, compeltion, acceptance and other specified tests

j. financing charges, overheads and profit

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/6
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TENDERING CONDITIONS & INFORMATION ... (Cont'd)

A SPECIFIED MATERIALS / SUPPLIERS

Model or brand of materials specified, including suppliers and/or manufacturers listed in the
Specifications or described in the Schedule of Works are preferred materials and suppliers and/or
manufacturers.

The Contractor is at liberty to propose alternative brand and/or model in substitution of specified
model/brand and/or suppliers/manufacturers. All alternative materials or finishes offered shall be
of “approved equivalent” as specified in the earlier clause on “Approved Equivalent “, and shall
offer substantial savings to qualify them for acceptance.

Acceptance and/or rejection of alternative materials and finishes shall be the sole discretion of the
Architect/S.O. In the event that alternative materials and finishes are accepted, these shall be
interpreted as substitute materials and shall be dealt with in the manner as stipulated under the
clause for “SUBSTITUTE MATERIALS” later in this SW No. 1.

B DIMENSIONS

Figured dimensions on the drawings shall be followed in all cases. Where dimensions are omitted or
in doubt, the Contractor shall seek clarification from the Architect.

C NEGLECT TO OBTAIN RELIABLE INFORMATION

It will be assumed that adequate information had been given to the Contractor for due and proper
performance of all works under this Contract. The Contractor shall submit a written request to the
Architect for any additional information he may require.

Any negligence or failure on the part of the Contractor in obtaining reliable information pertaining
to any matter which may affect the proper execution and completion of the Works shall not relieve
him of his liabilities or responsibilities in executing, completing and handing over the Works or any
Sections thereof in accordance with the Conditions of Contract.

D COMPLYING WITH THE SPECIFICATION

Allow herein for complying with any items in the Specifications involving expense, if not already
priced elsewhere in these Tender Documents.

E FLUCTUATIONS OF PRICES, WAGE RATE, ETC

The Contract will not be adjusted for fluctuations in prices. No claims shall be allowed for any
variation in the cost of wages, material, constructional plant, fuel, duties, taxes, temporary works
or transport or anything else whatsoever which may occur during the currency of this Contract.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/7
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT

A FORM OF CONTRACT

The Article of Agreement and Conditions of Contract into which the Contractor will be required to
enter in connection with this project is the Pertubuhan Akitek Malaysia (PAM), Private Edition
Without Quantities 2018 Edition), and they shall be read jointly with these Documents. Quantities
provided in the Schedule of Works are intended for guidance of the Contractor only in submitting a
tender price, and shall not be binding on the Contract.

B SCHEDULE OF CONDITIONS OF CONTRACT

The Contractor is referred to the full text of the undermentioned clauses of the Conditions of
Contract to which the following are short references and against which the Contractor is to provide
any sum he considers necessary in complying.

The Contractor is to note that additional clauses, if any stipulated in this Contract shall supercede
the general clauses provided in the PAM Form of Contract. If the Contractor considers that any of
the clauses of the Contract involves expenses he shall allow hereunder the money value of such
clauses. Allow for complying with each of the terms of the Schedule of Conditions summarised as
follows :-

Clause No.

1.0 Contractor's Obligations

2.0 Architect's Instruction

The Contractor shall note the requirements of this clause for Architects' instruction to be in writing
and/or the subsequent confirmation in writing of oral instructions issued.

Notify the Architect in advance of any work likely to be valued on a daywork basis. No variation
works are to be carried out on a daywork basis without the written approved of the Architect.

3.0 Contract Documents, Programme And As-built Drawings

4.0 Statutory Obligations, Notice, Fees And Charges

5.0 Levels and Setting Out Of The Works 16,500.00

The Contractor shall be responsible for setting out of the Works and shall provide all instruments
and attendance required by the Architect/S.O for checking the setting out. All setting out should be
done by a Registered Land Surveyor, stating that the works are as set out in the Drawings and
within the titled boundaries.

The Contractor shall be responsible for employing a registered Land Surveyor to do the setting out
and check the levels and alignments of the building during the progress of works and shall remedy at
his own expense any encroachment and any necessary making good resulting form his own incorrect
setting out.

Notwithstanding the fact that the setting out is checked by the Architect/S.O, the responsibility for
the survey of the setting out will rest at all times on the Contractor who should satisfy himself and
the Architect/S.O that the setting out is correct.

TO COLLECTION : RM 16,500.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/8
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT … (Cont'd)

A SCHEDULE OF CONDITIONS OF CONTRACT .... (Cont'd)

Clause No.

6.0 Materials, Goods And Workmanship To Confirm To Description, Testing And Inspection

The Contractor shall not alter or amend any part of the Specification.

The Contractor shall be responsible for all defects of workmanship, whether executed by his
workmen or staff, or by the workmen or staff of any Sub-Contractor, such errors or defects to be
remedied to the satisfaction of the Architect/S.O and at the cost of the Contractor.

The Contractor shall pay the cost of preparing all samples, transport, cost of testing and any other
charges for testing of materials. In the event that the Architect/S.O allows the substitution of any
material during the course of construction, such substitution shall be accompanied by a
corresponding deduction if there is any difference in cost.

7.0 Royalties And Patent Rights

8.0 Site Agent

9.0 Access To The Works

10.0 Site Staff

The Architect, from time to time, may delegate his authority to issue instructions which the
Architect is expressly empowered by these Conditions to act in such manner, provided that the
instruction will not cause a variation carrying time delay and/or cost implication, where in such case
the sole authority for issuing such instructions lie solely on the Architect

11.0 Variation, Provisional And Prime Cost Sums

Sub-clause 11.6, 1st line: Delete the wording "a reasonable time" and replace with "one month".

Daywork sheets are to be signed by the Foreman-in-charge and will be countersigned by the
Clerk-of-Works of the Architect/S.O. after verification. Such signature shall only imply that the
times and materials recorded on the daywork sheets are considered to be correct but shall not imply
the works recorded constitutes as variation nor that it will be valued as a daywork basis, these
being matters at the Quantity Surveyor's discretion.

The Contractor shall submit their price statement, providing the cost of variation works within
seven (7) days of receiving an instruction from the Architect.

The price statement should contain sufficient detail, with quantities and rates, supporting
quotation, invoices, etc. to enable a proper assessment by the Quantity Surveyor.

The Contractor shall not be entitled to any extra payment or enhanced rates or additional time
solely on the ground that the re-measured quantities differ from those in these Schedule of Works.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/9
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT … (Cont'd)

A SCHEDULE OF CONDITIONS OF CONTRACT .... (Cont'd)

Clause No.

12.0 Quality And Quantity Of The Works

Sub-clause 12.1 : Delete the clause in its entirety and substitute with:-

Where departures have been made from the Standard Method of Measurement, the method
adopted in the Schedule of Works will be adhered to for the purpose of ascertaining the value of
all variations.

Quantities provided in the Schedule of Works are intended for guidance of the Contractor only in
submitting a tender price, and shall not be binding on the Contract. The rates inserted by the
Contractor in the Schedule of Works, after proper rationalisation, are binding and shall, for all
purposes, be used as the Schedule of Rates for valuing variations in accordance with Clause 11.6.

13.0 Contract Sum

14.0 Materials and Goods Unfixed or Off -site

The amounts included as the value of materials and goods delivered to or adjacent to the Works for
use thereon in any certificate issued under clause 30 of the Schedule of Conditions, will

a. refer to materials and goods for incorporation into the permanent work only.

b. not exceed 75 per centum of their full value, which sum will then be subject to retention.

c. irrespective of the amount retained on work, materials and goods equals the amount named in
the Appendix to these Conditions as Limit of Retention Fund, the contents of sub-clause 14.2 will
still apply to all certificates.

15.0 Practical Completion And Defects Liability

The right is also reserved to the Architect/S.O. to certify conditionally that the buildings are
practically completed except for such outstanding items that are yet to be attended to. These
outstanding items will be specifically listed or appended in the certificate and their cost for
rectification will be assessed at the sole judgement of the Architect/S.O. Such assessed cost may
be deducted at the discretion of the Architect/S.O. and may be withheld until such time as the
Architect/S.O. is satisfied that the outstanding items have been properly attended to, after which,
the monies withheld will be released.

Notwithstanding the above, the Architect/S.O shall at any time during the Defects Liability Period,
have the further right to instruct that immediate action be taken to remedy any circumstances that
may arise after the building have been handed over, which in the opinion of the Architect/S.O. will
threaten the safety of the occupants or would render the building unfit for human habitation and if
in the opinion of the Architect/S.O, the Contractor is not in a position to provide such immediate
remedy or is uncontactable, the Architect/S.O. may in his sole discretion engage such others to
attend to these urgent defects and such rectification cost (which shall be decided at the sole
discretion of the Architect/S.O) shall be deducted from any monies that may fall due to the
Contractor under this Contract or recovered as a debt from the Contractor.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/10
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT … (Cont'd)

A SCHEDULE OF CONDITIONS OF CONTRACT .... (Cont'd)

16.0 Partial Possession by Employer

17.0 Assignment Or Sub-Letting

18.0 Injury To Persons Or Property And Employer's Indemnity

19.0 Insurance Against Injury To Persons And Property

Insert after "the Employer" on the 2nd line of Clause 19.5, the following words "at his absolute discretion
and without prejudice to the Contractor's liability to indemnify him under clause 18 of the Condition.

20.0 Insurance of the Works against Fire etc.

21.0 Date Of Commencement, Postponement And Date For Completion

On the Architect’s written instruction, the Contractor shall suspend the Works or any part thereof
for such duration and the manner directed. The Contractor shall, for the duration of such
suspension, properly protect and secure the Works as required and as may be reasonably directed
by the Architect.

Any loss and expense incurred by the Contractor in giving effect to the Architect’s instruction under
this Clause shall be borne and paid by the Employer, unless such suspension is:-
(i) necessary for the proper execution of the Works;
(ii) caused by weather conditions, or any other adverse conditions, which endangers or severely
compromises the safety and quality of the Works;
(iii) default on the part of the Contractor causing the Works to be impractical to continue; and
(iv) the safety of the Works or any part thereof or the safety of adjacent buildings or properties are
adversely affected by the continued execution of the Works

Provided always that the Contractor shall give notice to the Architect in writing of his intention to
claim within twenty eight (28) days of the Architect’s instruction.

22.0 Damages For Non-Completion

23.0 Extension Of Time (EOT)

The Contractor should take all practicable steps to avoid or reduce delays on the part of Nominated
Sub-Contractors or Nominated Suppliers and to produce evidence of such undertakings.

The Contractor is to note that no EOT will be given in respect of shortage of any one building
materials, unless the shortage is a national shortage.

Raining days shall not be entitled for EOT, unless exceptionally inclement weather occurred such as
flooding and all EOT claim shall be subjected to verification by authorized Top Glove Engineer and
approved by Top Glove Management.

Any application for EOT must be made by registered post to the Architect/S.O. within two weeks of
its occurrence.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/11
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT … (Cont'd)

A SCHEDULE OF CONDITIONS OF CONTRACT .... (Cont'd)

Clause No.

24.0 Loss And/Or Expense Caused By Matter Affecting The Regular Progress Of The Works

Written application by the Contractor to the Architect/S.O. must be made within one month
with substantiating evidence regarding the matter and all details for consideration, failing which,
no loss and expense caused by disturbance of regular progress of the works shall be allowed.

Claims for loss and/or expense shall be categorised as follows:-

(i) Loss and expense which has been incurred
(ii) Loss and expense which is being incurred

25.0 Determination Of Contractor's Employment By Employer

26.0 Determination Of Own Employment By Contractor

27.0 Nominated Sub-Contractors

28.0 Nominated Suppliers

29.0 Works By Craftsmen, Tradesmen Or Other Contractors Employed Or Engaged By Employer

30.0 Certificates And Payments

Sub-clause 30.6 : Add the following sentence at end of clause "If nothing in the measurement and valuation of
the Works submitted to the Contractor within the Period of Final Measurement is disputed by the Contractor
within three (3) months of receipt of the measurements, the measurement and valuation so submitted shall be
deemed to be conclusive between the parties and the Final Certificate shall be issued accordingly."

31.0 Outbreaks Of Hostilities

32.0 War Damage

33.0 Antiquities

34.0 Mediation

35.0 Expert Determination

36.0 Adjudication

37.0 Arbitration

38.0 Notice

39.0 Performance Bond

40.0 Governing Law

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/12
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

FORM OF CONTRACT … (Cont'd)

A Appendix To Form of Contract

The following particulars will be inserted in the blank spaces in the Appendix to the Form of Contract

Defects Liability : 24 Months

Period ( Clause 15,16 & 30 )

Percentage to Cover : 10%

Professional Fees
( Clause 20 (A) )

Date of Possession : To be stipulated on the acceptance of tender

( Clause 21 )

Time of Completion : To be stipulated on the acceptance of tender based on the period

( Clause 21 ) inserted in the Form of Tender

Liquidated Damages : (Awarded Contract Sum / 365 days x 10%) Per Day
( Clause 22 ) Actual amount to be confirmed upon award

Period of Delay ( Clause 26 )

i) by reason of loss or damage caused : 3 Months

by anyone of the contigencies referred
to in Clause 20(A) or Clause 20(B) if
applicable ( if none stated is 3 months )

ii) for any other reason : 3 Months

( if none stated is one month )

Period of Interim Certificate : One (1) month

( Clause 30(1) )
( If none stated is one month )

Period of Honouring of Certificate : Thirty (30) days

( Clause 30 (1) )
( If none stated is 21 days from the date of the Certificate )

Percentage of The Value of : Seventy Five (75) percent

Materials and Goods Included
( Clause 30 (2) )
( If none stated is 100% )

Percentage of Certified : Ten (10) percent

Value Retained
( Clause 30 (5) )

Limit of Retention : Five (5) percent of the Contract Sum or revised Contract Sum
( Clause 30 (5) ) whichever is higher

Period of Final Measurement : 6 Months

and Valuation ( Clause 30 (10) )

Amount of Performance Bond : Five (5) percent

( Clause 39 (1) )

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/13
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

THE CONTRACT

A PERFORMANCE BOND 9,000.00

The Contractor shall provide Performance Bond Guarantee of Bank operating in Malaysia, to the
Employer in a sum equal to five (5) percent of the Contract Sum, for the due observance and due
performance of the Contract under the terms of the Bond.

B DRAWINGS

The drawings issued to the Contractor for tendering purposes are listed in Appendix "A".

The Contractor shall check and examine the drawings and the accompanying tender documents to
satisfy himself that all information necessary for preparing his tender has been provided. Report any
missing drawings, documents, pages or other discrepancies to the Architect/S.O. No claims for
extra costs consequent upon non-examination of tender documents and drawings will be considered.

C CONSTRUCTION DRAWINGS

Two (2) sets of construction drawings shall be progressively issued to the Contractor for
construction purposes free of charge. Additional copies will be issued on request by the Contractor;
these will be charged to the Contractor.

Within one (1) month upon being given the official order to commence, the Contractor shall prepare
and submit to the Architect/S.O, and all Consultants, a detailed schedule with dates for timely
release of all construction drawings and details. Dates shall relate to critical times for start of
activities as per the accepted works programme.

E CONTRACT DOCUMENTS 22,500.00

The Contractor shall price the lithography charges for Contract Binding comprising Contract Drawings and Contract
Documents and reimburse to consultant accordingly once awarded.

D STAMP DUTY 18,750.00

The Contractor shall arrange the Contract Documents to be stamped and to bear all expenses
and any other fees incurred in the formalisation of this Contract between him and the Employer.

The Contractor shall prepare and submit to the Employer two (2) certified true copies and two (2)
original Contract Document immediately after the contract agreement has been formally executed.

E DISCREPANCIES IN CONTRACT DOCUMENTS

The several documents (including the drawings) forming the Contract are to be taken as mutually explanatory of
one another.

Immediately report any discrepancy to the Architect/S.O. and await further instructions before proceeding with
the Works.

TO COLLECTION : RM 50,250.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/14
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

TEMPORARY WORKS

A ACCESS AND EGRESS 12,500.00

Adhere strictly to the access and egress points shown on the drawings or such other access and
egress points approved by the Local Authorities.

Share the access and egress points with other Contractors engaged by the Employer. No claims will
be entertained in respect of any inconvenience or hindrance met by the Contractor due to sharing of
the access and egress points with other Contractors.

