‫‪THE HASHEMITE KINGDOM OF JORDAN‬‬

‫)‪ELECTRICITY DISTRIBUTION COMPANY (EDCO‬‬

‫( ‪Tender No. ) 35/2022‬‬

‫توريد وصالت ضغط متوسط‬

‫‪Tenderer:‬‬
‫ـــــ ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪ Name:‬‬
‫ـــــ ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‪ Address:‬‬
‫ـــــ ـــــــــــــــــــــــــــــــــــــــــــــــــــ‪ Telephone/ Cellular:‬‬
‫ـــــــــــــ ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪ Fax:‬‬
‫ــــ ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪ Website:‬‬
‫ــ ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪ E-Mail:‬‬
‫ـــــ ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪ Contact Person:‬‬

‫‪Director General‬‬
‫)‪Electricity Distribution Company (EDCO‬‬
‫‪P.O. BOX: 830878.‬‬
‫‪Amman – 11183 – Jordan.‬‬
‫‪The Hashemite Kingdom of Jordan.‬‬
 List of Contents
Table 1 (List of Contents)

No. Description Page

1 Cover Page 1
2 List of Contents 2
3 Invitation to Tender 3
4 General Conditions 4
5 Tendering Instructions 24
6 General Technical Conditions 22
7 Tender Agreement Summary 33
8 Form of Bid Bond 32
9 Form of Performance Bond 33
10 Form of Maintenance Bond 34
11 Technical Specifications & Schedules 33
 INVITATION TO TENDER

(35/2222)

Dear Sir,
You are kindly requested to tender for the supply of the below mentioned
materials as per the quantities and technical specifications enclosed herewith,
by filling in the schedules, signing the form of tender, and forwarding the
complete tender documents to the attention of EDCO-Director General
addressed as seen on the cover page, to be received not later than 2: 00 pm
(local time) ( 23/ 8 /2322).

All bids must be accompanied with a bid bond of a value not less than 5% of the
highest alternative tender price, otherwise your tender will not be considered.
The bid bond shall be enclosed in the same envelope of the tender and must be
delivered to the above office not later than 2:33 pm (local time) ( 23/ 8 /2322).

 The winning bidders/bidder shall bear the announcement costs in the

local newspapers, no matter how often the announcement has been
posted.
 GENERAL CONDITIONS
 The below are general conditions of contract for the supply and delivery of
plant and materials based on United Nations economic commission for
Europe publication ref.: me/ 188 Geneva. March, 1953 And/or according to
FIDIC 1999 if there is a constructions works.

1. Preamble

1.1. These General Conditions shall apply, save as varied by express

agreement accepted in writing by both parties.
1.2. Definition of Terms:

The "Purchaser" shall mean “ELECTRICITY DISTRIBUTION

COMPANY." Hereinafter called "EDCO", and shall include EDCOS legal
personal representatives and duly appointed engineers. The "Engineer"
shall mean ". ELECTRICITY DISTRIBUTION COMPANY " or persons for
the time being or from time to time duly appointed in writing by the
purchaser to act as Engineer for the purpose of the contract.
The words "approved" and "approval" where used in these conditions or
in the specification shall mean "approved by" and" approval of" the
purchaser respectively. The "Vendor" shall mean the "Contractor" who’s
tender has been accepted by the purchaser and shall include the
Vendor's. (Contractor's) legal personal representatives, successors and
permitted assigns, "F.O.B. Price" shall mean the cost of the equipment
delivered free on board the ship or truck or aircraft, all port charges and
handling charges (also heavy lift if applicable) included .
The contractor must insure the material against all risks from the time it
leaves the works until it is placed F.O.B "CFR price" shall mean F.O.B.
price plus freight including unloading at the port of destination. All
Marine Insurance will be affected by the purchaser.
NOTE:-The contractor must provide full details of the material to be
shipped in good time for EDCO to arrange for Marine Insurance before
the material is actually shipped.
2. Formation of Contract
2.1. The contract shall be deemed to have been entered into when the
purchaser has sent an acceptance in writing before the time set in the
tender for acceptance or any such later date extended by the tenderer at
the request of the purchaser.
2.2. Notwithstanding that the contract and correspondence in connection with
the contract shall be in the English language, the contract shall be and be
deemed to be a Jordan contract and shall accordingly be governed by and
construed according to the laws for the time being in force in the
Hashemite Kingdom of Jordan.
2.3. Power to Vary The Work: no alternations, amendments, omissions,
additions, suspensions, or variations of the work, (hereinafter referred to
as "variations") under the contract as shown by the contract drawings or
the specification shall be made by the contractor except as directed in
writing by the purchaser, but the purchaser shall have full power, subject
to the provision hereinafter contained, from time to time during the
execution of the contract by notice in writing to instruct the contractor to
make such variation without prejudice to the contract and the contractor
shall carry out such variations, and be bound by the same conditions, as
far as applicable, as though they said variations occurred in the
specification. If any suggested variations would, in the opinion of the
contractor, if carried out, prevent him from fulfilling any of his obligations
or guarantees under the contract, he shall notify the purchaser thereof in
writing, and the purchaser shall decide forthwith whether or not the
same shall be carried out, and if the purchaser confirms his instructions,
the contractor's obligations and guarantee shall be modified to such an
extent as may be justified. The difference in cost, if any, occasioned by any
such variations, shall be added to or deducted from the contract price as
the case may require.
The amount of such difference, if any, shall be ascertained and
determined in accordance with the rates specified in the schedule of
prices so far as the same may be applicable, and where the rates are not
contained in the said Schedule, or are not applicable they shall be settled
by the purchaser and the contractor jointly.
But the purchaser shall not become liable for the payment of any charge
in respect of any such variations, unless the instruction for the
 performance of the same shall have been given in writing by him. In the
event of the purchaser requiring any variation, such reasonable a proper
notice shall be given to the contractor as will enable him to make his
arrangements accordingly, and in cases where goods or materials are
already prepared, or any designs, drawings, or patterns made or work
done that requires to be altered a reasonable sum in respect thereof shall
be allowed by the purchaser. Provided that no such variations shall,
except with consent in writing of the contractor, be such as will involve an
increase or decrease of the total price payable under the contract by more
than 25 percent thereof. The power given to the purchaser to make any
alteration, amendment, omission, addition or variation to, from or in any
part of the works shall include power to vary from time to time the date
for the completion of the works or any part thereof, also the purchaser
shall have the absolute right to increase the quantities in such manner
that the increment does not exceed the amount of 25% of the total price
payable under the contract, however; the same prices awarded and any
other relevant conditions shall remain the same for this purpose. This
right is valid during the delivery period of the ordered material,
implementation of works, or (90) days from the date of the letter of
award, which is come later.
2.4. Precedence: In the event of any discrepancy or contradiction between
the provisions of the conditions of contract and of the specification, the
conditions of contract shall take precedence. Furthermore in case of
discrepancy between unit and total prices then unit price will be
considered.
2.5. Prices: the tender calls for firm prices, unless; otherwise mentioned in
the special requirements schedule.
3. Drawings and Descriptive Documents