Construct temporary accessways, diversions, etc. wherever the Works interfere with the free flow of traffic or
pedestrian or otherwise with the existing road.

B SITE OFFICE AND TEMPORARY BUILDINGS 17,500.00

The Contractor shall provide and maintain the following temporary buildings and services at a
position to be directed by the Architect/S.O, remove on completion of the works and pay all
charges in connection therewith unless otherwise directed by the Architect/S.O. All designs for
temporary buildings must be approved by the Architect/S.O. before construction.

These temporary structures and the fixtures therein shall remain the property of the Main
Contractor on completion:-

a. Adequate lock-up weather proofed sheds for safe storage of building materials.

b. Sanitary conveniences for the operatives, Supervisory and site staff in approved positions
and in the conformity with the requirements of the Local Authorities, maintain them in good
and hygienic conditions and deodorise ground after removal.

Upon completion of the Works, or earlier if the Architect/S.O so decides, the Contractor shall dismantle and
remove the Site Office with all fittings and furniture, within one (1) week of being so directed.

C WORKER'S ACCOMMODATION - OFF SITE 22,464.00

Workmen's accommodation on-site is strictly prohibited. The Contractor shall pay for all costs in connection
therewtih, providing off-site accommodation for his own and sub-contractor's workmen outside the site and
adequate transportation for all the workers. The Contractor shall also arrange for security passes for all workers.

D PROJECT SIGNBOARD 2,250.00

The Contractor shall provide and maintain a new metal/timber project signboard in accordance
with details provided by Architect/S.O; complete with all signwriting, logos, lighting fixtures and wiring.

E HOARDING MAINTENANCE 6,250.00

The Contractor shall maintain the existing hoardings including gates, screens, planked footways,
guard rail and gantry, for the full duration of this Contract.

F FIRST AID KITS

The Contractor shall provide first aid kits at suitable locations on the Site and instruct an
adequate number of persons in their use.

TO COLLECTION : RM 60,964.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/15
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

STATUTORY REQUIREMENTS / INSURANCES

A INSURANCE AND STATUTORY OBLIGATIONS 28,786.00

The Contractor shall provide the following documents: -

a. Contractor's All Risk Policy
b. Workmen's Compensation
c. Insurance of Works
d. SOCSO Registration
e. CIDB

All insurances shall be taken up by the Contractor through as Insurance Company approved by the
Employer.

Without prejudice to his liability to indemnify the Employer under Clause 18, the Contractor shall take
out a Contractor's All Risks Policy in the joint names of the Employer, the Contractor and all his
Sub-Contractors.

For "Material Damage" the amounts to be insured shall be:-

a. the Contract Sum;
b. removal of debris - RM250,000.00 ; and
c. professional fees at the percentage named in the Appendix

The Sum Insured for "Third Parties Liability" shall be RM 1,000,000.00 for any one occurrence but unlimited as to
the number of occurrences during the Period of Insurance.

The policy shall have the following endorsements:-

a. strike, riot and civil commotion clause;
b. cross liability clause;
c. vibration and/or removal or weakening of support;
d. extended maintenance clause; and
e. extended coverage for rectification costs for defective design, materials and/or workmanship.
f. inclusion of Architect/S.O, Consultants and Consultants’ representative as “third parties”.
g. group personal accident insurance for site staff and Consultants

Without prejudice to his liability to indemnify the Employer under Clause 18, the Contractor
shall take out, and shall cause all his Sub-Contractors to take out, Workmen's Compensation
Insurance with Common Law coverage in the joint names of the Employer and the Contractor
(and of his own Sub-Contractors, if any) against liability of the said joint parties for damages
or compensation payable under the Workmen's Compensation Ordinance or any other laws of
Malaysia in respect of or in consequence of any accident or injury to or disease sustained by
any workmen or other persons in the employment of the said joint insured parties.

For the purpose of this Contract, the sum representing the estimated earnings to be insured under
the Workmen's Compensation Insurance shall not be less than 15% of the value of Contract Sum
after deducting the amount for all P.C. Sums. If any of the workmen employed in the Works are
liable for coverage under the SOCSO Scheme then the sum insured under the Workmen's
Compensation Insurance shall be reduced by the estimated earnings of the said workmen covered by
the SOCSO Scheme.

The Contractor shall bear the full amount of the deductibles or excess.

All insurances shall be valid and cover for the whole Contract and Defects Liability Period.

TO COLLECTION : RM 28,786.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/16
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

STATUTORY REQUIREMENTS / INSURANCES … (Cont'd)

A INSURANCE AND STATUTORY OBLIGATIONS (Cont'd)

The Contractor shall comply with PART VII of the Lembaga Pembangunan Industri Pembinaan
Malaysia Act 1994, and the Construction Industry (Levy Collection) Regulations 1996, and shall
submit a notification on Form CIDB L1/96 to the Lembaga not later than 14 days after the
issuance of the letter of Acceptance / Letter of Award / or any document that constitute
acceptance of a contract of works or not less than 14 days before the commencement of the
works, whichever date is earlier. Pay all fees are charged in connection therewith.

The Contractor shall register all his employees under the Social Security (SOCSO) Scheme, submit all
contributions regularly and comply with the SOCSO Regulations made under the Employee's Social
Security Act (including any amendment thereof); and cause all his Sub-Contractors to comply similarly.

B LOCAL AUTHORITIES AND STATUTORY OBLIGATIONS

The Contractor shall comply with all bye-laws issued by Municipal Board or other local authorities
throughout his work and shall meet the requirements of the Medical Officer of Health regarding
sanitation and hygiene of his installations on the site of the work, and of the employment of any
workmen whose presence on health grounds is considered undesirable by the Medical Officer of Health.

C LABOUR-ON-COSTS

The Contractor shall provide for all costs in respect of workmen, as applicable, for:-
a. Annual and Public Holidays.
b. Travelling time and expenses, such as fares and transport.
c. Non-productive time and other expenses in connection with overtime.
d. Incentive and bonus payments.
e. Any other disbursements arising from employment of labour, e.g. SOCSO.

The Contractor shall comply with all Safety, Health and Welfare Regulations pertaining to all workmen employed on
the site.

D SAFETY, HEALTH AND WELFARE OF WORKPEOPLE 9,250.00

Allow for complying with statutory rules and regulations concerning the safety, health and welfare
of workmen, including workmen employed by Nominated Sub-Contractors and Specialist.

The Contractor in this relation shall provide the Architect/S.O. with his safety programme and
procedure proposal and to be ensure that all safety requirements are strictly adhered at all times.

E WORKING HOURS

Provide for working at night, on Sundays and on Public Holidays if deemed necessary (subject to the
written permission of the Architect/S.O), the Contracto shall make adequate security arrangements
and indemnifying the Employer against any claims by third parties caused by working outside normal
working hours. No claims for extra remuneration on account of working outside normal working
hours shall be entertained.

The normal working hours of the Resident Architect and the Resident Supervisory Staff are as follows:-
i. Monday to Friday - 8.00 a.m. - 5.00 p.m.
ii. Saturday - 8.00 a.m. - 12.00 noon

TO COLLECTION : RM 9,250.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/17
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

CONTRACTOR'S EQUIPMENT & FACILITIES

A PLANT AND EQUIPMENT 25,000.00

The Contractor shall provide adequate plant and equipment, including minor plant and tools, for the proper and
timely execution of the Works such as:-
a. mechanical plant and vehicles
b. non-mechanical plant

The Contractor shall include plant needed for the Contractor's proposed methods of undertaking and completing
the works.

The Contractor shall use proper and modern plant and other labour and time saving devices to ensure that the
Works are carried out diligently and expeditiously.

The Contractor shall obtain the written approval and certificates from the relevant Authorities for
all mechanical plant used on site. Ensure that the validity of such certificates is maintained
throughout the period of use. Copies of all such certificates shall be submitted to the Architect/S.O.

Unserviceable or incorrect plant and equipment shall be removed expeditiously from the site.

B GENERAL SCAFFOLDING AND STAGING 9,250.00

Provide and maintain all necessary temporary scaffolding and staging together with planks,
battens, cat-walks, gangways, ladders, etc., and pay all costs and charges in connection therewith.

The scaffolding and temporary work shall comply with the requirements of MS10.1:1975 Sirim
Code of Practice for Building Operations Code and other codes as may be required by the
relevant Authorities.

The scaffolding and temporary work shall be endorsed by the Contractor's qualified inspector
with methodology report.

C SIGNS AND NOTICES 3,500.00

The Contractor shall provide, erect, maintain and remove on completion such 'Danger',
'Warning' and 'Directional' works and safety notices as are required and directed during the
progress of the Works. No other sign or advertisement shall be displayed without the prior
written consent of the Architect/S.O. These sign boards shall be properly sited at night time.

D MATERIAL TESTS

The Contractor shall allow for all expenses and fees (including cost of packing and delivery or
specimen and test reports) for all necessary tests which the Architect/S.O may direct the
Contractor to carry out in accordance with the Specifications.

Regardless of any specified tests, the Contractor shall undertake regular tests and checks to
ensure that the work is functional and as specified, providing requisite apparatus and
equipment, including skilled and experienced staff for the purpose of carrying out tests.

TO COLLECTION : RM 37,750.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/18
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

MANAGEMENT OF THE WORKS

A SITE SUPERVISORY AND ADMINISTRATIVE STAFF 25,000.00

The Contractor shall constantly provide adequate site supervisory and administrative staff for
the proper execution of the Works. Such persons shall be careful, skilled and experienced in
their several trades and callings.

The Contractor shall employ a competent and authorised Site Agent or General Foreman,
approved by the Architect/S.O, on the site. Such Agent or General Foreman shall give his full
time to the supervision and management of the works and must be able to receive and act on
behalf of the Contractor, all instructions, directions or orders issued by the Architect/S.O or his
representatives.

B AS BUILT DRAWINGS 9,250.00

The Contractor shall submit As-Built Drawings showing the actual works as constructed and
incorporating all changes for the whole works in A1 size paper, progressively during construction,
as per a pre-agreed schedule, wherein the last batch of drawings shall be submitted not more than
two (2) weeks from the date of issuance of Certificate of Practical Completion.

For this purpose, the Contractor must employ the services of a Licensed Surveyor who shall
certify all drawings correct. Drawings as specified for recording as built shall be agreed with
the Architect/S.O. or his representatives.

C SITE MEETING 3,750.00

The Contractor shall make arrangements for bi-weekly Site Meetings to be held at the site
office or elsewhere as directed by the Architect/S.O during which a senior member of his
staff and the General Foreman of the Works including those of Nominated Sub-Contractors
and Suppliers shall be required to attend. However, if the Architect/S.O deems that the
progress of the Works is slow or where problems occur on site, the Architect/S.O may require
weekly or fortnightly site meetings to be held. The Architect/S.O shall also record the
proceedings of these meetings and arrange for the reproduction and distribution of copies of
the minutes of meetings to all parties concerned before the next meeting.

D PROGRESS PHOTOGRAPHS 1,750.00

The Contractor shall allow for the cost of providing six sets of monthly progress photographs
of postcard size prints in colour of the various elevations and sections of the works during the
currency of the project.

E PROGRESS REPORTS 4,250.00

The Contractor shall submit to the Architect/S.O bi-weekly reports on the progress of the
Works, including those of the Specialist contracts indicating the number of workmen employed,
materials and goods delivered, the extent and type of plant employed, weather conditions and
generally the progress of the Works.

The progress of the works shall be represented by percentage as well as bar charts indicating actual
progress and the proposed progress for two weeks in advance. These reports are to be based on the
daily reports delivered to the Clerk-of-Works for signature.

TO COLLECTION : RM 44,000.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/19
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

MANAGEMENT OF THE WORKS … (Cont'd)

A SECURITY OF THE WORKS / WATCHING AND LIGHTING 2,750.00

The Contractor shall provide watchmen, lighting, warning lamps, guards, barriers and other
safeguards as necessary or as required by the Architect/S.O, Statutory or other Authorities
to prevent injury to all persons and property including the Works, the workmen and the public.

The Contractor shall safeguard the works and stored materials from theft, vandalism or other
damage caused by persons or animals.

The Contractor shall abide strictly with any pre-existing security arrangements employed on the site.

B SAFETY MEASURES

The Contractor shall provide and install all necessary protective netting or other measures for
the safety of workmen; protecting the public from all risks of injury, especially from flying or
dropping objects, etc. at all the stages of construction. Safety measures adopted shall satisfy
the requirements of the Local Authorities.

C ELECTRICAL LIGHTING & POWER FOR THE WORKS 12,500.00

Allow for the provision of all necessary electricity and power for the Works at various points of the Site.

All areas with inadequate natural lighting shall be lighted with temporary lights during the construction of the
Works.

The Contractor shall provide sufficient electricity for his own works and for those of the
Sub-Contractors and for the Consultants' and his own offices.

D WATER FOR THE WORKS 9,250.00

Allow for the provision of all necessary clean and fresh water for the use on the Works at various
points of the Site.

The Contractor shall provide sufficient water for his own works and for the Specialists and
Consultants and for drinking, cleaning, sewage disposal, fire-fighting etc.

E KEEPING THE SITE DRY 6,250.00

Upon taking possession of site the Contractor shall be responsible for keeping the whole of the
Works well drained and free from all water (including rain, storm, spring and running water and
water below the water Table Levels and the Contractor is to ascertain for himself the water levels
as no claims shall be entertained on the grounds that these levels are not known or water arising
from any other sources) at all to ensure that, so far as practicable, all work is carried out in the "dry".

The Contractor shall employ whatever means that may be necessary to keep the site and
excavated areas dry including baling, pumping (including power pumping), provision of temporary
drains, drainage pits, water courses and any other mean which the Architect/S.O. may direct.

The Contractor shall implement adequate measures to keep site free from surface water,
continuously over the Contract period including the construction of all additional temporary
drains and diversions, the building of walls or bunds or other forms of de-watering.

TO COLLECTION : RM 30,750.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/20
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

MANAGEMENT OF THE WORKS … (Cont'd)

A DRAINAGE DURING CONSTRUCTION

In addition to any other requirements mentioned elsewhere in the Contract, the Contractor
shall submit for the Architect/S.O's approval, prior to the commencement of construction or
the Works or any temporary works, detailed plans of the measures he proposes to take for the
drainage during construction of the Works and temporary works, the prevention of the
movement of eroded materials and debris from construction areas into natural watercourses
and on to adjoining land. The Main Contractor shall carry out at his own expenses all such
approved measures and any additional measures the Architect/S.O. may from time to time
require to improve their effectiveness. The operation of this Clause shall in no way absolve
the Contractor from any of his obligations under the Contract.

B MAINTENANCE AND PROTECTION OF PUBLIC PROPERTY

The Contractor is to maintain and protect public property including that of drainage, eletricity,
highway and water authorities and similar undertakings, and is to make good or pay for the
reinstatement of all damage thereto.

C MAINTENANCE OF EXISTING ROADS

The Contractor shall be responsible for any damage to existing roads, kerbs, drains, crossings,
culverts, etc. caused by his workmen, vehicle or plant or that of Nominated Sub-Contractors and
Nominated Suppliers, approaching or leaving the Site, and to mantain, repair and reinstate the
aforesaid to their original condition to the satisfaction of the Architect/S.O. or restoration as a
deduction from any money due to or become due to the Contractor under this Contract.

The Contractor shall also allow for all necessary hosing down, clearing any droppings deposited
on any public roads or highways. He shall also be responsible to keep roads immediately
adjacent to the site free from mud, dirt or rubbish arising out of or in the course of or by
reason of the execution of the Works.

D FIRE PRECAUTIONS

The Contractor shall initiate and enforce strict fire prevention measures on the works; taking
special precautions to avoid the outbreak of fire.

The Contractor shall strictly comply with the Uniform Building Bye Laws (UBBL) 1984 -
Amendment 2007 particular requirements on requirements on fire prevention during construction.

All fire fighting equipment shall conform with the requirements of the Fire Department. These
shall be maintained throughout the duration of this Contract. Portable fire extinguishers of
ABC 9 kg. type shall be properly housed in a box with breakglass and provided at every
section/segment of the site where works are being carried out. At least one fire extinguisher
shall be provided at each wing on every floor to high rise buildings, the position of which shall
be determined by the Architect. Undertake regular checks to ensure that the fire-fighting
equipment are functional.

E SPOIL DUMPING PREVENTION

The Contractor shall take all reasonable step to prevent excavated spoil, rubbish, surplus materials,
etc. arising from the works being dumped on an area other than a recognised tipping area.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/21
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

MANAGEMENT OF THE WORKS … (Cont'd)

A MOSQUITO PREVENTION 3,750.00

The Contractor shall take all precaution as deemed necessary by the Architect/S.O. and/or the
Local Authorities for the prevention of breeding of moiquito including pumping dry or bailing
out stagnant water at the site. The Contractor shall pay any charges made by the Local
Authorities for anti-malaria and anti-dengue measures taken.

B CLEARING AND CLEANING OF SITE 15,000.00

The Contractor will, on completion of the work, remove as quickly as possible and convey away
from site at his own cost, all surplus materials, except those ordered to be left on site,
together with all rubbish and debris and leave the work site in a clean and perfect condition to
the satisfaction of the Architect/S.O.

On complection of the work, all plant, building appliances, apparatus or equipment are to be
removed as quickly as possible and conveyed away from the site at the sole cost of the Contractor.
All services and roads, temporary buildings, shed barriers, etc. required in the work of construction
are, unless otherwise directed, to be disconnected, dismantled, taken down and removed. All holes,
trenches and excavation in connection with the plant, etc. are to be filled in a proper manner,
levelled off ad closely turfed and the site left in a clean and orderly condition.

In the event of the Contractor not clearing away the above mentioned materials and plant
within a stipulated time the Architect/S.O. and the Employer will be empowered to perform
such work, by employing a third party for such purpose and the cost of such clearing away will
be deducted from the Contractor's Final Account. The Architect/S.O. and the Employer will not
be held responsible or liable for any material or plant left upon the site.

C PENALTY

Letter of Complaint (LOC) claim retention and Defect Inspection Notification shall be followed
and checked on if found any unsatisfactory works.

A competent full time site representative on site shall be designated to coordinate and execute
the works, failure to attend any meetings, a fine of RM250.00 will be imposed.

Provision of safety and personnel protective equipments, reflective jackets and other safety
materials, eg. Helmets, belts, boots, to your workers, failing which a fine of RM250.00 per
offence will be imposed.

No illegal immigrants are to be employed and work at the site, if any, a penalty of RM1,000.00
will be imposed.

Daily disposal off unwanted materials, rubbish to a designated place is required at the site,
failing which we may employ third party to clear it on behalf and all costs incurred shall be
deducted from any money due to you.

TO COLLECTION : RM 18,750.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/22
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

A MISCELLANEOUS SW NO.1 - PRELIMINARIES

Where other items of cost involvement or item of monetary value related to this Contract have
not been allowed for in the SW NO.1 - PRELIMINARIES and Standard Conditions of Contract,
the Contractor shall list such item below together with their monetary values extended
accordingly in the monetary columns and carried to collection. No subsequent claims for
non-allowance of such items in the SW NO.1 - PRELIMINARIES shall be entertained should the
Contractor decide not to or fail to list such other item of costs involvement or items of
monetary value related to the Contract but which have not been allowed for in the SW NO.1 -
PRELIMINARIES and Standard Conditions of Contract of this Contract. The Architect/S.O.
and/or the Quantity Surveyor shall reserve the right to request for breakdown of all items of
cost that may be listed herein below.

List of other item of cost involvements required

a.

b.

c.

d.

TO COLLECTION : RM 0.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/23
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.1 - PRELIMINARIES

ITEM DESCRIPTION AMOUNT (RM)

COLLECTION

From Page No. SW1/PRELIM/1 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/2 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/3 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/4 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/5 ................. ................. ................ 3,000.00

From Page No. SW1/PRELIM/6 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/7 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/8 ................. ................. ................ 16,500.00

From Page No. SW1/PRELIM/9 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/10 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/11 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/12 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/13 ................. ................. ................ 0.00

From Page No. SW1/PRELIM/14 ................. ................ ................. 50,250.00

From Page No. SW1/PRELIM/15 ................. ................. ................ 60,964.00

From Page No. SW1/PRELIM/16 ................. ................. ................ 28,786.00

From Page No. SW1/PRELIM/17 ................. ................. ................ 9,250.00

From Page No. SW1/PRELIM/18 ................. ................. ................ 37,750.00

From Page No. SW1/PRELIM/19 ................. ................. ................ 44,000.00

From Page No. SW1/PRELIM/20 ................. ................. ................ 30,750.00

From Page No. SW1/PRELIM/21 ................. ................. ............... 0.00

From Page No. SW1/PRELIM/22 ................. ................. ............... 18,750.00

From Page No. SW1/PRELIM/23 ................. ................. .............. 0.00

TOTAL CARRIED TO SUMMARY OF TENDER : RM 300,000.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse SW1/PRELIM/24
CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH

Taking over the site from piling contractor 0.00

0.00
1.01 cut-off and dispose excess long of pile at required level nr 1,200 38.50 46,200.00
0.00
1.02 Allow for the provision of joint inspection of completed piling m² 7,287 3.00 21,861.00
work based on as-built survey and drawings; incidental and 0.00
temporary works; prepare subgrade and compact with 8-10 ton 0.00
paver roller; make good and remove debris from site 0.00
0.00
Pile Caps 0.00
0.00
Excavate pit; commencing from formation level part return, fill 0.00
in, well ram and remove surplus excavated material from site 0.00
0.00
1.03 not exceeding 1.50m deep m³ 355 14.00 4,970.00
0.00
1.04 exceeding 1.50m deep, but not exceeding 3.00m deep m³ 237 18.00 4,266.00
0.00
1.05 50mm Thick lean concrete Grade 15 m² 297 11.50 3,415.50
0.00
1.06 Reinforced concrete Grade 30 m³ 274 250.00 68,500.00
0.00
1.07 Sawn formwork m² 755 36.00 27,180.00
0.00
Steel bar reinforcement 0.00
0.00
1.08 10mm Ø high tensile rod as links, stirrups and binders kg 2,115 3.00 6,345.00
0.00
1.09 12mm Ø high tensile rod kg 266 3.00 798.00
0.00
1.10 16mm Ø high tensile rod kg 1,434 3.00 4,302.00
0.00
1.11 20mm Ø high tensile rod kg 12,052 3.00 36,156.00
0.00
1.12 25mm Ø high tensile rod kg 4,195 3.00 12,585.00
0.00
Stumps 0.00
0.00
1.13 Reinforced concrete Grade 30 m³ 22 250.00 5,500.00
0.00
1.14 Sawn formwork m² 173 36.00 6,228.00
0.00
Steel bar reinforcement 0.00
0.00
1.15 10mm Ø mild steel rod as links, stirrups and binders kg 6 3.00 18.00
0.00
1.16 10mm Ø high tensile rod kg 198 3.00 594.00
0.00
1.17 12mm Ø high tensile rod kg 310 3.00 930.00
0.00
1.18 16mm Ø high tensile rod kg 3,105 3.00 9,315.00
0.00
1.19 20mm Ø high tensile rod kg 3,416 3.00 10,248.00
0.00
1.20 25mm Ø high tensile rod kg 4,837 3.00 14,511.00
0.00
0.00
0.00

To Collection SW2/MBW/1(Add1) 283,922.50

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

Ground Beams
0.00
1.21 Excavate trench; not exceeding 1.50m deep; commencing from formation level, part m³ 57 14.00 798.00
return, fill in, well ram and remove surplus excavated material from site 0.00
0.00
1.22 50mm Thick lean concrete Grade 15 m² 141 11.50 1,621.50
0.00
1.23 Reinforced concrete Grade 30 m³ 57 250.00 14,250.00
0.00
1.24 Sawn formwork m² 802 36.00 28,872.00
0.00
Steel bar reinforcement 0.00
0.00
1.25 10mm Ø mild steel rod as links, stirrups and binders kg 4,373 3.00 13,119.00
0.00
1.26 10mm Ø high tensile rod kg 981 3.00 2,943.00
0.00
1.27 12mm Ø high tensile rod kg 1,425 3.00 4,275.00
0.00
1.28 16mm Ø high tensile rod kg 2,052 3.00 6,156.00
0.00
1.29 20mm Ø high tensile rod kg 830 3.00 2,490.00
0.00
1.30 25mm Ø high tensile rod kg 6,543 3.00 19,629.00
0.00
Chiller Water Trench for underground pipe 0.00
0.00
1.31 Excavate trench; not exceeding 1.50m deep; commencing from formation level, part m³ 168 14.00 2,352.00
return, fill in, well ram and remove surplus excavated material from site 0.00
0.00
1.32 150mm thick well-compacted hardcore m² 227 12.00 2,724.00
0.00
1.33 50mm Thick lean concrete Grade 15 m² 227 11.50 2,610.50
0.00
1.34 Reinforced concrete Grade 30 - 200mm thick m³ 365 50.00 18,250.00
0.00
1.35 Sawn formwork m² 317 36.00 11,412.00
0.00
1.36 Steel bar reinforcement - 10mm Ø high tensile rod kg 10,950 3.00 32,850.00
0.00
6mm thick chequered plate as trench cover; complete with 3mm thick stiffener plate, 0.00
25mm x 25mm x 3mm thick mild steel angle and fishtail 0.00
0.00
1.37 type 1 - 400mm wide x 150mm deep m 86 144.00 12,384.00
0.00
1.38 type 2 - 600mm wide x 500mm deep m 86 202.50 17,415.00
0.00
1.39 type 3 - 800mm wide x 500mm deep m 42 270.00 11,340.00
0.00
1.40 type 4 - 1200mm wide x 150mm deep m 13 216.00 2,808.00
0.00
HDPE corrugated underground drainage pipe 0.00
0.00
1.41 100mm Ø m 92 85.00 7,820.00
0.00
1.42 300mm Ø m 258 178.00 45,924.00
0.00
1.43 Concrete pipe support complete with reinforced concrete grade 30 with reinforcement m 350 120.00 42,000.00
bars T12 at 1000mm centres and 2 x T12 at every fittings

To Collection SW2/MBW/2(Add1) 304,043.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

0.00
Piled Raft Slab & Suspended Slab 0.00
0.00
1.44 Excavate oversite; not exceeding 0.5m deep; commencing m² 6,439 6.00 38,634.00
from formation level, part return, fill in, well ram and 0.00
remove surplus excavated material from site 0.00
0.00
1.45 Anti-termite with 5-year warranty m² 6,439 3.50 22,536.50
0.00
1.46 0.25mm thick non-biodegradable heavy duty polythene m² 6,439 3.50 22,536.50
sheet laid under concrete slab and around drop panel 0.00
0.00
1.47 150mm Thick well-compacted crusher run m² 6,439 12.00 77,268.00
0.00
Reinforced concrete Grade 30 0.00

1.48 180mm thick m² 6,439 45.00 289,755.00

0.00
1.49 1200mm x 1200mm x 450mm thick drop panel nr 810 135.00 109,350.00
0.00
1.50 Extra over for 150mm wide x 250mm deep thickening m 201 18.50 3,718.50

1.51 Sawn formwork to edge of slab; not exceeding 0.50m high m 4,527 18.00 81,486.00

Steel bar reinforcement

1.52 10mm Ø high tensile rod kg 570 3.00 1,710.00

0.00
1.53 12mm Ø high tensile rod kg 20,789 3.00 62,367.00
0.00
Steel fabric reinforcement: measured nett - no allowance for laps 0.00
0.00
1.54 BRC A8; weighing not less than 3.95kg/m2 m² 1,367 14.20 19,411.40
0.00
1.55 BRC A9; weighing not less than 4.99kg/m2 m² 4,161 18.00 74,898.00

1.56 BRC DA9; weighing not less than 9.98kg/m2 m² 4,883 30.30 147,954.90
0.00
1.57 BRC DA10; weighting not less than 12.32kg/m2 m² 9,057 38.50 348,694.50
0.00
1.58 Extra over for saw cut with compression filter, silicon sealing LS 15,000.00
compound at 6m centres spacing or smaller panel with 5mm x 25mm 0.00
deep machine at 6m x 6m each panels as described 0.00
0.00
1.59 Extra over for expansion joint with 250mm wide waterstop, and T12 LS 8,000.00
and T20 deformed bars for every concrete pour to engineer's detail 0.00
0.00
1.60 Extra over for construction joint to Engineer's detail LS 5,000.00
0.00
1.61 Extra over for 1500mm long 5T-12mm @ 100mm c/c spacing at LS 4,079.05
reinforced concrete column and slab area 0.00
0.00
1.62 Allow the provision for concrete slump and reinforcement test LS 3,000.00
0.00

0.00

To Collection SW2/MBW/3(Add2) 1,335,399.35

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

Ramp Slab 0.00

0.00
1.63 Reinforced concrete Grade 30 - 300mm thick m² 33 75.00 2,475.00
0.00
1.64 Steel bar reinforcement - 10mm Ø high tensile rod kg 990 3.00 2,970.00
0.00
1.65 BRC A8; weighing not less than 3.95kg/m2 m² 33 14.20 468.60
0.00
1.66 Extra over for forming groove line m² 33 25.00 825.00
0.00
1m x 1m sump - 40 nos 0.00
0.00
1.67 Excavate pit; not exceeding 1.50m deep; commencing from m³ 60 14.00 840.00
formation level part return, fill in, well ram and remove 0.00
surplus excavated material from site 0.00
0.00
1.68 150mm thick well-compacted hardcore m² 40 12.00 480.00
0.00
1.69 50mm Thick lean concrete Grade 15 m² 40 11.50 460.00
0.00
1.70 Sawn formwork m² 320 36.00 11,520.00

Reinforced concrete Grade 30 0.00

0.00
1.71 180mm thick to slab m² 40 45.00 1,800.00
0.00
1.72 200mm thick to wall m² 160 50.00 8,000.00
0.00
1.73 Steel bar reinforcement - 10mm Ø high tensile rod kg 7,200 3.00 21,600.00
0.00
1.74 Galvanised iron sump cover; constructed of T20 reinforcement bar, including R9 dowel nr 40 550.00 22,000.00
bar, 50mm x 9mm thick flat bars and 50mm centres, 65mm x 6mm thick angle frame, 0.00
heavy duty grating hinges, including all necessary fixing, painting and welded together 0.00
0.00
0.00
0.00
0.00

To Collection SW2/MBW/4(Add2) 73,438.60

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

COLLECTION

SW2/MBW/1(Add2) 283,922.50

SW2/MBW/2(Add2) 304,043.00

SW2/MBW/3(Add2) 1,335,399.35

SW2/MBW/4(Add2) 73,438.60

TO SUMMARY SW2/MBW/5(Add2) 1,996,803.45

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 FRAMES

Columns and Stiffeners for brickwall

0.00
2.01 Reinforced concrete Grade 30 m³ 176 250.00 44,000.00
0.00
2.02 Sawn formwork m² 1,238 36.00 44,568.00
0.00
Steel bar reinforcement

2.03 10mm Ø mild steel rod as links, stirrups and binders kg 30 3.00 90.00
0.00
2.04 10mm Ø high tensile rod kg 1,823 3.00 5,469.00
0.00
2.05 12mm Ø high tensile rod kg 110 3.00 330.00
0.00
2.06 16mm Ø high tensile rod kg 3,776 3.00 11,328.00
0.00
2.07 20mm Ø high tensile rod kg 162 3.00 486.00
0.00
2.09 25mm Ø high tensile rod kg 16,381 3.00 49,143.00
0.00
2.10 32mm Ø high tensile rod kg 3,037 3.00 9,111.00
0.00
Lintol Beam for doors, windows & roller shutter 0.00
0.00
2.11 Reinforced concrete Grade 30 m³ 8 250.00 2,000.00
0.00
2.12 Sawn formwork m² 237 36.00 8,532.00
0.00
Steel bar reinforcement 0.00
0.00
2.13 6mm Ø mild steel rod as links, stirrups and binders kg 389 3.00 1,167.00
0.00
2.14 10mm Ø high tensile rod kg 58 3.00 174.00
0.00
2.15 12mm Ø high tensile rod kg 905 3.00 2,715.00
0.00
2.16 16mm Ø high tensile rod kg 488 3.00 1,464.00
0.00
Staircase 0.00
0.00
2.17 Reinforced concrete Grade 30 m³ 53 250.00 13,250.00
0.00
2.18 Sawn formwork m² 465 36.00 16,740.00