3.1. The weights, dimensions, capacities, prices, performance rating and other
data included in catalogues, prospectuses, circulars, advertisement,
illustrated matter and price lists constitute an approximate guide. These
data shall not be binding save to the extent that they are by reference
expressly included in the contract.
3.2. Any drawings or technical documents intended for use in the construction
of the material or of part thereof and submitted to the purchaser prior or
 subsequent to the formation of the contract remain the exclusive property
of the Vendor. They may not, without the Vendor's consent, be utilized by
the purchaser or copied, reproduced, transmitted or communicated to a
third party. Provided, however, that the said plans and documents shall
be the property of the purchaser.
a. If it is expressly so agreed, or
b. If they are referable to a separate preliminary development contract
on which no actual construction was to be performed and in which
the property of the Vendor in the said plans and documents was not
reserved.
3.3. Any drawings or technical documents intended for use in the construction
of the material or of part thereof and submitted to the Vendor by the
Purchaser prior or subsequent to the formation of the contract remain the
exclusive property of the Purchaser. They may not, without his consent be
utilized by the Vendor or copied, reproduced, transmitted or
communicated to a third party.
3.4. The Vendor shall, if required by the purchaser, furnish free of charge to
the purchaser at the commencement of the Guarantee Period, as defined
in clause 9, information and drawings other than manufacturing drawings
of the material in sufficient detail to enable the purchaser to carry out the
erection, commissioning, operation and maintenance (including running
repairs) of all parts of the material. Such information and drawings shall
be the property of the purchaser and the restrictions on their use set out
in paragraph 2 hereof shall not apply thereto. Provided that if the Vendor
so stipulates, they shall remain confidential.
4. Packing of the materials and shipping marks
4.1. All materials, equipment and goods shall be very well packed, in
seaworthy containers and/or wooden cases, etc. These should protect the
material during shipping, handling, unloading for a reasonable period of
storage at Aqaba and latter storage at EDCO stores.
4.2. Packing for indoor materials should be done in such manner as to
adequately ensure no ingress of moisture, during the shipping and
storage periods.
4.3. Packing of fragile equipment (e.g. including instruments and porcelain)
should be done in a way which ensures a reasonable resistance to impact
 breakage during transport.
4.4. Packing shall in general be adequate and in compliance with the best
international practice.
4.5. A descriptive and fully itemized list shall be prepared for the contents of
each packing case. A copy of this list shall be placed in a waterproof
envelope under a metal or other suitable plate and securely fastened to
the outside of one end of the case. And its position adequately indicated
by stenciling on the case. Where appropriate drawing showing the
erection marking of the items concerned shall be placed inside the case.
4.6. EDCO will supply the successful tenderer with a drawing of its shipping
mark for utilization.
4.7. All packing cases, crates, barrels and drums shall remain the property of
the purchaser.

5. Inspection and Tests

All inspections and tests of the Plant and materials shall be performed to
the extent and in the manner as stipulated in the Standards specified.
Type test certificates shall be submitted for all important items supplied.
They shall contain all major technical particulars which are mentioned in
the Technical Data Sheets.
Routine test certificates showing the results of all tests performed on the
individual Plant and materials shall be furnished to the Purchaser before
dispatch of such equipment. The Purchaser reserves the right to have
certain tests performed in the presence of his representative or an
independent testing authority. A suitable program for such inspections
and tests shall be agreed upon and adequate notice (at least 21 days) shall
be given when the Plant and/or materials are ready for inspection or test
and every facility shall provide by the Contractor to enable the Purchaser
to carry out the necessary inspections and tests. The performance of any
such inspections and tests in the presence of the Purchaser and/or an
independent testing authority does not relieve the Contractor from his
Contractual obligations.
5.1 General Inspection Requirement
The whole of the material by the contract will be subject to inspection and
testing by the engineer during manufacture and on completion. The
approval of the engineer or the passing of any such inspection or test will
not, however; prejudice the right of the purchaser to reject the material if
it fails to comply with the specification when erected or to give complete
satisfaction in service. The costs of all tests and inspection shall be borne
by the contractor and shall be deemed to be included in the contract price.
Before any material is packed or dispatched from the main or sub-
contractor’s works, all tests called for are to have been successfully
carried out in presence of the engineer. Adequate notice shall be given
when the material is ready for inspection or test and every facility shall be
provided by the contractor and his inspection and his sub-contractors to
enable the Engineer to carry out the necessary inspections and tests.
Triplicate copies of all principal test records and test certificates shall be
supplied to the Engineer for all tests carried out in accordance with the
provisions of the contract.
5.1.1 If expressly agreed in the contract, the purchaser shall be entitled to
have the quality of the materials used and the parts of the instruments,
both during manufacture and when completed, inspected and checked
by his authorized representatives.
Such inspection and checking shall be carried out at the place of
manufacture during normal working hours after agreement with the
Vendor as to date and time.
5.1.2 If as a result of such inspection and checking the purchaser shall be
of the opinion that any materials or parts are defective or not in
accordance with the contract, he shall state in writing his objections
and the reasons therefore.
5.1.3 Sub-Contractors: Within two months of acceptance of the tenders
the contractor shall forward to the engineer a list of all sub-orders
placed or intended. The contractor shall submit three copies of all sub-
orders or selected by the engineer for progress or inspection. One copy
of all drawings referred to in the sub-order is to be submitted unless
otherwise agreed by the engineer. The drawings and sub-orders
submitted to the engineer will cover all major components which are
subject to electrical and mechanical pressure or stress when the
material is in operation and also auxiliaries and stores which will be
dispatched to site direct from the sub-contractor’s work. For the
purpose of this clause inter-works orders are to be treated as sub-
order. Sub-orders are to include a statement advising the sub-
contractor that the items being order will be subject to inspection and
test by the Engineer. It is important that all copies of such orders are
clearly marked with the main contractor’s name and the following
reference:
ELECTRICITY DISTRIBUTION COMPANY. CONTRACT No. ( 35 /2222)
Sub-Contractors are to comply with all the applicable requirements of
this specification. Orders issued by the sub-contractor are also to
include the main contractor’s reference on their sub–order in addition
to the above–mentioned heading.
5.2 TESTS:

All tests should meet the requirements of latest international standard

mentioned in the contract or any relevant standard
5.2.1 Acceptance tests will be carried out and, unless otherwise agreed,
will be made at the Vendor's works and during normal working
hours. If the technical requirements of the tests are not specified in
the contract, the tests will be carried out in accordance with the
general practice obtaining in the appropriate branch of the industry
in the country where the material is manufactured.
5.2.2 The Vendor shall give to the purchaser sufficient notice of the tests to
permit the purchaser's representatives to attend. If the purchaser is
not represented at the tests, the tests report shall be communicated
by the Vendor to the purchaser and shall be accepted as accurate by
the purchaser.
5.2.3 If on any test (other than a test site, where test on site are provided
for in the contract) the material shall be found to be defective or not
in accordance with the contract, the Vendor shall with all speed make
good the defect or ensure that the plant complies with the contract.
Thereafter, if the purchaser so requires, the test shall be repeated.
5.2.4 Unless otherwise agreed, the Vendor shall bear all the expenses of
tests carried out in his works.
5.2.5 If the contract provides for tests on site, the terms and conditions
governing such tests shall be such as may be specially agreed
between the parties
5.2.6 Material Tests: The contractor shall provide test prices as required
by the engineer to enable him to determine the quality of the
material supplied free of charge and any cost of the tests shall be
borne by the contractor. If any test pieces fails to comply with the
requirements of the appropriate specifications for the material in
question, the engineer may reject the whole of the material
represented by that piece, the contractor’s designers and
Metallurgists will be consulted before any material is so rejected. In
 the event of the engineer being furnished with the certified
particulars of the tests which have been carried out for the
contractor by the suppliers of the material, he may, at his own
discretion, dispense with the previously mentioned tests entirely.
5.2.7 Tests at Manufacture’s Works: Works tests shall include all routine,
electrical, mechanical and hydraulic tests in accordance with the
relevant IEC standard or other standard may be approved except
where departures there from and modifications thereto are
embodied in this specification. For material not covered by an IEC or
British standard or specifically mentioned in this specification the
tests shall be agreed with the Engineer. After satisfactory completion
of the witnessed tests at the works, the material shall be submitted
for the engineer’s approval preparatory to shipping. No item of
material is to be dispatched to site until the Engineer has given his
approval in writing.
5.2.8 Test Certificates: Triplicate sets of all principal test records test
certificates and performance curves shall be supplied for all tests
carried out in accordance with the provisions of this contract. These
test records, certificates and performance curves shall be supplied
for all tests, whether or not they have been witnessed by the
engineer. The information given in such test certificates and curves
shall be sufficient to identify the material or equipment to which the
certificates refers and should also bear the contract reference and
heading as given in clause 7.2 of this section.
5.2.9 Rejection of the materials: If Any item of material or component
which fails comply with the requirements of this specification in any
respect whatsoever at any stage of manufacture, test, erection or on
completion at site may be rejected by the engineer either in whole or
in part as he considers necessary, and after adjustment or
modification if so directed by the Engineer, the contractor shall
submit the item for the item for
the further inspection and / or test.
In the event defects of such a nature that the requirements of this
specification cannot be fulfilled by adjustment or modification shall be
replaced by the contractor, at his own expense, to the entire satisfaction of
the engineer.
 5.3 Maintenance:

The contractor is to guarantee the efficient and good working of the

material supplied under the contract for a period of 12 months
(Gregorian) from the date of delivery of the material to EDCO SORES in
accordance with the General conditions of contract.

6. Passing of Risk

Save as provided in paragraph 7.6, the time at which the risk shall pass
shall be fixed in accordance with the International Rules for the
Interpretation of Trade Terms (Incoterms) of the International Chamber
of Commerce in force at the date of the formation of the contract.
7. Delivery:

7.1. Unless otherwise agreed the delivery period shall run from the latest of
the following dates:
a. The date of the formation of the contract as defined in clause 2.

b. The date on which the Vendor receives notice of the issue of a valid
import license where such is necessary for the execution of the
contract.
c. The date of the receipt by the Vendor of such payment in advance of
manufacture as stipulated in the contract.
7.2. Should delay in delivery be caused by any of the circumstances
mentioned in clause 10 or by an act or omission of the purchaser and
whether such cause occur before or after the time or extended time for
delivery, they shall be granted subject to the provisions of paragraph
5 hereof such extension of the delivery period as is reasonable having
regard to all the circumstances of the case.

7.3. If a fixed time for delivery is provided for in the contract and the Vendor
fails to deliver within such time or any extension thereof granted under
paragraph 2 hereof, the purchaser shall be entitled, on giving to the
 Vendor within a reasonable time notice in writing, to
Claim a deduction of the price payable under the contract. Such
deduction shall be calculated at the rate of one half of one percent
(0.5%) of that part of the price payable under the contract which is
properly attributable to such portion of the plant as cannot in
consequence of the said failure be put to the use intended for each
complete week of delay commencing on the due date of delivery,
but shall not exceed a maximum percentage deduction of ten
percent. Such deduction shall be allowed when a payment becomes due
on or after delivery. Save as provided in paragraph 5 hereof, such
deduction of price shall be to the exclusion of any other remedy of the
purchaser in respect of the Vendor's failure to deliver as aforesaid.
7.4. If the time for delivery mentioned in the contract is an estimate
only, either party may after the expiration of two thirds of such
estimated time require the other party in writing to agree a fixed time.
Where no time for delivery is mentioned in the contract, this course
shall be open to either party after the expiration of six months from the
formation of the contract. If in either case the parties fail to agree, either
party may have recourse to arbitration, in accordance with the
provisions of clause 13, to determine a reasonable time for delivery and
the time so determined shall be deemed to be the fixed time for delivery
provided for in the contract and paragraph 3 hereof shall apply
accordingly.
7.5. If any portion of material in respect of which the purchaser has become
entitled to the maximum deduction provided for by paragraph 3 hereof,
or in respect of which he would have been so entitled had he given the
notice referred to therein, remains undelivered, the purchaser may by
notice in writing to the Vendor require him to deliver and by such last
mentioned notice fix a final time for delivery which shall be reasonable
taking into account such delay as has already occurred.

7.6. If for any reason whatever the Vendor fails within such time to do
everything that he must do to effect delivery, the purchaser shall be
entitled by notice in writing to the Vendor, and without requiring the
consent of any court, to terminate the contract in respect of such portion
 of the material and thereupon to recover from the Vendor any amount
not exceeding that part of the price payable under the Contract which is
properly attributable to such portion of the material as could not in
consequence of the Vendor's failure be put to the use intended.
7.7. If the purchaser fails to accept delivery on due date, he shall
nevertheless make any payment conditional on delivery as if
the paternal had been delivered. The Vendor shall arrange for the
storage of the material at the risk and cost of the purchaser. If required
by the purchaser, the Vendor shall insure the material at the cost of the
purchaser. Provided that if the delay in accepting delivery is due to one
of the circumstances mentioned in clause 10 and the Vendor is in a
position to store it in his premises without prejudice to his business, the
cost of storing the material shall not be borne by the purchaser.
7.8. Unless the failure of the purchaser is due to any of the circumstances
mentioned in clause 10, the Vendor may require the purchaser by notice
in writing to accept delivery within reasonable time. If the purchaser
fails for any reason whatever to do so within such time, the Vendor shall
be entitled by notice in writing to the purchaser, and without requiring
the consent of any court, to terminate the contract in respect of
such portion of the material as is by reason of the failure of the
purchaser aforesaid not delivered and thereupon to recover from the
purchaser any loss, suffered by reason of such failure up to an amount
not exceeding the value of the material, the delivery of which has not
been accepted.
7.9. If the winner contractor in the tender , refrained for supply the
material or execution of works which award for him or failed to
execute the contract on the limited time ,or failed to replace the rejected
material or works in another applying materials on his account, the
tenders committee which take its previous design to award the tender for
this supplier has the right to Confiscation the bid bond or the performance
bond or part of them as commensurate with the material &works value.
7.10. If refrained bidder to comply with his offer or did not complete the
necessary contract and signing of the purchase order an did
not submitted the performance bond within 15 days from the date of the
order, the tender s committee has the right to confiscated the bid bond.
Force Majeure

- Notwithstanding the provisions of clauses 7, the supplier shall not be

liable for forfeiture of its performance security, liquidated damages or
termination for default, if and to the extent that, it’s delay in
performance or other failure to perform its obligations under the
contract is the result of an event of Force Majeure.
- For purposes of this clause, "Force Majeure" means an event beyond
the control the supplier not involving the supplier's fault or negligence.
Such events may include, but are not restricted to, acts to the
purchaser either in its sovereign or contractual capacity, wars or
revolutions, fires, floods, epidemics, quarantine restrictions and fright
embargoes.
- If a Force Majeure situation arises, the supplier shall promptly notify
the purchaser in writing of such condition and the cause thereof.
Unless otherwise directed by the purchaser in writing, the supplier
shall continue to perform its obligations under the contract as far as is
reasonably practical, and shall all reasonable alternative means for
performance not prevented by the Force Majeure event.
8. Payment:

8.1. Terms of Payment:

Subject to any deduction which the purchaser may be authorized to
make under the contract or subject to any additions or deductions
provided for under clause 2-3 above, The Company (EDCO) prefers to
deal with the supplier on an open account basis, and the payment to
be made as the following:
a. (10%) of the CFR contract value (as shown by the supplier’s
invoice/contractor invoice) on receipt of the following legalized
shipping documents by EDCO:
 (Original Invoice + five copies)
 (Certificate of origin + five copies)
 (Bill of lading 3-negotiable + 5 non–negotiable)
 (Test certificate (where applicable) + 6 copies).

The original shipping documents must arrive to EDCO or
to our bank before (5) days at least prior the materials
arrival.
b. (80%) of the invoice value to be paid within 60 days of Receipt of
EDCO’s certificate of acceptance, Receipt of goods at EDCO stores.
c. (10%) of the contract value within 60 days from expiration of the
guarantee period.
If the bidder insists on L/C (letter of credit) as a method of payment,
all L/C charges will be on his own expense, in all respects all banking
charges are at vendor account, the terms will be as follows:
a. The L/C will be confirmed and irrevocable but has to be
acceptance L/C, and the supplier has to send the following
legalized shipping documents:
 (Original Invoice + five copies),
 (Certificate of origin + five copies),
 (Bill of lading 3-negotiable + 5 non–negotiable),
 (Test certificate (where applicable) + 6 copies).
 (Release of shipment (where applicable) – fax copy is accepted).