Steel bar reinforcement 0.00

0.00
2.19 6mm Ø mild steel rod as links, stirrups and binders kg 187 3.00 561.00
0.00
2.20 10mm Ø high tensile rod kg 1,774 3.00 5,322.00
0.00
2.21 12mm Ø high tensile rod kg 283 3.00 849.00
0.00
2.22 16mm Ø high tensile rod kg 4,849 3.00 14,547.00
0.00
0.00
0.00
0.00

To Collection SW2/MBW/6 231,846.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 FRAMES (Cont'd)

First Floor Beam 0.00

0.00
2.23 Reinforced concrete Grade 30 m³ 171 250.00 42,750.00
0.00
2.24 Sawn formwork m² 1,543 36.00 55,548.00
0.00
Steel bar reinforcement 0.00
0.00
2.25 6mm Ø mild steel rod as links, stirrups and binders kg 8,576 3.00 25,728.00
0.00
2.26 10mm Ø high tensile rod kg 69 3.00 207.00
0.00
2.27 12mm Ø high tensile rod kg 4,271 3.00 12,813.00
0.00
2.28 16mm Ø high tensile rod kg 5,888 3.00 17,664.00
0.00
2.29 20mm Ø high tensile rod kg 1,662 3.00 4,986.00
0.00
2.30 25mm Ø high tensile rod kg 26,781 3.00 80,343.00
0.00
2.31 32mm Ø high tensile rod kg 1,163 3.00 3,489.00
0.00
Second Floor Beam 0.00
0.00
2.32 Reinforced concrete Grade 30 m³ 50 250.00 12,500.00
0.00
2.33 Sawn formwork m² 448 36.00 16,128.00
0.00
Steel bar reinforcement 0.00
0.00
2.34 6mm Ø mild steel rod as links, stirrups and binders kg 2,669 3.00 8,007.00
0.00
2.35 12mm Ø high tensile rod kg 1,775 3.00 5,325.00
0.00
2.36 16mm Ø high tensile rod kg 1,763 3.00 5,289.00
0.00
2.37 20mm Ø high tensile rod kg 828 3.00 2,484.00
0.00
2.38 25mm Ø high tensile rod kg 9,363 3.00 28,089.00
0.00
2.39 32mm Ø high tensile rod kg 2,669 3.00 8,007.00
0.00
Roof and Upper Floor Beams 0.00
0.00
2.40 Reinforced concrete Grade 30 m³ 56 250.00 14,000.00
0.00
2.41 Sawn formwork m² 515 36.00 18,540.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00

To Collection SW2/MBW/7 361,897.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 FRAMES (Cont'd)

Roof and Upper Floor Beams (Cont'd)

Steel bar reinforcement 0.00

0.00
2.42 6mm Ø mild steel rod as links, stirrups and binders kg 2,669 3.00 8,007.00
0.00
2.43 12mm Ø high tensile rod kg 1,775 3.00 5,325.00
0.00
2.44 16mm Ø high tensile rod kg 1,764 3.00 5,292.00
0.00
2.45 20mm Ø high tensile rod kg 798 3.00 2,394.00
0.00
2.46 25mm Ø high tensile rod kg 9,363 3.00 28,089.00
0.00
2.47 32mm Ø high tensile rod kg 2,669 3.00 8,007.00

First Floor Slab

Reinforced concrete Grade 30

2.48 150mm thick m² 59 37.50 2,212.50

0.00
2.49 200mm thick m² 1,001 50.00 50,050.00
0.00
2.50 250mm thick m² 2,416 62.50 151,000.00
0.00
2.51 Sawn formwork m² 3,362 36.00 121,032.00
0.00
Steel fabric reinforcement: measured nett - no allowance for laps 0.00
0.00
2.52 BRC A8; weighing not less than 3.95kg/m2 m² 91 14.20 1,292.20
0.00
2.53 BRC B7; weighing not less than 4.53kg/m2 m² 427 16.40 7,002.80
0.00
2.54 BRC B8; weighing not less than 5.92kg/m2 m² 1,028 21.00 21,588.00
0.00
2.55 BRC B9; weighing not less than 6.97kg/m2 m² 5,406 23.40 126,500.40

Second Floor Slab

Reinforced concrete Grade 30 0.00

0.00
2.56 150mm thick m² 23 37.50 862.50
0.00
2.57 175mm thick m² 92 43.75 4,025.00
0.00
2.58 200mm thick m² 263 50.00 13,150.00
0.00
2.59 Sawn formwork m² 378 36.00 13,608.00
0.00
Steel fabric reinforcement: measured nett - no allowance for laps 0.00
0.00
2.60 BRC A8; weighing not less than 3.95kg/m2 m² 46 14.20 653.20
0.00
2.61 BRC B7; weighing not less than 4.53kg/m2 m² 92 16.40 1,508.80
0.00
2.62 BRC B8; weighing not less than 5.92kg/m2 m² 618 21.00 12,978.00

To Collection SW2/MBW/8 584,577.40

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 FRAMES (Cont'd)

Roof Slab

Reinforced concrete Grade 30 0.00

0.00
2.63 150mm thick m² 77 37.50 2,887.50
0.00
2.64 175mm thick m² 67 43.75 2,931.25
0.00
2.65 250mm thick m² 314 62.50 19,625.00
0.00
2.66 Sawn formwork m² 458 36.00 16,488.00
0.00
Steel fabric reinforcement: measured nett - no allowance for laps 0.00
0.00
2.69 BRC A8; weighing not less than 3.95kg/m2 m² 153 14.20 2,172.60
0.00
2.70 BRC B7; weighing not less than 4.53kg/m2 m² 134 16.40 2,197.60
0.00
2.71 BRC B9; weighing not less than 6.97kg/m2 m² 629 23.40 14,718.60
0.00
2.72 50mm-75mm thick cement and sand (1:3) protective paving laid to falls m² 458 69.60 31,876.80
over waterproofing membrane; with BRC and cut induce joint max 0.00
1.5m x 1.5m intervals and groove sealed with sealant nad backer rods 0.00
0.00
2.73 Prepare and apply 2 layers of Proofkote 550; complete with m² 458 44.00 20,152.00
application of layer of non shrink grout and chapped strain 0.00
mat (CSM) Fiber 100g/m2, all in accordance to the 0.00
manufacturer's specification; providing 10-years warranty 0.00
0.00
2.74 Extra over 300mm x 50mm depth scupper drain m 86 51.00 4,386.00
0.00
0.00
0.00
0.00
0.00

To Collection SW2/MBW/9 117,435.35

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 FRAMES (Cont'd)

COLLECTION

SW2/MBW/6 231,846.00

SW2/MBW/7 361,897.00

SW2/MBW/8 584,577.40

SW2/MBW/9 117,435.35

TO SUMMARY SW2/MBW/10 1,295,755.75

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 STEEL STRUCTURE

Note: i) The Contractor shall provide a full time team at Site to plant the
anchor bolts. Setting out of anchor bolts positions shall be License
Surveyor and two (2) sets of setting out drawings endorsed by Licensed
Surveyor shall be submitted to Engineer progressively for record.

ii) Unless otherwise agreed, all steel structure shall be welded with
steel lugs. No steel structure shall be allowed to be lifted without
steel lugs. The steel lugs will remain at the steel structure after
erection but shall be painted.

iii) Painting also applies to all bolts and nuts and sag rods.

iv) The Contract Sum shall be deemed to have included the testing
and particles inspection to welding at steel structure members
selected by the S.O. and conducted by independent laboratory.

v) All mild steel surface to be painted shall be clean and dry from
dirt, dust, grease, oil and other contaminants before application
of paint. It is important that the standard should be maintained
until the paint is applied on. If the steel colour or rust bloom
begins to form, it will be necessary or reblast the steel.

Supply, hoist and fixed In position fabricated weldable steel structure

including non-shrink grout, enchased in concrete, anti-rust bolts, nuts and
washers, anchor bolts, plates, stiffeners, shop and site cutting, welding,
drilling, bolting and splice plate welding and all necessary fixing
accessories. (Painting measured separately)
0.00
Main portal frame 0.00
0.00
3.01 UB - 838mm x 292mm x 176kg/m kg 240,387 4.45 1,069,722.15
0.00
3.02 UC1 - 610mm x 305mm x 238kg/m kg 226,533 4.45 1,008,071.85

3.03 UC3 - 457mm x 152mm x 82kg/m kg 4,052 4.45 18,031.40

3.04 UB - 356mm x 171mm x 45kg/m kg 11,597 4.45 51,606.65

Tie Beam

3.05 UB - 356mm x 171mm x 45kg/m kg 49,695 4.45 221,142.75

0.00
3.06 UB - 356mm x 127mm x 39kg/m kg 5,616 4.45 24,991.20

To Collection SW2/MBW/11(Add2) 2,393,566.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 STEEL STRUCTURE (Cont'd)

Gutter Support

3.07 SHS - 100mm x 100mm x 4mm thk x 11.73kg/m kg 8,837 4.45 39,324.65

Truss T1 / T1A and Jack Roof

3.08 SHS - 150mm x 150mm x 5mm thk x 22.26kg/m kg 26,369 4.45 117,342.05

Facial Truss
0.00
3.09 SHS - 100mm x 100mm x 5mm thk x 14.41kg/m kg 7,997 4.45 35,586.65
0.00
3.10 SHS - 100mm x 100mm x 4mm thk x 11.73kg/m kg 21,884 4.45 97,383.80
0.00
3.11 SHS - 75mm x 75mm x 4mm thk x 8.59kg/m kg 8,400 4.45 37,380.00
0.00
3.12 SHS - 50mm x 50mm x 3mm thk x 4.25kg/m kg 702 4.45 3,123.90
0.00
Canopy Truss 0.00
0.00
3.13 SHS - 50mm x 50mm x 3mm thk x 4.25kg/m kg 805 4.45 3,582.25
0.00
3.14 SHS - 25mm x 25mm x 3mm thk x 1.89kg/m kg 330 4.45 1,468.50

Bracing Pipe / Tie Rod

3.15 Angle - 150mm x 75mm x 12mm thk x 20.20kg/m kg 3,499 4.45 15,570.55
0.00
3.16 Mild steel plate; varies thickness kg 123,341 4.45 548,867.45
0.00
3.17 Accessories, bolts, nuts and the like kg 74,004 4.45 329,317.80
0.00
3.18 Wind Bracing Tie Rod 22mm diameter with turnbuckles m 2,145 27.00 57,915.00
0.00
3.19 Holding down bolt M24 x 600mm Long nr 332 53.00 17,596.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00

0.00
0.00

To Collection SW2/MBW/12(Add2) 1,304,458.60

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 STEEL STRUCTURE (Cont'd)

0.00
Painting to all Mild Steel Structure 0.00
0.00
3.20 Surface preparation : Sand blast "Swedish Standard 2.5" kg 512,233 0.20 102,446.60
0.00
3.21 Supply, prepare and apply the following "KOSSAN" painting system to kg 512,233 0.44 225,382.52
structural steelwork and shall be protected within 4 hours after being cleared 0.00
- One coat of "Kossan Transpoxy Masterbond BT Clear 4.68" primer coat 0.00
- Two coats of "Kossan Transpoxy Masterbond BT Clear 4.68 Grey" finishing coat 0.00
Miniumum Dry Film Thickness = 250 microns 0.00
Minimum 10-year warranties 0.00
0.00
3.22 Surface preparation : Power brush "ST3" or "SSPC SP3" kg 301,815 0.12 36,217.80
0.00
3.23 Supply, prepare and apply the following "NIPPON" painting system to structural kg 301,815 0.24 72,435.60
steelwork and shall be protected within 4 hours after being cleared 0.00
- One coat of "Nippon Zinc Chormic" primer coat 0.00
- Two coats of "Nippon Micaceous Iron Oxide (MIO) Grey" finishing coat
Miniumum Dry Film Thickness = 200 microns
Minimum 2-year warranty

Galvanised Roof & Wall Purlin

0.00
3.24 203mm x 71mm x 16mm x 2mm thick YCP 2020 to roof kg 51,844 4.45 230,705.80
0.00
3.25 12mm diameter sag rod kg 1,431 4.45 6,367.95
0.00
3.26 203mm x 71mm x 16mm x 2mm thick YCP 2020 to wall kg 24,939 4.45 110,978.55
0.00
3.27 12mm diameter sag rod kg 693 4.45 3,083.85
0.00
Painting to all Mild Steel Structure 0.00
0.00
3.28 Surface preparation : Galvanised wash kg 78,907 0.20 15,781.40
0.00
3.29 Supply, prepare and apply the following "KOSSAN" painting system to kg 78,907 0.44 34,719.08
structural steelwork and shall be protected within 4 hours after being cleared 0.00
- One coat of "Kossan Transpoxy Masterbond BT Clear 4.68" primer coat 0.00
- Two coats of "Kossan Transpoxy Masterbond BT Clear 4.68 Grey" finishing coat 0.00
Miniumum Dry Film Thickness = 250 microns 0.00
Minimum 10-year warranties 0.00
0.00
Side opening stainless steel wire mesh with certificate 10 x 10mm 0.00
with 1mm thick 0.00
0.00
3.30 Stainless steel wire mesh with Grade 316 m² 340 250.00 85,000.00

To Collection SW2/MBW/13 923,119.15

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 STEEL STRUCTURE (Cont'd)

COLLECTION

SW2/MBW/11(Add2) 2,393,566.00

SW2/MBW/12(Add2) 1,304,458.60

SW2/MBW/13 923,119.15

TO SUMMARY SW2/MBW/14(Add2) 4,621,143.75

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

4 ROOFS & WALL CLADDING

Roof Cladding

Note: i) No lapping for roof is permitted.

ii) The Contract Sum shall deemed to be included the mobilisation

and demobilisation of roll forming machineries at site.

iii) The tenderers shall provide warranty for roof/wall light with minimum
warranty against penetration of water through the actual sheet for a
period of 5 years; warranty against light transmission value of not
less than 70% of the original value over a period of 5 years and
warranty against protrusion of glass fibre for a period of 1 year.

iv) Rate of the roof / wall cladding shall be inclusive of Corner

copping/ trim to wall of eave & gutter, Corner capping/trim to
wall of canopy fascia, Corner capping/trim at gable end fascia,
Base capping/trim to wall cladding, etc , all as described and
necessary as directed by the S.O

v) Ridge capping, fascia cappings, barge and parapet flashing and

stopped end, external and internal corner pieces shall be of the
same gauges, material and finish as that of the main roof, fascia
and wall cladding and all edges shall have moulded closures to suit
the main decking or cladding area.

vi) Fixing accessories and fasteners shall carried out in 0.00

strict accordance with manufacturer's instruction. 0.00
0.00
4.01 Supply and deliver for 0.9mm TCT aluminium roof cladding "ALCOM m² 7,214 82.50 595,155.00
COMSPAN", complete with color bottom PVDF Grey and color top PE 0.00
Grey; including fixing corrosion resistant fasteners and all other 0.00
necessary accessories

4.02 Labour and tools to lay aluminium roof cladding "ALCOM" m² 7,214 8.50 61,319.00
0.00
4.03 5mm thick aluminium & metalized foil; "COOLMAX CP3 NET FIBER m² 7,214 9.70 69,975.80
FREE"; thermal reflective insulation bonded to fire retardant 0.00
reinforce high density polyethylene leno fabric with special material 0.00
0.00
4.04 50mm thick fiberglass insulation m² 7,214 5.30 38,234.20
0.00
4.05 Standard ridge capping m 110 42.70 4,697.00
0.00
4.06 Fascia and edge capping m 821 42.70 35,056.70
0.00
4.07 Flashing between brickwall and metal roofing with profile m 500 42.70 21,350.00
0.00
4.08 2400gsm (1.5mm thick) Vermax Lite FR Ultra Fire-Retardant m² 547 130.00 71,110.00
fibreglass reinforced polyester translucent sheet; including 0.00
minimum 2-year warranty 0.00
0.00
0.00
0.00
0.00