b. Payment will be released after submitting EDCO’s certificate of

acceptance to the bank within (30) days after receipt of goods at
EDCO’s stores.
 In the case of a Jordanian Supplier (materials are delivered from local
companies), payment will be made through presentation of the invoice as
following:
a. (90%) of the contract value to be paid within 30 days from date of
receipt and acceptance of the materials at our EDCO stores.
b. (10%) of the contract value within 30 days from expiration of the
guarantee period (one year from the date of receipt and acceptance
of the materials at EDCO stores)
NOTE:
- In case the supplier has better terms of payment than those mentioned
above the purchaser will discuss such terms.
- Any deviation on the payment methods mentioned above, will
negatively affect the evaluation of tenderer’s offer.
- In case the payment by acceptance L/C, The performance bond should
be valid for a period expiring at least one year after receipt of the last
consignment in EDCO stores.
- EDCO has the right to request an additional bank guarantee equal to
(5%) five percent to cover the guarantee period.
Currency of Payment: The contract price will normally be paid in the
currency or currencies in which the price has been stated. The purchaser,
however, reserves the right to make payments in the currencies of the
countries of origin of goods and services at the exchange rates applicable
at the time of payment of the contract price.
Shipping documents shall comprise the following documents: -
1) Invoices – one original, five copies.
2) Shipping specification (packing list) – six copies.
3) Certificate of origin – one original, five copies.
4) Bill of lading – 3 three negotiable, five non-negotiable.
5) Test certificates (where applicable) – six copies.
6) Release of shipment (where applicable) – fax copy is accepted.
7) EDCO’s Certificate of Acceptance - fax copy is accepted
8.2. Any advance payments made by the Purchaser are payments on account
and do not constitute a deposit, the abandonment of which would entitle
either party to terminate the Contract.
8.3. If delivery has been made before payment of the whole sum payable
under the Contract, plant delivered shall, to the extent permitted by the
law of the country where the plant is situated after delivery, remain the
property of the Vendor until such payment has been effected. If such law
does not permit the Vendor to retain the property in the plant, the Vendor
shall be entitled to the benefit of such other rights in respect thereof as
such law permits him to retain. The Purchaser shall give the Vendor every
assistance in taking any measures required to protect the Vendor’s right
of property or such other rights as aforesaid.
8.4. A payment conditional on the fulfillment of an obligation by the Vendor
shall not be due until such obligation has been fulfilled, unless the failure
of the Vendor is due to an act or omission of the Purchaser.
8.5. If the Purchaser delays in making any payment, the Vendor may postpone
the fulfillment of his own obligations until such payment is made, unless
the failure of the Purchaser is due to an act or omission of the Vendor.
8.6. If delay by the Purchaser in making any payment is due to one of the
circumstances mentioned in clause 10, the Vendor shall not be entitled to
any interest on the sum due.
8.7. Save as aforesaid, if the Purchaser delays in making any payment, the
Vendor shall on giving to the Purchaser within a reasonable time notice in
writing be entitled, and without requiring the consent of any Court, to
terminate the Contract and thereupon to recover from the Purchaser the
amount of his loss up to the value of the plant, the payment for which has
been unreasonably delayed.
9. Guarantee:

9.1. Subject as hereinafter set out; the Vendor undertakes to remedy any
defect resulting from faulty design, materials or workmanship.
9.2. This liability is limited to defects which appear during the period

(Hereinafter called the Guarantee Period) of fifteen months from date of

dispatch ex-works or twelve months from the date of accepting the
 Materials at EDCO stores whichever shall be later.
Or in case of turn key projects eighteen months from the date of setting to
work.
9.3. In fixing this period due account has been taken of the time normally
required for transport as contemplated in the contract.
9.4. In respect of such parts (whether of the Vendor's own manufacture or
not) of the material as are expressly mentioned in the contract, the
Guarantee Period shall be such other period (if any) as is specified in
respect of each of such parts.
9.5. The Guarantee period is based on the continuous use of the plant in
services for 24 hours every day.
9.6. A fresh Guarantee Period equal to that stated in paragraph 2 hereof shall
apply, under the same terms and conditions as those applicable to the
original material, to parts supplied in replacement of defective parts or to
parts renewed in pursuance of this clause. This provision shall not apply
to the remaining parts of material, the Guarantee Period of which shall be
extended only by a period equal to the period during which the material is
out of action as result of a defect covered by this clause.
9.7. In order to be able to avail himself of his rights under this clause the
purchaser shall notify the Vendor in writing without delay of any defects
that have appeared and shall give him every opportunity of inspecting
and remedying them.
9.8. On receipt of such notification the Vendor shall remedy the defect
forthwith and at his own expense. Save where the nature of the defect is
such that it is appropriate to effect repairs on site, the purchaser shall
return to the Vendor any part in which a defect covered by this clause has
appeared, for repair or replacement by the Vendor, and in such case the
delivery to the purchaser of such part properly repaired or a part in
replacement thereof shall be deemed to be a fulfillment by the Vendor of
his obligations under this paragraph in respect of such defective part.
9.9. The Vendor shall bear all the costs and risks of the transport of defective
parts or equipment’s and their replacements.
9.10. Where, in pursuance of paragraph 9 hereof, repairs are required to be
effected on site, the conditions covering the attendance of the Vendor's
 representatives on site shall be such as may be specially agreed between
the parties.
9.11. Defective parts replaced according to this clause shall be placed at the
disposal of the Vendor.
9.12. If the Vendor refuses to fulfill his obligations under this clause or fails to
proceed with due diligence after being required so to do, the purchaser
may proceed to do the necessary work at the Vendor's risk and expense,
provided that he does so in a reasonable manner.
9.13. The Vendor's liability does not apply to defects arising out of materials
provided, or out of a design stipulated, by the purchaser.
9.14. The Vendor's liability shall apply only to defect that appears under the
conditions of operation provided for by the contract and under proper
use. It does not cover defects due to causes arising after the risk in the
material has passed in accordance with clause 6. In particular it does not
cover defects arising from the purchaser's faulty maintenance or erection,
or from alterations carried out without the Vendor's consent in writing, or
from repairs carried out improperly by the purchaser, nor does it cover
normal deterioration.
9.15. Save as in this clause expresses, the Vendor shall be under no liability in
respect of defects after the risk in the material has passed in accordance
with clause 6, even if such defects are due to causes existing before the
risk so passed. It is expressly agreed that the purchaser shall have no
claim in respect of personal injury or of damage to property not the
subject matter of the contract or of loss of profit unless it is shown from
the circumstances of the case that the Vendor has been guilty of gross
misconduct.
9.16. All defective and/ or not complying materials shall be

Evacuated from
EDCO stores within a maximum of one month by the vender from the date
of notifying him. All costs and expenses of transportation shall be borne
by the vendor. Unless otherwise agreed.
Otherwise; EDCO has the right to deal with the defective materials in a
proper way.
9.17. Gross misconduct "does not comprise any and every lack of proper care
 or skill, but means an act or omission on the part of the Vendor implying
either a failure to pay due regard to serious consequences which a
conscientious contractor would normally foresee as likely to ensue, or a
deliberate disregard of any consequences of such act or omission.

10. Relief

10.1. The following shall be considered as cases of relief if they intervene after
the formation of the contract and impede its performance: industrial
disputes, and any other circumstances (e.g. fire, mobilization, requisition,
embargo, currency restrictions, insurrection, shortage of transport,
general shortage of materials and restrictions in the use of power) when
such other circumstances are beyond the control of the parties.
10.2. The party wishing to claim relief by reason of any of the said
circumstances shall notify the other party in writing without delay on the
intervention and on the cessation thereof.
10.3. The effects of the said circumstances so far as they affect the timely
performance of their obligation by the parties, are defined in clauses 7
and 8. Save as provided in paragraph 7.5, 7.7, and 8.7, if by reason of any
of the said circumstances, the performance of the contract within a
reasonable time becomes impossible, either party shall be entitled to
terminate the contract by notice in writing to the other part without
requiring the consent of any court.
10.4. If the contract is terminated in accordance with paragraph 3 hereof, the
division of the expenses incurred in respect of the contract shall be
determined by agreement between the parties.
10.5. In default of agreement it shall be determined by the arbitrator which
party has been prevented from performing his obligations and that party
shall bear the whole of the said expenses.
Where the purchaser is required to bear the whole of the expenses and
has before termination of the contract paid to the Vendor more than the
amount of the Vendor's expenses, the purchaser shall be entitled to
recover the excess. If the arbitrator determines that both parties have
been prevented from performing their obligation, he shall apportion the
said expenses between the parties in such manner as to him seems fair
 and reasonable, having regard to all the circumstances of the case.
10.6. For the purposes of this clause "expenses" means actual out of pocket
expenses reasonably incurred, after both parties shall have mitigated
their losses as far as possible. Provided that as respects material delivered
to the purchaser the Vendor's expenses shall be deemed to be that part of
the price payable under the contract which is properly attributable
thereto.

11. Limitation of Damages:

11.1. Where either party is liable in damages to the other these shall not exceed
the damage which the party in default could reasonably have foreseen at
the time of the formation of the contract.
11.2. The party who sets up a breach of the contract shall be under a duty to
take all necessary measures to mitigate the loss which has occurred
provided that he can do so without unreasonable inconvenience or cost.
Should he fail to do so, the party guilty of the breach may claim a
reduction in the damages.

12. Rights at Termination:

Termination of the contract from whatever cause arising shall be without

prejudice to the rights of the parties accrued under the contract up to the
time of termination.
Arbitration and Law Applicable:

13.1. If Any dispute, question or controversy shall arise between the purchaser
and the contractor concerning this contract the matter in dispute shall be
referred to an arbitration committee composed of three (3) arbitrators
13.2. One arbitrator shall be nominated by the purchaser and one by the
contractor, and the third arbitrator shall be appointed by both parties.
13.3. If either party fails to appoint his arbitrator within one month of the
appointment of the arbitrator by the other party, or if the two parties fail
to agree on the third arbitrator within two months of the date of the
request to refer the dispute to arbitration, such arbitrator shall be
appointed by the president of the highest court in Jordan at the request of
 either or both parties.
13.4. The decision of the arbitrators shall be final and binding on both the
purchaser and the contractor. Any such reference shall conform to the
statutory enactment or regulation governing arbitration as may be in
force in Jordan at the time. The assessment of costs incidental to the
reference and award respectively shall be at the discretion of the
arbitration committee.
 TENDERING INSTRUCTIONS
1. The Tender shall be made in one copy of the accompanying form; however,
all blanks and schedules shall be filled up in ink, and signed without
alteration to the form of tender. If any such alteration were made, or if these
Instructions were not fully complied with, the tender may be rejected. The
tenderer; however, is at liberty to add any further details that he may deem
desirable and, in the event of his so doing, shall print or type such details and
annex the added matter to the tender submitted by him. Such additional
details shall not be binding upon the purchaser unless they shall be
subsequently incorporated in the contract.
2. One copy of the tender, and its accompanying documents, filled up as
directed, together with the drawings, catalogs, and relevant documents called
for, must be enclosed in a secure envelope endorsed (Tender for Contract)
No. (33/2322).
3. All correspondences in connection with this tender and all matters
accompanying the tender that are relevant to its examination shall be in
English language and expressed in metric units.
4. The tender is to be held open for acceptance or rejection for a validity period
of (90) days from the time fixed for opening the tenders.
5. Tenders received prior to the time fixed for opening of tenders will be
securely kept, unopened. Tenders received after that time will be rejected.
The purchaser bears no responsibility for premature opening of tenders not
properly addressed or identified.
6. Tenders may be withdrawn by formal request received in writing from the
tenderer prior to the time fixed for opening. If for any reason the tender
should be withdrawn after the time fixed for opening and before expiry of the
said validity period, the purchaser has the right to retain the full value of the
tender bond.
7. The successful tenderer shall abide by the commercial and professional
regulations as required by the Ministry of Industry & Trade, Engineering
Association and other relevant Institutions in Jordan.
8. Tenderers attention is drawn to the action of customs officers in the
discharge of their duties. Whereby air parcels are frequently opened In their
own interests and in order to preserve the confidential nature of the tender
price, tenderers are urged to pay attention to the:
a. To dispatch the completed tender document and any covering letter only
by Air Mail which should be endorsed and labeled in the manner laid
down in paragraph 10 of the Instructions to Tendering.
b. Technical literature and the like may reasonably be sent by Air Parcel or
Air Freight but since this would then be separated from the actual
Tender, each parcel should contain specific evidence identifying the
Tender to which the contents refer.
c. The purchaser will not consider late or incompletely delivered tenders or
literature supporting tenders due to the action of any customs officer.
9. In the event that the intending signatory does not manufacture one or more
of the main sections of equipment and materials, then the tender submitted
should give evidence to show that all the obligations imposed by the
documents on the intending signatory have been fully understood and
accepted, where applicable, by the manufacturer(s) to whom it would be
intended to sub-contract one or more of the main sections of the equipment
and materials.
10. For overseas transport of the contractor and his Sub-contractors, suppliers
and manufactures must give priority to Jordan shipping national lines, and to
Arab shipping companies and their subsidiaries for the shipping of goods,
materials provided such companies ships call at the port of export. The
contractor shall also give priority to the Royal Jordanian Airlines for air
freight shipment and transport of personnel.
11. Tenderer must submit country of origin and name of manufacturer for the
offered goods.
12. The foreign bidders who participate in this tender must submit their bids
through a registered local agent or through their registered office in Jordan.
13. For all manufacturers from inside Jordan it is quite essential that they have
JQM for their products and the purchaser will have the right to accept or
reject their offer if they did not submitted the JQM certificate with their offer.
14. If samples were not re-claimed by the tenderer within one month from date
of order all samples shall remain the property of the purchaser.
15. The purchaser will not be responsible for, nor to pay for, any expenses or
losses which may be incurred by a tenderer in the preparation of his tender.
16. If the tenderer has any doubt about the meaning of any portion of the
General Conditions, Specifications, Drawings, he shall clarify such doubts
before submitting his tender, or in case of any further information can be
obtained by an application in writing to the director general.
17. Tenderers are particularly directed that the amount entered on the form of
tender shall be a fixed price for performing the contract strictly in
accordance with the bound document, and shall be the sum total of all the
amounts printed into and entered by the tenderer upon the schedule of
prices.
18. Tender price shall include all incidental and contingent expenses.