0.00
0.00

To Collection SW2/MBW/15 896,897.70

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

4 ROOFS & WALL CLADDING (Cont'd)

Floor cladding 0.00

4.09 Supply and deliver ONLY 0.7mm TCT aluminium floor cladding "ALCOM"; m² 48.00
0.7mm x 889mm Stucco Embossed with color bottom and top Bare
Aluminium Colour, including fixing corrosion resistant fasteners and all
other necessary accessories

4.10 Labour and tools to lay aluminium roof cladding "ALCOM" m² 8.50

Wall Cladding 0.00

0.00
4.11 Supply and deliver ONLY 0.5mm TCT Aluminium wall cladding "ALCOM"; m² 4,549 44.00 200,156.00
complete with internal colour PE Grey (15μ), external colour PE cream 0.00
smooth (15μ) smooth with primer (5μ) each for both side, including 0.00
fixing corrosion resistant fasteners and all other necessary accessories 0.00
0.00
4.12 Labour and tools to lay aluminium wall cladding "ALCOM" m² 4,549 8.50 38,666.50
0.00
4.13 2400gsm (1.5mm thick) Vermax Lite FR Ultra Fire-Retardant FRP m² 406 130.00 52,780.00
translucent sheet (colour code: blue to match with cladding 0.00
profile); including minimum 2-year warranty 0.00
0.00
4.14 Fascia capping to wall cladding m² 775 42.70 33,092.50
0.00
Unplasticised Polyvinyl Chloride (uPVC) Rainwater Downpipe to BS4514 with solid steel 0.00
bracket
0.00
4.15 160mm Ø; vertically m 922 54.00 49,788.00
0.00
4.16 160mm Ø; discharge to the nearest parameter drain m 188 54.00 10,152.00
0.00
4.17 160mm Ø; rain water outlets / dome nr 65 36.00 2,340.00
0.00
4.18 160mm Ø; extra for bends nr 130 36.00 4,680.00
0.00
4.19 160mm Ø; extra for tee nr 10 70.00 700.00
0.00
UPVC/0.5mm thick stainless steel gutter; bent to profile, one 0.00
end fixed to steel frames and other end tucked under roof decking, 0.00
including anti-rust holding clips, brackets, making holes for rainwater 0.00
down pipe and other necessary fixing accessories all as specified 0.00

4.19 size 600mm wide x 655mm deep m 457 270.00 123,390.00

4.20 600mm x 600mm x 1000mm deep collection brick sump; nr 30 500.00 15,000.00
constructed with 225mm thick brickwall, rendering to all 0.00
exposed surfaces with 20mm cement and sand (1:3) including 0.00
forming all inlets/outlets for incoming and outgoing drains 0.00
0.00
4.21 600mm x 600mm galvanised iron grating; including SS304 1B nr 30 880.00 26,400.00
perforated plate with 4mm thick as top cover

To Collection SW2/MBW/16(Add2) 557,145.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

4 ROOFS & WALL CLADDING (Cont'd)

COLLECTION

SW2/MBW/15 896,897.70

SW2/MBW/16(Add2) 557,145.00

TO SUMMARY SW2/MBW/17(Add2) 1,454,042.70

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

5 WALLS

Note: i) Rate shall include all connection jointing with wiremesh

between two different material (concrete/brickwall)

ii) 6mm Diameter mild steel rod 350mm long as bonding tie
with one end cast into concrete and the other end builts
into joints of brickwall

iii) Approved started bar at the junction of brickwall and concrete

iv) 20mm thick cement and sand grouting

External Brickwall
0.00
Common clay brickwall laid in cement and sand (1:3) mortar 0.00
including 'exmet' reinforcement at every fourth course, well 0.00
lapped with bonding ties/dowels and etc 0.00
0.00
5.01 115mm thick m² 1,838 39.00 71,682.00
0.00
5.02 115mm thick as parapet brickwall m² 193 39.00 7,527.00
0.00
5.03 230mm thick m² 256 78.00 19,968.00
0.00
Horizontal damp proof course well lapped at joints and intersections 0.00
0.00
5.04 115mm thick m 322 1.80 579.60
0.00
5.05 230mm thick m 61 3.60 219.60
0.00
Internal Brickwall 0.00
0.00
Common clay brickwall laid in cement and sand (1:3) mortar 0.00
including 'exmet' reinforcement at every fourth course, well 0.00
lapped with bonding ties/dowels and etc 0.00
0.00
5.05 75mm thick as box up m² 63 26.00 1,638.00
0.00
5.06 115mm thick m² 1,225 39.00 47,775.00
0.00
5.07 230mm thick m² 583 78.00 45,474.00
0.00
Horizontal damp proof course well lapped at joints and intersections 0.00
0.00
5.08 75mm thick as box up m 9 1.20 10.80
0.00
5.09 115mm thick m 179 1.80 322.20
0.00
5.10 230mm thick m 74 3.60 266.40
0.00
External Feature 0.00
0.00
5.11 Reinforced concrete and precast concrete coping, moulding, m 44 70.00 3,080.00
cantilever, coping slab, hood, groove line and etc, all as described 0.00
including plastering, painting and all the necessary work 0.00
0.00
5.12 150mm thick GRC coping, moulding, cantilever, coping slab, hood,groove line and etc, m 25 50.00 1,250.00
all as described including plastering, painting and all the necessary work 0.00
0.00

TO SUMMARY SW2/MBW/18 199,792.60

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

6 DOORS & WINDOWS

Doors

Note: i) Rate shall include set of door, complete with frame,

ironmongeries, painting and the like, etc

ii) All aluminium sections for doors are to be minimum 1.5mm thick
unless otherwise specified.

iii) All metal door frames are to be minimum 1.0mm thick

Zincalume' metal frames unless otherwise specified

iv) All door ironmongeries are to be ''St. Guchi S.S. "or other approved
equivalent heavy duty stainless steel locksets/lock cylinders complete
with stainless steel hinges, approved door closers and accessories.

v) All timber/metal surfaces to be painted with one coat of "ICI"

primer sealer and two coats of "ICI GLOSS 104
EXECUTIVE GREY" enamel paint unless stated otherwise.

vi) All aluminium roller shutter to be completed with

painted metal frame, motor and drum, control panel,
etc all to manufacturer's details

vii) All door vision panel to have dimension of 600mm wide x 800mm
high for vision panel except wicket door and fire-rated door

Fire-rated door 0.00

0.00
6.01 1000mm x 2100mm high single leaf 2-hour fire rated door (Bomba nr 8 1,260.00 10,080.00
Approved) with aluminium frame and 5mm thick fixed glass vision 0.00
panel (Type FD1) 0.00
0.00
6.02 1800mm x 2100mm high double leaf two hour fired rated door nr 2 2,268.00 4,536.00
(Bomba Approved) with aluminium frame and 5mm thick fixed glass 0.00
vision panel (Type FD2) 0.00
0.00
Metal plate door 0.00
0.00
6.03 1000mm x 2100mm high single leaf with metal frame and 5mm thick nr 7 1,680.00 11,760.00
fixed glass vision panel (Type D1) 0.00

Aluminium louvred door

6.04 2400mm x 3000mm high single leaf with metal frame and 5mm thick nr 2 3,600.00 7,200.00
fixed glass vision panel (Type D8) 0.00
0.00
PVC door 0.00
0.00
6.05 750mm x 2100mm high single leaf with metal frame (Type D4) nr 13 349.50 4,543.50
0.00
Aluminium frame glass door 0.00

6.06 4924mm x 2400mm high double leaves with aluminium frame and nr 1 6,507.60 6,507.60
8mm thick fixed glass panel (Type D10)

To Collection SW2/MBW/19 44,627.10

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

6 DOORS & WINDOWS (Cont'd)

Doors (Cont'd)

Timber flush door 0.00

0.00
6.07 900mm x 2100mm high single leaf with metal frame and 5mm thick nr 2 661.50 1,323.00
fixed glass vision panel (Type D7) 0.00
0.00
6.08 1000mm x 2100mm high single leaf with metal frame; complete with nr 9 735.00 6,615.00
5mm thick fixed glass panel (Type D9) 0.00
0.00
6.09 1800mm x 2400mm high single leaf with metal frame; complete with nr 3 1,512.00 4,536.00
5mm thick fixed glass panel (Type D9A) 0.00
0.00
2-hour fire rated aluminium roller shutter
0.00
6.10 3000mm x 3000mm high motorised operated (Type RS3) nr 1 4,117.50 4,117.50
0.00
6.11 4000mm x 3000mm high motorised operated (Type RS4) to chlorine nr 2 5,400.00 10,800.00
0.00
6.12 4500mm x 3000mm high motorised operated (Type RS5) nr 5 6,075.00 30,375.00
0.00
Mild steel corrugated sliding door 0.00
0.00
6.13 5829mm x 5050mm high stainless steel Grade 316 wire mesh sliding door nr 6 18,956.70 113,740.20
(Type MSD1) 0.00
0.00
6.14 Extra over for 1000mm x 2300mm high wicket door and clear acrylic nr 6 825.00 4,950.00
0.00
Windows 0.00
0.00
Note: i) Rate shall include set of window, complete with frame, 0.00
glazing, ironmongeries and the like, etc 0.00
0.00
ii) All aluminium sections for windows are to be minimum
1.1mm thick natural anodised unless otherwise specified

iii) All aluminium installations are to be with sub-frame

system with concealed fasterners unless otherwise specified.

iv) All glass panels for toilets are to be dark frosted

tinted glass unless otherwise specified.

v) All window ironmongeries are to be provided including all necessary

glazing beads and gaskets, locks, sliding gears, recessed finger
pull, push/pull handles and accessories unless otherwise specified.

Natural anodised frame window 0.00

0.00
6.15 1200mm x 1200mm high top hung window panel with 5mm thick dark nr 9 403.20 3,628.80
tinted glass panel (Type W1) 0.00

6.16 2200mm x 750mm high top hung window panel with 5mm thick dark nr 4 462.00 1,848.00
frosted tinted glass panel (Type W3)

To Collection SW2/MBW/20 181,933.50

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

6 DOORS & WINDOWS (Cont'd)

Windows (Cont'd)

Natural anodised frame window (Cont'd)

6.17 3925mm x 1500mm high with top hung and fixed panel window with nr 15 1,650.60 24,759.00
5mm thick dark tinted glass (Type W10) 0.00
0.00
6.18 1150mm x 1200mm high casement window panel with 5mm thick nr 2 386.40 772.80
frosted clear tinted glass panel (Type W11) 0.00
0.00
6.19 Plain metal framed with overall size 1250mm x 1200mm high nr 10 420.00 4,200.00
complete with removable stainless steel wire mesh with 2 panels, 0.00
all to manufacturer's detail (Type W12) 0.00
0.00
6.20 Plain metal framed with overall size 4850mm x 1200mm high nr 14 1,629.60 22,814.40
complete with removable stainless steel wire mesh with 8 panels, 0.00
all to manufacturer's detail. (Type W13) 0.00
0.00
6.21 1800mm x 750mm high top hung window with 5mm thick dark tinted nr 2 378.00 756.00
glass (Type W14) 0.00
0.00
6.22 1800mm x 1500mm high top hung and fixed panel window with 5mm nr 1 756.00 756.00
thick dark tinted glass (Type W15) 0.00
0.00
6.23 750mm x 750mm high top hung window with 5mm thick dark tinted nr 2 179.20 358.40
glass (Type W16) 0.00
0.00
6.24 3050mm x 1200mm high top hung window with 5mm thick clear nr 7 1,024.80 7,173.60
tinted glass (Type W17) 0.00
0.00
6.25 1800mm x 1200mm high top hung window with 5mm thick clear nr 3 604.80 1,814.40
tinted glass (Type W17A) 0.00
0.00
6.26 5400mm x 1200mm high composite unit and sliding counter window nr 1 1,814.40 1,814.40
panel with 5mm thick clear tinted glass with 4 panels 0.00
(Type W18) 0.00
0.00
6.27 4800mm x 600mm high aluminium louvre panel with mosquito wire nr 2 806.40 1,612.80
net with 8 panels, all to manufacturer's detail. (Type W19) 0.00
0.00
0.00
0.00

0.00

To Collection SW2/MBW/21 66,831.80

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

6 DOORS & WINDOWS (Cont'd)

COLLECTION

SW2/MBW/19 44,627.10

SW2/MBW/20 181,933.50

SW2/MBW/21 66,831.80

TO SUMMARY SW2/MBW/22 293,392.40

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

7 WALL FINISHES

External Wall Finishes

0.00
7.01 20mm thick cement and sand (1:6) mixed with an approved m² 2,896 26.00 75,296.00
plasticiser externally as described plainface to walls and columns; 0.00
complete with PVC corner bead 0.00
0.00
7.02 Prepare and apply one coat of sealer and two coats of weather m² 2,896 13.20 38,227.20
shield paint "ICI DULUX 12138 BANANA" 0.00
0.00
Internal Wall Finishes 0.00
0.00
7.03 20mm thick cement and sand (1:6) mixed with an approved m² 6,638 24.00 159,312.00
plasticiser internally as described plainface to walls and columns; 0.00
complete with PVC corner bead 0.00
0.00
7.04 Prepare and apply one coat of solvent base sealer 1500 and two m² 4,647 12.60 58,552.20
coats of gloss paint "KTH 5953 PAPRUS 2056" at 2100mm high 0.00
0.00
7.05 Prepare and apply one coat of sealer and two coats of emulsion m² 1,991 8.40 16,724.40
paint "ICI DULUX 12393 MAXILITE LINEN" above gloss paint 0.00
0.00
7.06 20mm thick cement and sand (1:4) screed mixed with adhesive m² 598 22.00 13,156.00
setting bed to wall to receive wall tiles

7.07 300mm x 300mm "WHITE HORSE C30032" homogeneous wall tiles with m² 472 70.00 33,040.00
smooth finish; including pointed in white cement to toilet 0.00
0.00
7.08 Extra over "GUOCERA KV951" strip tiles to male toilet m² 63 70.00 4,410.00
0.00
7.09 Extra over "GUOCERA KV905" strip tiles to female toilet m² 63 70.00 4,410.00
0.00
0.00
0.00
0.00
0.00

TO SUMMARY SW2/MBW/23 403,127.80

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

8 FLOOR FINISHES
0.00
8.01 Prepare and apply power float surface with concrete Grade 30, m² 7,077 5.00 35,385.00
without any cement render and floor hardener 0.00
0.00
8.02 20mm thick cement and sand (1:4) rendering m² 160 24.00 3,840.00
0.00
Floor Tiles 0.00
0.00
8.03 20mm thick cement and sand (1:3) levelling screed with adhesive m² 1,196 22.00 26,312.00
setting bed to receive floor tiles
0.00
8.04 Ditto; to skirting 100mm high m 591 2.20 1,300.20
0.00
8.05 Ditto; to drop 100mm high m 35 2.20 77.00
0.00
8.06 300mm x 300mm "GUOCERA KV953" homogeneous floor tiles with m² 136 70.00 9,520.00
matte finish; including pointed in white cement to toilet and utility

8.07 300mm x 300mm "GUOCERA KV908" ceramic floor tiles with matte m² 1,060 70.00 74,200.00
finish; including pointed in white cement to office and WTT room
0.00
8.08 Ditto; to skirting 100mm high m 591 7.00 4,137.00
0.00
8.09 Ditto; to drop 100mm high m 35 7.00 245.00
0.00
Waterproofing (10 Years Warranty) 0.00
0.00
8.10 Prepare and apply 2 coats of "Sika Top Seal 107"; 2 part polymer modified, m² 136 35.00 4,760.00
portable water cementitious waterproof mortar slurry comprising of a liquid 0.00
polymer and cement based mix incorporating special admixtures at a rate of 0.00
1.0kg/m2/coat as described all in accordance with manufacturer 0.00
specifications and instructions to floor to fall and drop 50mm & 25mm high; 0.00
to toilet, kitchen, water tank, m&e room, retail, canteen, WTT room 0.00
0.00
8.11 Extra over for 300mm high upturn inclusive of treated with Sika m 226 10.50 2,373.00
Sealtape-F 0.00
0.00
8.12 Extra over for working around floor trap including forming groove nr 33 30.00 990.00
and sealing joints 0.00
0.00

TO SUMMARY SW2/MBW/24 163,139.20

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

9 CEILING FINISHES

Note: i) Rates shall include odd panels at borders of room.

ii) Rates shall include forming opening / recess for lighting.

iii) All ceilings shall be set out symmetrically from centre of room.