19. The tender shall be accompanied by a tender bond in the form of a Bank
Guarantee valid for at least 90 days from the time fixed for opening the
tenders or certified check in favor of and payable to the purchaser for a sum
of 5% Of Your Offer ‫ ـــــــــــــــــــــــــــــــــــ‬as a guarantee of good faith. This bond
is to be issued by any approved bank in Jordan. The bond will be returned to
the unsuccessful tenderer within (90) days from the time fixed for opening
the tenders or at such earlier time as a tender shall have been accepted by
the purchaser. In the case of the successful tenderer, the bond will, subject to
the conditions of contract, be returned as soon as a formal contract
agreement and a performance bond have been entered into.
20. The successful tenderer has to submit a performance bond equal to (10%)
ten percent of the total amount of the order within (15) days from date of
receipt of the order. Any delay will be subject to delay penalty.
If the successful tenderer fails for any reason to submit the required
performance bond within (15) days, the purchaser will confiscate the bid
bond and the awarding letter will be cancelled too.
21. The performance bond should be valid for a period; expiring at least one
month after receipt of the last consignment in EDCO stores.
22. The tenderer shall state in his tender the name or names of the sureties,
insurance company, or bank proposed for guaranteeing the performance of
the contract.
23. Prices are highly recommended to be on the basis of C&F EDCO STORES.
However CFR Aqaba port or Amman customs are also accepted. All prices
offered shall be exempted from custom duties, sales taxes, import license
fees and any other tariffs.
24. The tenderer may state the tender price in Jordanian Dinars. If however, a
portion of the tenderer's expenditure under the contract is expected to be
made in countries other than Jordan he may state a corresponding foreign
currency portion of the tender price in the currencies of those other
countries.
25. Stamp duty and award fees are payable on Jordanian contracts according to
Jordanian laws and, after the placing of a contract, it is the contractor's
responsibility to purchase legal stamps to the requisite amount depending
on the contract value.
26. If after receipt of tenders, the purchaser finds any difference between
prices shown on the form of tender in writing and in numerals, then the
price shown in writing shall be considered correct by the purchaser and the
tenderer. If any discrepancies are found between the total in the price
schedule and the total obtained by adding the products of each quantity and
its particular rate then, whether the price shown on the form of tender in
numerals or in writing corresponds or not, the total obtained by adding the
products of the quantities and their particular rates shall be considered by
the purchaser and the tenderer as the tender price.
27. Tender evaluation will be consistent with the terms and conditions set forth
in the tender document. In addition to the tender price adjusted to correct
arithmetical errors, other relevant factors such as the time of completion of
delivery or construction, operating costs where applicable, or the efficiency
and compatibility of the equipment, the availability of service and spare
parts, and reliability of construction methods proposed will be taken into
consideration, to the extent and in the manner specified in the tender
documents, in determining the evaluated tender most advantageous to the
purchaser. For comparison of all tenders, the currency or currencies of the
tender price for each tender will be valued in terms of Jordanian Dinars. The
 rates of exchange to be used in such valuation will be the selling rates
published by the CENTRAL BANK OF JORDAN and applicable to similar
transactions, on the day tenders are opened unless there should be a change
in the value of the currencies before the award is made. In the latter case, the
exchange rates prevailing at the time of the decision to notify the award to
the successful tenderer may be used.
28. The purchaser does not bind himself to accept the lowest offers of any
tender, nor to assign any reason for the rejection of any tender, nor to
purchase the whole of the equipment and materials specified. The purchaser
has the right to purchase part of the tender, even if it is only one item from
the schedule of rates and prices.
29. The tenderer shall submit with his tender in order of the relevant clauses, a
statement of any departures from specifications, or he can fill in the related
schedule attached herewith. Notwithstanding any description, drawings, or
literature which may be submitted, all details other than those in the
statement of departures shall be assumed to be in accordance with the
specification.
30. Although IEC standards for workmanship, equipment and materials, have
been selected in this specification as a basis of reference, standards and
specifications of other countries and recommendations of other
international standard organizations will be acceptable provided that they
are substantially equivalent to the designated standards and provided
Further that the tenderer submits for approval detailed specification which he
proposes to use.
31. References to brand names or catalog numbers, if any, in this specification
have been made only for that equipment for which it has been determined
that a degree of standardization is necessary to maintain certain essential
features. In certain instances such references have also been made for
purpose of convenience to specify the requirements. In either case offers of
alternative goods which have similar characteristics and provide
performance and quality at least equal to those specified are acceptable.
32. Where compliance with a specific standard specification is called for the
standard specification used shall be that in force at the time of tender.
33. The Tenderer should submit a type test certificate from independent testing
laboratory similar to the Tender materials as an evidence of his capability to
 manufacture such materials also to submit a reference list showing his past
supply and he should prove that he supplied similar materials to more than
one firm and operated for more than 3 years without problems otherwise his
offer will not be considered.
34. A nonrefundable fee of (33) JD will be charged for each set comprising one
copy of the Tender Documents.

TENDER AGREEMENT SUMMARY

Tender No. ( 35/2222)
Dear Sir;
1. Having examined the conditions of Contract, specification and schedule for
the above Works, the undersigned, offer to manufacture, supply, work, test,
and deliver the said works described in the specification and schedules and
in accordance with the said conditions of contract, for the sum of
‫ ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬or such other sum as may be
ascertained in accordance with the said conditions.
2. We agree that this tender shall be held open for acceptance or rejection for
the validity period of (90) days from the date fixed for opening tenders and
it shall remain binding upon us and may be accepted at any time before the
expiration of that period.
3. Unless and until a formal agreement is prepared and executed, this tender,
together with your written acceptance thereof, shall constitute a binding
contract between us.
4. If our tender is accepted, we will deliver to ELECTRICITY DISTRIBUTION
COMPANY. Within (15) days of being called upon to do so a performance
bond by bank or insurance company (to be approved in either case by the
purchaser) to be jointly and severally bound with us in a sum equal to 10%
of the value of the contract. The form of the performance bond will be as
attached hereto. We propose the following Bank or insurance company as
surety (or sureties) in this respect:-.........................................
5. We undertake if our tender is accepted and on receipt of your acceptance to
commence and manufacture, works test, and complete for delivery ex-
works the whole of the Works offered within (‫ )ـــــــــــــ‬weeks calculated from
the date of Order Letter Awarding, and to deliver on the dock at
(‫ ــــــــــــــــــــــــــــــــ‬port) - Jordan the whole of the works offered within a
further (‫ ــــــــــــــــــــــــــــــــ‬weeks, or to EDCO stores within a further
(‫ )ـــــــــــــــــ‬weeks.

6. We undertake to insure the materials against all risks from the time they
leave the works until they are placed on board ship. We understand that
marine insurance will be affected by ELECTRICITY DISTRIBUTION
COMPANY. And we will provide details of the materials to be shipped in
good time for ELECTRICITY DISTRIBUTION COMPANY to arrange for the
said marine insurance.
7. A guarantee Period will apply to each section of the works of 15 months from
the date of dispatch ex-works or 12 months from the date of setting to work
whichever shall be later.
8. We understand that you are not bound to accept the lowest or any tender
you may receive.

Dated this ‫ ــــــــــــــــــــــــــــــــ‬day of / / 2322.

Signature‫ ــــــــــــــــــــــــــــــــ‬in the capacity of ‫ـــــــــــــــــــــــــــــــــــــــــــــــــ‬

Duly authorized to sign Tender for and on behalf of ‫ــــــــــــــــــــــــــــــــ‬

ADDRESS ‫ ــــــــــــــــــــــــــــــــ‬OCCUPATION ‫ــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬

 ELECTRICITY DISTRIBUTION COMPANY.

Form of Bid Bond

Tender No. ( 35/2222)

Dear Sir,

We are pleased to inform you that we guarantee

M/S ‫ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬for the amount
of ‫ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬in order to allow them to submit an offer
for the due performance of the undertaking and obligation as specified in their
Tender for Contract No. ‫ـــــــــــــــــــــــــــــــــ‬This Guarantee shall remain valid for a
period of (90) days from the time fixed for opening the Tenders by
ELECTRICITY DISTRIBUTION COMPANY.

This Guarantee shall be free from any interest and will be extended or paid in
cash upon your first request in any or required, without the need for natural
warning or judicial proceedings and without any rights to delay, oppose, or stop
payment on our part, or on the part of the Tenderer or any of his
representatives whomever.
This Guarantee shall be deemed valid until the submittal of a duly executed
Performance Bond.

Signed ‫ ــــــــــــــــــــــــــــــــــــــــــــــــــ‬Bank (Surety)

 ELECTRICITY DISTRIBUTION COMPANY.

Form of Performance Bond

Tender No. ( 35/2222)

Dear Sirs,

At the request of ‫ ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬bank (the Foreign Bank)

and on behalf of M/S ‫ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬
(Contractor's Name and Address), we ‫ ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬Bank (the
Local Bank) issue in your favor our irrevocable and unconditional Performance
Bond No.‫ـــــــــــــــــــــــــــــــــــــــــــــ‬in the amount of.‫ـــــــــــــــــــــــــــــــــــــــــــــــ‬
‫(ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬In words), in this connection we
‫ ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬Bank (the Local Bank) hereby consider
ourselves responsible forth unconditional payment to you or to your authorized
representatives of the above sum on your first written demand in whole or in
part notwithstanding any objections on the part of the above named contractor
and without any need for natural warning or judicial proceedings.

This Bond will expire on ‫ ــــــــــــــــــــــــــــــــ‬and shall be renewed automatically for

a period of ‫ ــــــــــــــــــــ‬months and for consecutive similar periods until it is
returned by you to us.

Signed ‫ ــــــــــــــــــــــــــــــــــــــــــــــــــ‬Bank (Surety

 ‫‪ELECTRICITY DISTRIBUTION COMPANY.‬‬

‫‪Form of Maintenance Bond‬‬

‫)‪Tender No. ( 35/2222‬‬

‫)‪M/S. ELECTRICITY DISTRIBUTION CO. (EDCO‬‬

‫‪Amman – Jordan‬‬

‫‪ Bank ( the foreign bank ) and on‬ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪At the request of‬‬
‫‪ ( The‬ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪behalf of M/S :‬‬
‫‪ Bank (the‬ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪Contractor name and address ), we‬‬
‫‪local bank) issue in your favor our irrevocable and unconditional maintenance‬‬
‫‪bond‬‬ ‫) ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ(‪No.‬‬ ‫‪in‬‬ ‫‪the‬‬ ‫‪amount‬‬ ‫‪of‬‬
‫‪ covering‬ــــــــــــــــــــــــــــ ‪ (In words) valid until‬ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬
‫ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬ ‫‪PCT‬‬ ‫‪value‬‬ ‫‪of‬‬ ‫‪the‬‬
‫‪ (Contract No. Name), in this connection we the‬ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬
‫‪ Bank (local bank ), hereby consider ourselves‬ـــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ‬
‫‪responsible for the unconditional payment to you or your authorized‬‬
‫‪representatives of the above sum on your first written demand in whole or in‬‬
‫‪part not withstanding any objections on the part of the above named Contractor‬‬
‫‪and without any need for notarial warning or judicial proceedings.‬‬

‫‪and shall be renewed‬ــــــــــــــــــــــــــــــــــــــــــــــــــــــــــــ ‪This bond will expire on‬‬

‫‪) months and for consecutive‬ــــــــــــــــــــــــــــــــــــــ( ‪automatically for a period of‬‬
‫‪similar periods until it is returned by you to us.‬‬

‫)‪ Bank (Surety‬ــــــــــــــــــــــــــــــــــــــــــــــــــ ‪Signed‬‬

 Cable joint and termination accessories for power cable

1. General

XLPE cables shall be terminated and jointed with suitable terminating kits and shall be
of the blocking type designed that prevents the ingress of moisture from one cable to the
next through the through joints.

The Straight through joint kit or termination shall be complete with all accessories,
jointing material, insulating stress control and sealing material, lugs, nuts, bolts etc. as
well as an instruction booklet Explaining the method of using the kit and it shall be
complied with IEC 60502.

The straight through joints should be absolutely impervious to the entry of water. The
manufacturer shall use the proven technologies and design to ensure a construction which
will prevent entry of water or any other liquid inside the straight through joint and cable.

1.1 General requirements for straight joint and terminations

 Each kit shall be provided with all necessary insulation materials and other
accessories, cable lugs must be tinned copper suitable for connection Cu, Al, Al
Alloy, ACSR on copper terminals or aluminium terminals. Cable lugs inside covered
with contact grease for a best electrical contact, closed by protection cap. It shall be
suitable for crimping by hexagonal compression, where all accessories shall be dry
& clean.

 Red anti-tracking mastic

The Red anti-tracking mastic must be suitable for power cable heat shrink outdoor
termination and joints for 12 and 36 kV to provide insulation and sealing. The red
mastic shall not flow or exude at temperature below 85OC.

 Each kit shall be provided with all necessary insulation materials, grounding kit
and other accessories, the thickness of insulated material should comply with the min
thickness of cable’s insulation.

 Designs, drawings and details of all terminations, quantified materials to be used,

with copies of instructions shall be submitted for approval by the Engineer before the
factory orders are issued for manufacture.

 Each kit shall be provided with complete detailed installation instruction and be
clearly marked to show its application.

 Three copies of the instruction for the installation of each type of cable
termination supplied shall be submitted to the engineer

1
 1.2 Condition of operation and rating:

The cables where laid in the ground shall be rated to suit the following conditions:-

a) Depth of laying 1.0 m

O
b) Ground Temperature 40 C at 1.0 m depth
c) Soil thermal resistivity 2Cm/W
d) Spacing between circuits 0.6 m

2. Heat Shrincable Cable Joints and Termination

2.1 General

The cable jointing and terminating accessories for power cables shall be according to related
standards and comprise the standard predicts of an approved manufacturer. These having been
previously type tested according to IEC 60502-4, IEC 61442 and CENELEC HD 639.1 and
approved in service.

The required type of straight joints and terminations is heat shrinkable,where other
proposed type could be accepted .
The heat shrink tubing and moulded parts shall be flexible, flame retardant, polyolefin based
materials and shall reduce to the predetermined size and shape when heated above 120C. Where
ever required, the heat shrinkable components shall be provided with an internal coating of hot
melt adhesive/ compound which shall not flow or exude at temperature below 85C. Stress
control tubing shall be included to provide stress relief for the higher voltage cables as required.
The complete kit should also include additional components necessary for efficiently connecting
the cable screen and armour to the earth and to provide adequate protection to the joint or
termination.

The joints shall be suitable for operation when directly buried in the ground or installed in
exposed conditions as required in service. The terminations shall have adequate sealing against
ingress of moisture/water and the core insulating tubes shall be non-tracking and weather
resistant Details of design of all Joints and terminations, materials to be used, with copies of
jointing instructions shall be submitted for approval by the Engineer before the factory orders are
issued for manufacturing.

2.2 Straight Joints

a) For conductor jointing, the required number of crimping type connectors shall be supplied in
the kit. The dimensions of the connectors should conform to DIN 46267.

For the ease of installation and to eliminate problems arising out of improper crimping or
use of improper crimping connectors or tools, joints with sheer bolt bimetallic mechanical
connectors will be preferred. However the connector design should have been tested in
accordance with IEC-61238 Class A.

b) High permittivity void filler mastic shall be used over the screen end to fill the voids that
may exist below the stress control tubing.

The stress control function over the connectors and at the screen cut back shall be achieved
by a combination of stress grading filler and thermally stable heat shrinkable stress control
tubing.

2
 The impedance of the stress control tubing shall not change over a range of temperature from
0 Deg. C to 125 Deg. C. The impedance shall also remain constant irrespective of the
differences in stress which will exist within the tubing due to the heating effect within the
conductor and the ambient temperature.

c) Insulation tube layer over the stress control tube and outer tube layer over armour should
have a high recovery force to achieve tight electrical interfaces and perfect sealing ability.

A Joint design with mechanical sheer bolt connectors and insulation tubing, duly tested as a
complete system, in accordance with IEC-60502-4 and CENELEC HD 629.1 S2 standard,
will be given preference to joints with multi-layer tubings.

d) Electrical continuity of the copper tape screen across the joint shall be provided by means of
tinned copper mesh of adequate cross section and constant force stainless steel roll springs.

In case of cables with wire shield, the required connectors should be included in the kit for
connection of the shield wires across the joint.

e) In 3 core cables, the electrical continuity of the armour shall be reinstated by use of a steel
armour case with adequate short circuit withstand capability. The steel armour case shall
also withstand the external mechanical forces that may otherwise damage the cable
components.

On all armoured cable, armouring wires or tapes shall be bonded across each straight joint in
an approved manner by means of a copper bond with a sectional area of at least 95 mm2. The
resistance of all copper bonds shall not be higher than that of an equal length of the
armouring and the metallic screen.

The design of the steel armour case shall ensure reduced overall diameter and minimum air
entrapment in the joint to improve heat dissipation and increased rating factor of the cable.
The armour case shall be secured over the armour with 2 no of stainless steel worm drive
clamps on either side. An adjustable stainless steel support ring shall be placed under the
armour to enable adequate electrical contact and to avoid the penetration of wire armour into
the cable bedding.

To ensure a reliable connection of the cable armour in single core cables, the aluminum
wires must be joined across the joint with sheer bolt mechanical or compression connectors.

f) To prevent the joint and cable components from external environment and water ingress, the
encapsulation of the joint shall be achieved by thick wall adhesive lined sealing sleeves.

Each kit shall be provided with complete detailed installation instruction and be clearly marked
to show its application.

Three copies of the instruction for the installation of each type of cable joint supplied, shall be
submitted to the engineer.

3
2.3 Repair Joints

Repairing joints will be used to repair the damaged cables without adding additional cable length.
Each Repairing joint shall be provided with all necessary insulation materials and other
accessories; the mechanical connector shall be bolted type with more than 400mm length, to join
the cable conductor and must be for connection Cu, Al.
Thickness of insulated material should comply with the min thickness of cable’s insulation.