External Ceiling Finishes 0.00

0.00
9.01 3mm Thick skim coat "SIKA Brefill Mortar" to concrete slab soffit and m² 233 8.00 1,864.00
sides of beams 0.00
0.00
9.02 Prepare and apply one coat of sealer and two coats of weather shield m² 233 13.20 3,075.60
paint "ICI DULUX 12138 BANANA" 0.00
0.00
Internal Ceiling Finishes 0.00
0.00
1220mm x 610mm x 12mm thick USG Boral exposed grid gypsum 0.00
plasterboard suspended ceiling; complete with hollow section 0.00
support system, DX1 main tee and DX1 cross tee; including 0.00
hangers etc as specified 0.00
0.00
9.03 Moisture-resistant "Vinyl Laminated" m² 136 42.20 5,739.20
0.00
9.04 Non-moisture resistant "Press Engraved" m² 1,060 35.20 37,312.00
0.00
9.05 extra over for 1100mm high L-Box m 10 46.40 464.00
0.00
9.06 3mm Thick skim coat "SIKA Brefill Mortar" to concrete slab soffit and sides of beams m² 7,237 8.00 57,896.00
0.00
9.07 Prepare and apply one coat of sealer and two coats of emulsion paint "ICI DULUX m² 7,237 8.40 60,790.80
MAXILITE 12393 LINEN" 0.00
0.00
0.00
0.00

TO SUMMARY SW2/MBW/25 167,141.60

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

10 STAIRCASE FINISHES

20mm thick cement and sand (1:3) levelling screed with adhesive setting bed to receive 0.00
floor tiles
0.00
10.01 Landing slab m² 103 22.00 2,266.00
0.00
10.02 Riser 162.5mm high m 277 4.40 1,218.80
0.00
10.03 Tread 275mm wide m 277 6.60 1,828.20
0.00
10.04 Skirting 100mm high m 183 2.20 402.60
0.00
300mm x 300mm "Alpha YLH04M" ceramic floor tiles with matte 0.00
finish; including pointed in white cement 0.00
0.00
10.05 Landing slab m² 103 70.00 7,210.00
0.00
10.06 Riser 162.5mm high m 277 14.00 3,878.00
0.00
10.07 Tread 275mm wide m 277 21.00 5,817.00
0.00
10.08 Skirting 100mm high m 183 7.00 1,281.00
0.00
10.09 Extra over for 300mm x 75mm x 7mm thick "GUOCERA ESN 908" nosing tile m 277 38.50 10,664.50
0.00
20mm thick cement and sand (1:4) levelling screed 0.00
0.00
10.10 Landing slab m² 31 24.00 744.00

10.11 Riser 162.5mm high m 130 4.80 624.00

0.00
10.12 Tread 275mm wide m 130 7.20 936.00

10.13 Extra over for 200mm x 75mm x 7mm thick "GUOCERA ESN 950" nosing tile m 130 38.50 5,005.00
0.00
3mm thick "SIKA Brefill Mortar / Fine White" 0.00
0.00
10.14 Soffit and sides of landing slabs m² 134 8.00 1,072.00
0.00
10.15 Sloping soffit of staircase m² 129 8.00 1,032.00
0.00
10.16 Soffit and sides of landing beam m² 68 8.00 544.00

10.17 Open stringer of staircase m 158 4.00 632.00

0.00
Prepare and apply one coat of solvent base sealer 1500 and two 0.00
coats of gloss paint "KTH 5953 PAPRUS 2056" at 2100mm high 0.00
0.00
10.18 Soffit and sides of landing slabs m² 134 12.60 1,688.40
0.00
10.19 Sloping soffit of staircase m² 129 12.60 1,625.40
0.00
10.21 Soffit and sides of landing beam m² 68 12.60 856.80

10.20 Open stringer of staircase m 158 6.30 995.40

TO SUMMARY SW2/MBW/26 50,321.10

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

11 HANDRAILING AND BALUSTRADING

Polished stainless steel railing to staircase; complete with 60mm Ø

circular hollow section tube as top rail; 40mm Ø circular hollow section
as vertical post rail and 25mm Ø circular hollow section tube as
horizontal sub-frame rail

11.01 1000mm high x 60mm Ø circular hollow section tube as top rail m 167 345.00 57,615.00

Powder coated railing constructed of 50mm Ø handrail; including

painting, base plate, bolts and nuts and all necessary fixing accessories 0.00
0.00
11.02 1200mm high at factory 1st and 2nd floor m 92 160.00 14,720.00
0.00
11.03 1500mm high above chlorine gas room m 70 200.00 14,000.00
0.00
0.00
0.00
0.00

TO SUMMARY SW2/MBW/27 86,335.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

12 SANITARY WARES AND FITTINGS

Supply and fix sanitary wares and fittings "JOHNSON SUISSE/DOE";

including extra labour in finishing tiles around fittings and
including all joints and connecting to supply, waste, soil, vent
and overflow pipes
0.00
For kitchen and retail 0.00
0.00
12.01 DOE "CF6020SSDEBSD" Stainless steel kitchen sink lay-on double nr 2 500.00 1,000.00
bowl single drainer 0.00
0.00
12.02 DOE "DE115A" pillar mounted sink mixer c/w 200mm swivel nr 2 150.00 300.00
anti-splash aerator outlet 0.00
0.00
12.03 150mm x 150mm stainless steel floor trap nr 2 28.00 56.00
0.00
For male & female toilet

12.04 Johnson Suisse "Andermatt WBACAM000WW" squatting pan nr 7 533.50 3,734.50

0.00
12.05 Johnson Suisse closed coupled washdown wc with plastic cristen tank nr 8 936.00 7,488.00
0.00
12.06 Johnson Suisse "Santana 320 WBSIST121WW" wall hung urinal nr 8 841.00 6,728.00
0.00
12.07 Johnson Suisse "Boston 400 WBSABS100WW" wall hung basin nr 11 350.00 3,850.00
0.00
12.08 DOE "DE101" manual self closing pillar tap nr 11 161.50 1,776.50
0.00
12.09 DOE "HB72" hose bib nr 15 45.00 675.00
0.00
12.10 DOE "DE71" hand bidet c/w flexible hose and wall bracket nr 15 104.50 1,567.50
0.00
12.11 600mm x 500mm high mirror nr 11 314.00 3,454.00
0.00
12.12 DOE "SB1503" paper holder nr 15 80.00 1,200.00
0.00
12.13 DOE "SB1501" soap dispenser nr 6 150.00 900.00
0.00
12.14 150mm x 150mm stainless steel floor trap nr 22 28.00 616.00
0.00
For ablution 0.00
0.00
12.15 DOE 117A ablution tap nr 4 85.00 340.00
0.00
12.16 150mm x 150mm stainless steel floor trap nr 4 28.00 112.00
0.00
For WTT room 0.00
0.00
12.17 Johnson Suisse "Trezzo 480 WBAATZ201WW" wall hung basin nr 2 350.00 700.00
0.00
12.18 DOE "DE101" manual self closing pillar tap nr 2 161.50 323.00
0.00
12.19 150mm x 150mm stainless steel floor trap nr 2 28.00 56.00
0.00

TO SUMMARY SW2/MBW/28 34,876.50

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

13 SUNDRIES

Squatting WC Stooling
0.00
13.01 Allow for concrete works with concrete grade 30, extra formwork and nr 7 130.20 911.40
reinforcement; for squatting WC at common toilet 0.00
0.00
Urinal Partition 0.00
0.00
13.02 Urinal fixed panel; including approved accessories and all nr 4 400.00 1,600.00
necessary fittings in accordance with manufacturer's details

Reinforced Concrete Custom Made Counter Top Completed With Finishes

13.03 size 1850mm x 600mm x 200mm to male & female toilet nr 1 1,110.00 1,110.00
0.00
13.04 size 1500mm x 600mm x 200mm to male & female toilet nr 1 900.00 900.00
0.00
0.00
0.00
0.00

TO SUMMARY SW2/MBW/29 4,521.40

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT
KILANG 1 TINGKAT BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT
PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS
UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS
LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL
EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.2 - FACTORY (BLOCK 1) AND WAREHOUSE

ITEM DESCRIPTION AMOUNT (RM)

SUMMARY

1 WORK BELOW LOWEST FLOOR FINISH SW2/MBW/5(Add2) 1,996,803.45

2 FRAMES & FLAT ROOFS SW2/MBW/10 1,295,755.75

3 STEEL STRUCTURE SW2/MBW/14(Add2) 4,621,143.75

4 ROOF AND WALL CLADDING SW2/MBW/17(Add2) 1,454,042.70

5 WALLS SW2/MBW/18 199,792.60

6 DOORS & WINDOWS SW2/MBW/22 293,392.40

7 WALL FINISHES SW2/MBW/23 403,127.80

8 FLOOR FINISHES SW2/MBW/24 163,139.20

9 CEILING FINISHES SW2/MBW/25 167,141.60

10 STAIRCASE FINISHES SW2/MBW/26 50,321.10

11 HANDRAILING AND BALUSTRADING SW2/MBW/27 86,335.00

12 SANITARY WARES AND FITTINGS SW2/MBW/28 34,876.50

13 SUNDRIES SW2/MBW/29 4,521.40

TOTAL CARRIED TO SUMMARY OF TENDER SW2/MBW/SUM(Add2) 10,770,393.25

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR
DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.3 - LINK BRIDGE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 STEEL STRUCTURE

Note: i) The Contractor shall provide a full time team at Site to plant the
anchor bolts. Setting out of anchor bolts positions shall be License
Surveyor and two (2) sets of setting out drawings endorsed by Licensed
Surveyor shall be submitted to Engineer progressively for record.
0.00
ii) Unless otherwise agreed, all steel structure shall be welded with steel lugs. No 0.00
steel structure shall be allowed to be lifted without steel lugs. The steel lugs will 0.00
remain at the steel structure after erection but shall be painted. 0.00
0.00
iii) Painting also applies to all bolts and nuts and sag rods. 0.00
0.00
iv) The Contract Sum shall be deemed to have included the testing 0.00
and particles inspection to welding at steel structure members 0.00
selected by the S.O. and conducted by independent laboratory. 0.00
0.00
v) All mild steel surface to be painted shall be clean and dry from dirt, dust, 0.00
grease, oil and other contaminants before application of paint. It is important that 0.00
the standard should be maintained until the paint is applied on. If the steel colour 0.00
or rust bloom begins to form, it will be necessary or reblast the steel. 0.00
0.00
Supply, hoist and fixed In position fabricated weldable steel structure including 0.00
non-shrink grout, enchased in concrete, anti-rust bolts, nuts and washers, anchor 0.00
bolts, plates, stiffeners, shop and site cutting, welding, drilling, bolting and splice 0.00
plate welding and all necessary fixing accessories. (Painting measured separately) 0.00
0.00
Main Portal Frame 0.00
0.00
1.01 UC - 203mm x 203mm x 46 kg/m kg 13,697 4.45 60,951.65
0.00
1.02 SHS - 150mm x 150mm x 8mm thk x 33.95 kg/m kg 9,539 4.45 42,448.55
0.00
1.03 SHS - 100mm x 100mm x 5mm thk x 14.41 kg/m kg 4,100 4.45 18,245.00
0.00
1.04 YCP 2020 kg 659 4.45 2,932.55
0.00
1.05 YCP 1520 kg 1,151 4.45 5,121.95
0.00
1.06 12mm diameter sag rod kg 45 4.45 200.25
0.00
1.07 Mild steel plate, accessories, bolts, nuts and the like kg 5,838 4.45 25,979.10
0.00
1.08 Holding down bolt M24 x 600mm Long nr 24 53.00 1,272.00
0.00
Painting to all Mild Steel Structure 0.00
0.00
1.09 Surface preparation : Power brush "ST3" or "SSPC SP3" kg 35,029 0.12 4,203.48
0.00
1.10 Supply, prepare and apply the following "NIPPON" painting system to kg 35,029 0.24 8,406.96
structural steelwork and shall be protected within 4 hours after being 0.00
cleared, all in accordance with manufacturer's instruction and requirement:- 0.00
- One coat of "Nippon Zinc Chormic" primer coat 0.00
- Two coat of "Nippon Micaceous Iron Oxide (MIO) Grey" finishing coat 0.00
Total average miniumum Dry Film Thickness = 200 microns 0.00
Minimum 2-year warranty 0.00
0.00
1.11 Reinforced concrete Grade 30 - 115mm thick m² 60 28.75 1,725.00
0.00
1.12 BRC A8; weighing not less than 3.95kg/m2 m² 60 14.20 852.00
0.00
1.13 1mm thick Lysaght Bondek II steel sheeting; complete with shear studs m² 60 63.50 3,810.00

TO SUMMARY SW3/LB/1 176,148.49

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR
DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.3 - LINK BRIDGE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 ROOFS & WALL CLADDING

Roof Cladding

Note: i) No lapping for roof is permitted.

ii) The Contract Sum shall deemed to be included the mobilisation

and demobilisation of roll forming machineries at site.

iii) The tenderers shall provide warranty for roof/wall light with
minimum warranty against penetration of water through the
actual sheet for a period of 5 years; warranty against light
transmission value of not less than 70% of the original value over a
period of 5 years and warranty against protrusion of glass fibre for
a period of 1 year.

iv) Rate of the roof / wall cladding shall be inclusive of Corner

copping/ trim to wall of eave & gutter, Corner capping/trim to
wall of canopy fascia, Corner capping/trim at gable end fascia,
Base capping/trim to wall cladding, etc , all as described and
necessary as directed by the S.O

v) Ridge capping, fascia cappings, barge and parapet flashing and

stopped end, external and internal corner pieces shall be of the
same gauges, material and finish as that of the main roof, fascia
and wall cladding and all edges shall have moulded closures to suit
the main decking or cladding area.

vi) Fixing accessories and fasteners shall carried out in

strict accordance with manufacturer's instruction. 0.00
0.00
2.01 Supply and deliver for 0.7mm TCT aluminium roof cladding "ALCOM"; m² 58 48.00 2,784.00
0.7mm x 889mm Stucco Embossed with color bottom and top Bare 0.00
Aluminium Colour, including fixing corrosion resistant fasteners and all 0.00
other necessary accessories 0.00
0.00
2.02 Labour and tools to lay aluminium roof cladding "ALCOM" m² 58 8.50 493.00
0.00
2.03 5mm thick aluminium & metalized foil; "COOLMAX CP3 NET FIBER m² 58 9.70 562.60
FREE"; thermal reflective insulation bonded to fire retardant 0.00
reinforce high density polyethylene leno fabric with special material 0.00
0.00
2.04 50mm thick fiberglass insulation m² 58 5.30 307.40
0.00
2.05 Standard ridge capping m 5 42.70 213.50
0.00
2.06 Fascia and edge capping m 12 42.70 512.40
0.00
2.07 Flashing between brickwall and metal roofing with profile m 24 42.70 1,024.80
0.00
Wall Cladding 0.00
0.00
2.08 Supply and deliver for 0.5mm TCT Aluminium wall cladding "ALCOM"; m² 90 44.00 3,960.00
complete with internal colour PE Grey (15μ), external colour PE cream 0.00
smooth (15μ) smooth with primer (5μ) each for both side, including 0.00
fixing corrosion resistant fasteners and all other necessary accessories 0.00
0.00
2.09 Labour and tools to lay aluminium wall cladding "ALCOM" m² 90 8.50 765.00
0.00
2.10 Fascia capping to wall cladding m² 23 42.70 982.10
0.00

To Collection SW3/LB/2 11,604.80

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR
DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.3 - LINK BRIDGE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 ROOFS & WALL CLADDING (Cont'd)

Unplasticised Polyvinyl Chloride (uPVC) Rainwater Downpipe to BS4514 with solid steel 0.00
bracket
0.00
2.11 160mm diameter; vertically m 20 54.00 1,080.00
0.00
2.12 160mm Diameter; discharge to the nearest parameter drain m 40 54.00 2,160.00
0.00
2.13 160mm Diameter; rain water outlets / dome nr 2 36.00 72.00
0.00
2.14 160mm Diameter; extra for bends nr 4 36.00 144.00
0.00
2.15 600mm x 200mm wide UPVC/0.5mm thick stainless steel gutter; bent to profile, m 10 224.82 2,248.15
one end fixed to steel frames and other end tucked under roof decking, 0.00
including anti-rust holding clips, brackets, making holes for rainwater down pipe 0.00
and other necessary fixing accessories all as specified

To Collection SW3/LB/3 5,704.15

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR
DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.3 - LINK BRIDGE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 ROOFS & WALL CLADDING (Cont'd)

COLLECTION

SW3/LB/2 11,604.80

SW3/LB/3 5,704.15

TO SUMMARY SW3/LB/4 17,308.95

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR
DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.3 - LINK BRIDGE

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

SUMMARY

STEEL STRUCTURAL 176,148.49

ROOF AND CLADDING WORKS 17,308.95

TOTAL CARRIED TO SUMMARY OF TENDER SW3/LB/5 193,457.44

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH

0.00 0.00
Pile Caps 0.00 0.00
0.00 0.00
1.01 Excavate pit; not exceeding 1.50m deep; commencing m³ 14.00 7 98.00 5 70.00
from formation level, part return, fill in, well ram and 0.00 0.00
remove surplus excavated material from site 0.00 0.00
0.00 0.00
1.02 50mm thick lean concrete Grade 15 m² 11.50 5 57.50 4 46.00
0.00 0.00
1.03 Reinforced concrete Grade 30 m³ 250.00 4 1,000.00 3 750.00
0.00 0.00
1.04 Sawn formwork m² 36.00 20 720.00 13 468.00
0.00 0.00
Steel bar reinforcement

1.05 10mm Ø mild steel rod as links, stirrups and binders kg 3.00 39 117.00 26 78.00

1.06 16mm Ø high tensile rod kg 3.00 385 1,155.00 190 570.00
0.00 0.00
Stumps 0.00 0.00
0.00 0.00
1.07 Reinforced concrete Grade 30 m³ 250.00 2 500.00 1 250.00
0.00 0.00
1.08 Sawn formwork m² 36.00 5 180.00 4 144.00
0.00 0.00
Steel bar reinforcement

1.09 10mm Ø mild steel rod as links, stirrups and binders kg 3.00 22 66.00 15 45.00

1.10 12mm Ø high tensile rod kg 3.00 534 1,602.00 422 1,266.00

Ground Beams 0.00 0.00

0.00 0.00
1.11 Excavate trench; not exceeding 1.50m deep; commencing m³ 14.00 2 28.00 2 28.00
from formation level, part return, fill in, well ram and 0.00 0.00
remove surplus excavated material from site 0.00 0.00
0.00 0.00
1.12 50mm thick lean concrete Grade 15 m² 11.50 3 34.50 3 34.50
0.00 0.00
1.13 Reinforced concrete Grade 30 m³ 250.00 1 250.00 1 250.00
0.00 0.00
1.14 Sawn formwork m² 36.00 15 540.00 15 540.00
0.00 0.00
Steel bar reinforcement

1.15 6mm Ø mild steel rod as links, stirrups and binders kg 3.00 18 54.00 25 75.00

1.16 10mm Ø high tensile rod kg 3.00 15 45.00

1.17 12mm Ø high tensile rod kg 3.00 77 231.00 20 60.00

1.18 16mm Ø high tensile rod kg 3.00 81 243.00

Ramp Slab 0.00 0.00

0.00
1.19 Reinforced concrete Grade 30 - 150mm thick m² 37.50 2 75.00
0.00
1.20 Steel bar reinforcement - 10mm diameter high tensile rod kg 3.00 3 9.00
0.00
1.21 BRC A7; weighing not less than 3.02kg/m2 m² 12.50 4 50.00
0.00
1.22 Extra over for forming groove line m² 25.00 2 50.00
0.00
0.00
0.00
0.00

To Collection SW4/AB/1 6,633.00 5,146.50

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

Suspended Ground Slabs 0.00

0.00 0.00
1.23 Excavate oversite; not exceeding 0.5m deep; commencing m² 6.00 27 162.00 15 90.00
from formation level, part return, fill in, well ram and 0.00 0.00
remove surplus excavated material from site 0.00 0.00
0.00 0.00
1.24 Anti-termite with 5-year warranty m² 3.50 27 94.50 15 52.50
0.00 0.00
1.25 0.25mm thick non-biodegradable heavy duty polythene m² 3.50 27 94.50 15 52.50
sheet laid under concrete slab 0.00 0.00
0.00 0.00
1.26 150mm thick well-compacted crusher run m² 12.00 27 324.00 15 180.00
0.00 0.00
Reinforced concrete Grade 30

1.27 125mm thick m² 31.25 27 843.75

0.00
1.28 135mm thick m² 33.75 15 506.25

1.29 Extra over 150mm x 38mm depth scupper drain m 34.00 4 136.00
0.00
1.30 Steel bar reinforcement - 10mm diameter kg 3.50 41 143.50 23 80.50
0.00 0.00
1.31 BRC A7; weighing not less than 3.02kg/m2 m² 12.50 54 675.00 30 375.00
0.00 0.00
Apron Slab 0.00
0.00
1.32 Excavate oversite; not exceeding 0.5m deep; commencing m² 6.00 23 138.00
from formation level, part return, fill in, well ram and remove 0.00
surplus excavated material from site 0.00
0.00
1.33 0.25mm thick non-biodegradable heavy duty polythene sheet m² 3.50 23 80.50
laid under concrete slab 0.00
0.00
1.34 150mm Thick well-compacted crusher run m² 12.00 23 276.00
0.00
1.35 Reinforced concrete Grade 30 - 125mm thick m² 31.25 23 718.75
0.00
1.36 Steel bar reinforcement - 10mm diameter high tensile rod kg 3.50 127 444.50
0.00
1.37 BRC A7; weighing not less than 3.02kg/m2 m² 12.50 23 287.50
0.00
1.38 Extra over for 200mm wide x 200mm deep thickening m 35.00 24 840.00

To Collection SW4/AB/2 5,122.50 1,472.75

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH (Cont'd)

COLLECTION

SW4/AB/1 6,633.00 5,146.50

SW4/AB/2 5,122.50 1,472.75

TO SUMMARY SW4/AB/3 11,755.50 6,619.25

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

2 FRAMES

Columns 0.00 0.00

2.01 Reinforced concrete Grade 30 m³ 250.00 2 500.00 1 250.00

0.00 0.00
2.02 Sawn formwork m² 36.00 5 180.00 12 432.00
0.00 0.00
Steel bar reinforcement 0.00 0.00

2.03 10mm Ø mild steel rod as links, stirrups and binders kg 3.00 79 237.00 40 120.00

2.04 12mm Ø high tensile rod kg 3.00 396 1,188.00 269 807.00
0.00 0.00
Lintol Beam for doors, windows & roller shutter 0.00 0.00

2.05 Reinforced concrete Grade 30 m³ 250.00 2 500.00 3 750.00

0.00 0.00
2.06 Sawn formwork m² 36.00 18 648.00 27 972.00
0.00 0.00
2.07 Steel bar reinforcement - 12mm Ø high tensile rod kg 3.00 297 891.00 446 1,338.00
0.00 0.00
Coping with throating 0.00 0.00

2.08 Reinforced concrete Grade 30 m³ 250.00 1 250.00 1 250.00

0.00 0.00
2.09 Sawn formwork m² 36.00 13 468.00 12 432.00
0.00 0.00
2.10 Steel bar reinforcement - 10mm Ø high tensile rod kg 3.00 59 177.00 39 117.00
0.00
Parapet Wall 0.00

2.11 Reinforced concrete Grade 30 m³ 250.00 4 1,000.00

0.00 0.00
2.12 Sawn formwork m² 36.00 24 864.00
0.00 0.00
2.13 Steel bar reinforcement - 12mm Ø high tensile rod kg 3.00 533 1,599.00
0.00
Roof Beams 0.00

2.14 Reinforced concrete Grade 30 m³ 250.00 2 500.00 1 250.00

0.00 0.00
2.15 Sawn formwork m² 36.00 20 720.00 15 540.00
0.00 0.00
Steel bar reinforcement 0.00 0.00

2.16 6mm Ø mild steel rod as links, stirrups and binders kg 3.00 21 63.00 16 48.00

2.17 12mm Ø high tensile rod kg 3.00 59 177.00 67 201.00

2.18 16mm Ø high tensile rod kg 3.00 33 99.00

Roof Slab 0.00

2.19 Reinforced concrete Grade 30 - 125mm thick m² 31.25 35 1,093.75

0.00
2.20 Sawn formwork m² 36.00 35 1,260.00
0.00
2.21 BRC A7; weighing not less than 3.02kg/m2 m² 12.50 70 875.00
0.00
2.22 50mm-75mm thick cement and sand (1:3) protective paving laid to falls m² 69.60 35 2,436.00
over waterproofing membrane; with BRC and cut induce joint max 0.00
1.5m x 1.5m intervals and groove sealed with sealant nad backer rods 0.00 0.00
0.00 0.00
2.23 Prepare and apply 2 layers of Proofkote 550; complete with m² 44.00 35 1,540.00 24 1,056.00
application of layer of non shrink grout and chapped strain mat (CSM) 0.00 0.00
Fiber 100g/m2, all in accordance to the manufacturer's specification; 0.00 0.00
providing 10-years warranty to roof slab and parapet wall 0.00

2.24 Extra over 150mm x 25mm depth scupper drain m 34.00 6 204.00

TO SUMMARY SW4/AB/4 14,006.75 11,026.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

3 ROOFS

Roof Covering 0.00 0.00

0.00 0.00
3.01 Lightweight steel framing system; comprising circular hollow m² 140.00 18 2,520.00 15 2,100.00
section mild steel, connection plates, bolts and anchorages; 0.00 0.00
including fabrication, transportation, erection, surface 0.00 0.00
preparation, welding, filling smooth junctions and painting one 0.00 0.00
coat of Micaceous Iron Oxide primer and two finishing coats of gloss 0.00 0.00
enamel paint; hoisting and fixing in position to a height as per 0.00 0.00
Engineer details; including providing 10 years performance warranty 0.00 0.00
(measured nett - no allowance made for laps) 0.00 0.00
0.00 0.00
3.02 Supply, deliver, labour and tools to lay zincalume roofing; m² 52.00 18 936.00 15 780.00
0.47mm thick total coated thickness (TCT) Coolzal AZ150 in 0.00 0.00
cream color; including fixing corrosion resistant fasteners and 0.00 0.00
all other necessary accessories 0.00
0.00
3.03 5mm thick aluminium & metalized foil; "COOLMAX CP3 m² 9.70 18 174.60
Net Fiber Free"; thermal reflective insulation bonded to fire 0.00
retardant reinforce high density polyethylene leno fabric 0.00
0.00 0.00
3.04 Fascia and edge capping m 42.70 15 640.50 11 469.70
0.00 0.00
3.05 Flashing between brickwall and metal roofing with profile m 42.70 22 939.40 16 683.20
0.00 0.00
UPVC/0.5mm thick stainless steel gutter; bent to profile, one end fixed to 0.00 0.00
steel frames and other end tucked under roof decking, including anti-rust 0.00
holding clips, brackets, making holes for rainwater down pipe and other 0.00
necessary fixing accessories all as specified 0.00
0.00
3.06 150mm x 230mm wide m 80.00 29 2,320.00

3.07 150mm x 400mm wide m 120.00 4 480.00

0.00
Unplasticised Polyvinyl Chloride (uPVC) Rainwater Downpipe to 0.00 0.00
BS4514 with solid steel bracket
0.00 0.00
3.08 110mm Ø; vertically m 36.00 8 288.00 3 108.00
0.00 0.00
3.09 110mm Ø; discharge to the nearest parameter drain m 36.00 16 576.00 6 216.00
0.00 0.00
3.10 110mm Ø; rain water outlets nr 24.00 2 48.00 1 24.00
0.00 0.00
3.11 110mm Ø; extra for bends nr 24.00 4 96.00 2 48.00
0.00 0.00
3.12 230mm diameter x 350mm average deep perimeter drain in suitable m 104.00 21 2,184.00 17 1,768.00
length; laid to fall;bedded, jointed and pointed in cement and sand 0.00 0.00
(1:3)mortar with and including concrete base; including all necessary 0.00
excavation, formwork, junction, ends and disposal of surplus 0.00
excavated material away from site 0.00 0.00
0.00 0.00
3.13 600mm x 600mm x 1000mm deep brick sump; constructed with nr 500.00 2 1,000.00 1 500.00
225mm thick brickwall, rendering to all exposed surfaces with 0.00 0.00
20mm cement and sand (1:3) including forming all 0.00 0.00
inlets/outlets for incoming and outgoing drains 0.00 0.00
0.00 0.00
3.14 600mm x 600mm galvanised iron grating; including SS304 1B nr 880.00 2 1,760.00 1 880.00
perforated plate with 4mm thick as top cover 0.00 0.00
0.00
3.15 160mm diameter waste, soil and vent pipes; complete with outlet m 300.00 14 4,200.00
grating to connecting manholes or water channel drains including 0.00
all necessary excavation, concrete casing around pipework 0.00
0.00
3.16 900mm long x 900mm wide x 1500mm deep shallow manhole nr 880.00 1 880.00
consisting of brickwork chamber sides and rendered internally 0.00
with 20mm thick alumina cement and sand (1:2)
0.00 0.00

TO SUMMARY SW4/AB/5 18,562.50 8,056.90

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

4 WALLS

Note: i) Rate shall include all connection jointing with wiremesh

between two different material (concrete/brickwall)

ii) 6mm Diameter mild steel rod 350mm long as bonding tie
with one end cast into concrete and the other end builts
into joints of brickwall

iii) Approved started bar at the junction of brickwall and concrete

iv) 20mm thick cement and sand grouting

External Brickwall
0.00 0.00
Common clay brickwall laid in cement and sand (1:3) mortar
including 'exmet' reinforcement at every fourth course, well
lapped with bonding ties/dowels and etc 0.00
0.00
4.01 115mm thick m² 39.00 79 3,081.00 42 1,638.00
0.00
4.02 300mm thick m² 97.50 35 3,412.50
0.00
Horizontal damp proof course well lapped at joints and intersections 0.00
0.00
4.03 115mm thick m 1.80 45 81.00 16 28.80
0.00
4.04 300mm thick m 4.50 11 49.50
0.00
Internal Brickwall 0.00
0.00
4.05 115mm thick common clay brickwall laid in cement and m² 39.00 57 2,223.00
sand (1:3) mortar including 'exmet' reinforcement at 0.00
every fourth course, well lapped with bonding 0.00
ties/dowels and etc 0.00
0.00
4.06 115mm Wide horizontal damp proof course laid in m 1.80 15 27.00
brickwall well lapped at joints and intersections 0.00
0.00
Railing 0.00
0.00
4.07 Stainless steel guard rail at the entrance m 350.00 5 1,750.00
0.00
Register counter 0.00
0.00
4.08 Stainless counter m 412.60 5 2,063.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00
0.00

TO SUMMARY SW4/AB/6 12,687.00 1,666.80

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

5 DOORS & WINDOWS

0.00 0.00
Doors

Note: i) Rate shall include set of door, complete with frame,glazing

ironmongeries, painting and the like, etc

ii) All aluminium sections for doors are to be

minimum 1.5mm thick unless otherwise specified.

iii) All aluminium door frames are to be minimum 1.0mm

thick Zincalume' metal frames unless otherwise specified

iv) All door ironmongeries are to be ''St. Guchi S.S. "or other approved
equivalent heavy duty stainless steel locksets/lock cylinders complete
with stainless steel hinges, approved door closers and accessories.

v) All timber surfaces to be painted with one coat of "ICI" aluminum

wood primer sealer and two coats of "ICI GLOSS 104 EXECUTIVE
"GREY "enamel paint unless stated otherwise.

vi) All aluminium roller shutter to be completed with painted metal

frame, motor and drum, control panel, all to manufacturer's details
0.00 0.00
5.01 1650mm x 2400mm high aluminium frame glass door with 8mm nr 1,584.00 1 1,584.00
thick glass panel with dark tinted layer (Type GH D2) 0.00
0.00
5.02 750mm x 2100mm high singe leaf metal plate door with metal frame nr 1,575.00 1 1,575.00
(Type GH D3) 0.00

5.03 2400mm x 2450mm high aluminium frame manual operated nr 2,940.00 1 2,940.00
aluminium roller shutter (Type RC D1) 0.00
0.00
Windows 0.00
0.00
Note: i) Rate shall include set of window, complete with 0.00
frame, glazing, ironmongeries and the like, etc 0.00
0.00
ii) All aluminium sections for windows are to be minimum 0.00
1.1mm thick natural anodised unless otherwise specified 0.00
0.00
iii) All aluminium installations are to be with sub-frame
system with concealed fasterners unless otherwise specified.

iv) All glass panels for toilets are to be dark tinted 0.00
frosted glass unless otherwise specified. 0.00

v) All window ironmongeries are to be provided including all necessary 0.00

glazing beads and gaskets, locks, sliding gears, recessed finger pull, 0.00 0.00
push/pull handles and accessories unless otherwise specified. 0.00 0.00
0.00 0.00
5.04 1500mm x 1550mm high aluminium frame with powder coated fixed nr 697.50 1 697.50
glass panel with 5mm thick dark tinted glass panel (Type W2) 0.00
0.00
5.05 3000mm x 1550mm high aluminium frame with powder coated fixed nr 1,395.00 1 1,395.00
glass panel with 5mm thick dark tinted glass panel (Type W4) 0.00
0.00
5.06 600mm x 600mm high aluminium composite frame with nr 108.00 1 108.00
powder coated top hung glass panel with 5mm thick 0.00
dark tinted glass panel (Type W5) 0.00 0.00
0.00
5.07 1800mm x 950mm high vent block bricks (Type RC W1) nr 200.00 3 600.00
0.00
0.00
0.00

TO SUMMARY SW4/AB/7 5,359.50 3,540.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

6 FINISHES
0.00
EXTERNAL WALL FINISHES 0.00 0.00
0.00 0.00
6.01 20mm thick cement and sand (1:6) mixed with an approved m² 26.00 41 1,066.00 42 1,092.00
plasticiser externally as described plainface to walls and columns; 0.00 0.00
complete with PVC corner bead 0.00 0.00
0.00 0.00
6.02 Prepare and apply one coat of sealer and two coats of weather m² 13.20 41 541.20 42 554.40
shield paint "ICI DULUX 12138 BANANA" 0.00 0.00
0.00
6.03 20mm thick cement and sand (1:4) screed mixed with adhesive m² 22.00 72 1,584.00
setting bed to wall to receive wall tiles 0.00
0.00
6.04 300mm x 300mm "WHITE HORSE C30108" glazed ceramic m² 70.00 72 5,040.00
wall tiles; including pointed in white cement 0.00
0.00
INTERNAL WALL FINISHES 0.00
0.00
6.05 20mm thick cement and sand (1:6) mixed with an approved m² 24.00 182 4,368.00
plasticiser internally as described plainface to walls and columns; 0.00 0.00
complete with PVC corner bead 0.00
0.00
6.06 Prepare and apply one coat of solvent base sealer 1500 and two m² 12.60 109 1,373.40
coats of gloss paint "KTH 5953 PAPRUS 2056" at 2100mm high 0.00
0.00
6.07 Prepare and apply one coat of sealer and two coats of emulsion m² 8.40 73 613.20
paint "ICI DULUX MAXILITE 12393 LINEN" 0.00
0.00 0.00
6.08 20mm thick cement and sand (1:4) screed mixed with m² 22.00 45 990.00 33 726.00
adhesive setting bed to wall to receive wall tiles 0.00 0.00
0.00 0.00
6.09 300mm x 300mm "WHITE HORSE C30032" glazed ceramic m² 70.00 45 3,150.00 33 2,310.00
wall tiles; including pointed in white cement 0.00 0.00
0.00 0.00
EXTERNAL FLOOR FINISHES 0.00 0.00
0.00
6.10 20mm thick cement and sand (1:4) rendering m² 24.00 15 360.00

6.11 20mm thick cement and sand (1:3) levelling screed m² 22.00 23 506.00
with adhesive setting bed to receive floor tiles 0.00 0.00
0.00 0.00
6.12 300mm x 300mm "GUOCERA KV908" homogeneous m² 70.00 23 1,610.00
porcelain floor tiles; including pointed in white cement 0.00 0.00
0.00 0.00
INTERNAL FLOOR FINISHES 0.00 0.00
0.00 0.00
6.13 20mm thick cement and sand (1:3) levelling screed m² 22.00 27 594.00 15 330.00
with adhesive setting bed to receive floor tiles 0.00 0.00
0.00 0.00
300mm x 300mm homogeneous porcelain floor tiles; including 0.00 0.00
pointed in white cement 0.00
0.00
6.14 "ALPHA YLH04M" m² 70.00 27 1,890.00
0.00 0.00
6.15 "GUOCERA KV953" m² 70.00 15 1,050.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00

To Collection SW4/AB/8 23,325.80 6,422.40

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

6 FINISHES (Cont'd)

EXTERNAL CEILING FINISHES 0.00 0.00

0.00
6.16 1220mm x 610mm x 12mm thick USG Boral exposed grid m² 42.20 15 633.00
moisture-resistant gypsum plasterboard suspended ceiling; complete 0.00
with hollow section support system, DX1 main tee and DX1 cross tee; 0.00
including hangers etc as specified 0.00 0.00

6.17 3mm thick skim coat "SIKA BREFILL MORTAR" to m² 8.00 23 184.00
concrete slab soffit and sides of beam 0.00
0.00
6.18 Prepare and apply one coat of sealer and two coats of weather m² 13.20 23 303.60
shield paint "ICI DULUX 12138 BANANA" 0.00 0.00
0.00 0.00
INTERNAL CEILING FINISHES 0.00 0.00
0.00 0.00
1220mm x 610mm x 12mm thick USG Boral exposed grid gypsum 0.00
plasterboard suspended ceiling; complete with hollow section 0.00
support system, DX1 main tee and DX1 cross tee; including 0.00
hangers etc as specified 0.00

6.19 Moisture-resistant "Vinyl Laminated" m² 42.20 5 211.00

0.00
6.20 Non-moisture resistant "Press Engraved" m² 35.20 22 774.40 15 528.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00
0.00
0.00
0.00

To Collection SW4/AB/9 1,473.00 1,161.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

6 FINISHES (Cont'd)

COLLECTION

SW4/AB/8 23,325.80 6,422.40

SW4/AB/9 1,473.00 1,161.00

TO SUMMARY SW4/AB/10 24,798.80 7,583.40

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT BERSERTA RUANG
PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3
TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT
213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE
SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER
ITEM DESCRIPTION UNIT RATE QTY AMOUNT QTY AMOUNT
(RM) (RM) (RM)

7 SANITARY WARES AND FITTINGS

Supply and fix the following sanitary wares and fittings 0.00
including all necessary joints and connection to supply, 0.00
waste and overflow pipes 0.00 0.00
0.00 0.00
7.01 Johnson Suisse closed coupled washdown wc with plastic cristen tank nr 936.00 1 936.00
0.00
7.02 Johnson Suisse "Trezzo 480 WBAATZ201WW" wall hung basin nr 350.00 1 350.00
0.00
7.03 DOE "DE101" manual self closing pillar tap nr 161.50 1 161.50
0.00
7.04 DOE "HB72" hose bib nr 45.00 1 45.00 1 45.00
0.00 0.00
7.05 150 x 150mm Stainless steel floor trap cover nr 28.00 2 56.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00 0.00
0.00
0.00
0.00

TO SUMMARY SW4/AB/11 1,548.50 45.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3
TINGKAT IV) 2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM
TAKUNGAN AIR VIII) LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH
KUALA LANGAT, SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO. 4 - GUARD HOUSE (TYPE C) AND REFUSE CHAMBER

GUARD HOUSE (TYPE C) REFUSE CHAMBER

ITEM DESCRIPTION AMOUNT AMOUNT
(RM) (RM)

SUMMARY

1 WORK BELOW LOWEST FLOOR FINISH SW4/AB/3 11,755.50 6,619.25

2 FRAMES SW4/AB/4 14,006.75 11,026.00

3 ROOFS SW4/AB/5 18,562.50 8,056.90

4 WALLS SW4/AB/6 12,687.00 1,666.80

5 DOORS & WINDOWS SW4/AB/7 5,359.50 3,540.00

6 FINISHES SW4/AB/10 24,798.80 7,583.40

7 SANITARY WARES AND FITTINGS SW4/AB/11 1,548.50 45.00

TOTAL CARRIED TO SUMMARY OF TENDER SW4/AB/SUM 88,718.55 38,537.35

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.5 - EXTERNAL WORKS WITHIN BOUNDARY (ALL PROVISIONAL)

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

1 WORK BELOW LOWEST FLOOR FINISH

Driveway Slab
0.00
1.01 Excavate oversite; not exceeding 0.5m deep; commencing m² 6,266 6.00 37,596.00
from formation level, part return, fill in, well ram and remove 0.00
surplus excavated material from site 0.00
0.00
1.02 0.25mm thick non-biodegradable heavy duty polythene sheet m² 6,266 3.50 21,931.00
laid under concrete slab 0.00
0.00
1.03 150mm Thick well-compacted crusher run m² 6,266 12.00 75,192.00
0.00
Reinforced concrete Grade 30 0.00
0.00
1.04 180mm thick m² 6,266 45.00 281,970.00
0.00
1.05 1200mm x 1200mm x 450mm thick drop panel nr 1,061 135.00 143,235.00
0.00
1.06 Extra over for 150mm wide x 250mm deep thickening m 239 18.50 4,421.50
0.00
1.07 Sawn formwork to edge of slab; not exceeding 0.50m high m 4,787 18.00 86,166.00
0.00
1.08 Steel bar reinforcement - 10mm Ø high tensile rod kg 16,631 3.00 49,893.00
0.00
Steel fabric reinforcement: measured nett - no allowance for laps 0.00
0.00
1.09 BRC A8; weighing not less than 3.95kg/m2 m² 2,954 14.20 41,946.80
0.00
1.10 BRC B9; weighing not less than 6.97kg/m2 m² 4,610 23.40 107,874.00
0.00
1.11 BRC DA10; weighting not less than 12.32kg/m2 m² 6,266 38.50 241,241.00
0.00
1.12 Extra over for saw cut with compression filter, silicon sealing Item 3,500.00 3,500.00
compound at 6m centres spacing or smaller panel with 5mm x 25mm 0.00
deep machine at 6m x 6m each panels as described 0.00
0.00
1.13 Extra over for expansion joint with 250mm wide waterstop, and T12 Item 2,500.00 2,500.00
and T20 deformed bars for every concrete pour to engineer's detail 0.00
0.00
1.14 Extra over for construction or contraction joint to Engineer's detail Item 2,000.00 2,000.00
0.00
1.15 Extra over for 500mm long 3T-12mm @ 50mm c/c spacing at Item 1,428.41 1,428.41
reinforced concrete column and slab area 0.00
0.00
1.16 Allow the provision for concrete slump and reinforcement test LS 500.00 500.00
0.00
1.17 Allow the provision for road marking LS 8,000.00 8,000.00
0.00

TO SUMMARY SW5/EXT/1(Add2) 1,109,394.71

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.5 - EXTERNAL WORKS WITHIN BOUNDARY (ALL PROVISIONAL)

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

2 STORMWATER DRAINAGE

"Hume" or other approved equivalent precast reinforced concrete box

culvert or u-drain, complete with precast cover lid; laid to falls in
trenches; jointing and pointing in cement mortar (1:3); 100mm Ø
weephole pipe spaced at 2000mm centres staggered; with 25mm 0.00
aggregates wrapped in filter media packed around ends of weepholes; 0.00
sitting on 50mm thick lean concrete Grade 15, 150mm thick mass 0.00
concrete base Grade 20 with 2 layer of BRC A6, including all necessary 0.00
excavation, earth backfilling and formwork, etc 0.00
0.00
2.01 750mm x 750mm deep box culvert as perimeter drain m 818 440.00 359,920.00
0.00
2.02 1000mm x 1000mm x 1000mm deep reinforced concrete sump; nr 50 1,200.00 60,000.00
constructed of 200mm thick reinforced concrete Grade 20 base and wall 0.00
with reinforcement bar T12 at 200 centres and trimmer bars T16; sitting 0.00
on 50mm thick lean concrete and 300mm thick well-compacted hardcore; 0.00
rendered on all exposed surfaces with 20mm sulphate-resisting cement 0.00
and sand (1:3) ; 250mm x 150mm cast iron steps; including excavation, 0.00
backfilling; disposal, formwork and forming outlets 0.00
0.00
2.03 600mm x 600mm galvanised iron grating; including SS304 1B nr 50 880.00 44,000.00
perforated plate with 4mm thick as top cover 0.00
0.00
2.04 160mm Ø waste, soil and vent pipes; complete with outlet m 569 132.30 75,278.70
grating to connecting manholes or water channel drains including 0.00
all necessary excavation, concrete casing around pipework 0.00
0.00
2.05 900mm long x 900mm wide x 1500mm deep shallow manhole nr 32 1,000.00 32,000.00
consisting of brickwork chamber sides and rendered internally 0.00
with 20mm thick alumina cement and sand (1:2); including light 0.00
pattern galvanised iron manhole cover; including all necessary 0.00
excavation, formwork and disposal of surplus excavated material away 0.00
0.00

TO SUMMARY SW5/EXT/2(Add2) 571,198.70

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.5 - EXTERNAL WORKS WITHIN BOUNDARY (ALL PROVISIONAL)

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

3 FENCING
0.00
Mild Steel Sliding Main Entrance Gate 0.00
0.00
3.01 12400mm long x 2100mm high mild steel sliding entrance gate; nr 1 18,500.00 18,500.00
comprising 800mm wide x 1750mm high entrance gate beside sliding gate; 0.00
including top gate of 1400mm high with 100mm x 100mm rectangular 0.00
hollow section steel frame system, 30mm x 30mm rectangular hollow 0.00
section steel vertical louver, bottom gate with 1.2mm thick metal 0.00
expanded sheet; complete with motors, cabling, gas stopper, control 0.00
panel at Guard House, heavty duty I-steel roller track, heavy duty twin 0.00
roller, mild steel tube / rod to gate with painting in approved color, and etc; 0.00
all as per drawing nr. YCSA-131/GH/TD-501 & 502 0.00
0.00
3.02 2300mm High brick gate post comprising of 1900mm high nr 2 900.00 1,800.00
brick pier to sliding entrance gate and concrete coping on top 0.00
of brick pier complete with cement plaster, painted with 0.00
approved acrylic & weather resistant paint, signage and etc 0.00
0.00
0.00
0.00
0.00
0.00

TO SUMMARY SW5/EXT/3(Add2) 20,300.00

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse

CADANGAN MEMBINA DAN MENYIAPKAN PEMBANGUNAN PERINDUSTRIAN YANG MENGANDUNGI : FASA 1 : - I) 2 UNIT KILANG 1 TINGKAT
BERSERTA RUANG PEJABAT DI ARAS MEZZANINE II) 1 UNIT GUDANG 1 TINGKAT III) 1 UNIT PEJABAT DAN PUSAT PENYELIDIKAN 3 TINGKAT IV)
2 BLOK ASRAMA PEKERJA 3 TINGKAT V) 1 UNIT STESEN SUIS UTAMA (SSU) VI) 4 UNIT PONDOK PENGAWAL VII) KOLAM TAKUNGAN AIR VIII)
LOJI RAWATAN KUMBAHAN DI ATAS LOT 213, 214, 215, 216, 217 DAN 218, PEKAN BUKIT CHANGGANG, DAERAH KUALA LANGAT,
SELANGOR DARUL EHSAN UNTUK TETUAN TOP QUALITY GLOVE SDN BHD

PARCEL 1 : PACKAGE A - FACTORY (BLOCK 1)

SW NO.5 - EXTERNAL WORKS WITHIN BOUNDARY (ALL PROVISIONAL)

ITEM DESCRIPTION UNIT QTY RATE AMOUNT

(RM) (RM)

SUMMARY

DRIVEWAY SLAB 1,109,394.71

STORMWATER DRAINAGE 571,198.70

MAIN ENTRANCE GATE 20,300.00

TOTAL CARRIED TO SUMMARY OF TENDER SW5/EXT/4(Add2) 1,700,893.41

Top Quality Glove Sdn Bhd - F42 Factory & Warehouse