They shall utilize the heat shrinkable system with mechanical connecter according to IEC 61238-
1 Class A.

Each Repairing joint shall be provided with all necessary insulation materials and other
accessories. And shall be provided with complete detailed installation instruction and be clearly
marked to show its application.

2.4 General requirements for heat shrinkable terminations

a) The stress control function at the screen cut back shall be provided by thermally stable heat
shrinkable stress control tubing in combination with high permittivity void filler mastic over
the screen end. The impedance of the stress control tubing shall not change over a range of
temperature from 0 Deg. C to 125 Deg. C. The impedance shall also remain constant
irrespective of the differences in stress which will exist within the tubing due to the heating
effect within the conductor and the temperature of environment.

b) The kits offered shall provide for total environmental sealing of the cable crotch. A cable
breakout with sealant coating should be provided for 3 core cable terminations.

c) Adequate quantity of sealant strips for application over the lug barrel and exposed strands
between the lug and cable insulation shall be provided in the kit.

d) Anti-tracking breakout Insulation Tubing shall be supplied to provide complete leakage

insulation between the lugs and the cable breakout to prevent the cable insulation from the
effects of weathering and electrical tracking caused by the leakage current flowing over the
insulation surface. The tubing shall be coated with non tracking flexible sealant at one end.
Single piece, heat shrinkable weather sheds having non tracking, weather resistant properties
shall be supplied with the kits for application over non tracking tubing. The quantity of sheds
to be supplied shall depend upon voltage grade and Indoor / Outdoor application and shall be
indicated in the kit content list.

e) Connection of the copper tape screen to ground shall be achieved by tinned copper braids of
adequate cross section secured in place with constant force stainless steel roll springs.

Each kit shall be provided with complete detailed installation instruction and be clearly marked
to show its application.

Three copies of the instruction for the installation of each type of cable termination supplied,
shall be submitted to the engineer.

4
2.4.1 Indoor Terminations

Indoor termination kits shall be suitable for terminating the cables in air, transformer/switchgear
cable boxes. Each termination kit shall be complete in all respects including crimping type lugs
the Lugs dimensions should be according to DIN 46235.
Aluminum cable lugs shall have corrosion inhibiting compound filled inside and ends closed with
protection caps. Sheer bolt mechanical lugs suitable for both copper and aluminum conductors,
shall also be considered. All required materials for cable preparation shall be supplied with the
kit.

For 3 Core cables Indoor terminations, the tail length shall not be less than 600 mm and 850mm
for 12 kV and 36 kV respectively & (1) shed per phase for 36kv indoor terminations.

2.4.2 Outdoor Terminations

Terminating kits shall be suitable for outdoor use for terminating cables .The termination kit shall
be complete in all respects including crimping type cable lugs. Aluminum cable lugs shall have
corrosion inhibiting compound filled inside and ends closed with protection caps. Sheer bolt
mechanical lugs suitable for both copper and aluminum conductors, shall also be considered. All
required materials for cable preparation shall be supplied with the kit.
For 3 Core Outdoor terminations, the tail length shall not be less than 800mm and 1200mm for
12 kV and 36 kV respectively.

The recovered thickness of insulation tubing over the connector shall be uniform and equal to
insulation thickness as in IEC 60502-2. The insulation tubing shall be generally suitable for
outdoor installation, ultra-violet and chemical resistant, with creepage distance not less than
44mm/kV.

3. Cold Cable Terminations

The cable jointing and terminating accessories for power cables shall be according to IEC 60502-
4 and comprise the standard predicts of an approved manufacturer. These having been previously
tested and approved in service.

They shall be cold silicon rubber terminations, and shall meet or exceed the specifications of
cables mentioned.

Terminations shall provide water proofing, mechanical and electrical protection, moister sealed,
including the crotched area of multi core cables and complete re-jacketing of individual cores(
including 3 core anti tracking breakout) , to be suitable for operation in the ground or installed
in exposed position or in condition of high humidity, as required in service.

The recovered thickness of insulation tubing over the connector shall be uniform and equal to
insulation thickness as in IEC 60502-2. The insulation tubing shall be generally suitable for
indoor / outdoor installation, ultra-violet and chemical resistant, with creepage distance of
44mm/kV.

5
The kit shall include all arrangements to terminate cable screening, armouring and sheathing in
such a way as to provide earth continuity and adequate protection as required at all joints and
terminations.

4. Packing & Identification

All components shall be supplied in a single package as a complete kit.

The kit label shall indicate the complete details of the kit such as voltage grade, type of kit, i.e.
indoor/ outdoor termination or joint along with number of cores and conductor size. Each kit
shall have a batch no printed on the label.

5. Traceability

For traceability purpose, each component of termination& straight joint shall be made up into kits
in which each part shall be correctly identify the manufacturer's name, part number,
manufacturing date, minimum & maximum cable cross-sections, minimum & maximum
insulation diameters, rated voltage and any other necessary marking.

6. Samples

The Contractor may be required to submit a sample for offered terminations and joints for
evaluation purposes. EDCO has the right to reject the offer if the samples are not submitted
or do not meet the specification requirement.

7. Inspection and Testing

All cables joints and terminations shall be subjected to inspection and testing in accordance with
IEC 60502-4 or IEEE 404. The purchaser shall attend these tests.

Adequate notice shall be given when the cables joints and terminations are ready for inspection
and tests, every facility shall be provided by the supplier to enable the purchaser to carry out the
necessary inspections and tests.

Before the Joints and terminations are packed or dispatched, all tests including the electrical test
shall have been carried out successfully.

No passing of plant or materials by the purchaser shall relieve the Contractor from this
responsibility. The Contractor shall also be responsible for proper carrying out of all tests of plant
or materials carried out or supplied by a sub-contractor to the same extent as if the work were
carried out or supplied by the Contractor himself.

If, due to the Contract work and/or component materials not complying with this specification,
further tests are necessary, the Contractor shall pay all additional costs, which may be incurred in
re-testing.

The following tests shall be carried out in accordance with IEC 60502 and its amendments: -

a) Routine Tests.
b) Type Tests, Electrical
c) Type Tests, non-electrical.
6
d) Special Tests

8. Document to be Supplied in the Offer

The following items must be attached and submitted with the offer:
- Instructions for installation for each type of offered accessories.
- Catalogues, technical leaflets, drawings...etc.
- Test certificates.
- Reference lists for similar products.

9. XLPE Cable (NOT REQUIRED)

All XLPE cables shall comply with the current editions of IEC 60502-2, or other equivalent and
related National Standards, subject to the variations and additions stated herein.

All cables shall be suitable for operation under the respective loads and such sudden
variations of load and voltage as may be met with under working conditions on the system,
and in the climatic conditions prevailing on site.

Rated Voltage
The rated voltages of cables in this tender are Uo/U(Um)= 19/33(36) KV and 6.35/11(12) kV
according to BS 6622, where Uo, U and Um as defined in IEC 60502-2 or other approved
Standards. Conductors shall be circular stranded and compacted copper or aluminium with cross
sections, as mentioned in SCOPE OF WORK above.

Highest Rated Temperature

XLPE insulated cables shall be designed for a maximum continuous conductor temperature of
90oC, and a maximum short-circuit temperature of 250oC.

Conductor Screening
Conductor screening shall consist of a layer of thermosetting extruded semi-conducting
compound of adequate thickness having a smooth even surface in intimate contact with the cable
insulation and the conductor, but firmly bonded to the insulation layer. The nominal thickness of
this layer shall be 0.5mm.

Insulation and Insulation Screening

Insulation material and thickness shall meet all the relevant requirements of IEC 60502 or other
approved standards. The insulation shall be dry-cured cross-linked polyethylene (XLPE) with a
nominal thickness of 8.0mm and 3.4mm (minimum average) for 19/33(36) kV and 6.35/11(12)
kV respectively. The minimum thickness at any point shall not fall below 7.10mm and 2.96mm
for 19/33(36) kV and 6.35/11(12) kV respectively.

Insulation screening shall consist of a layer of thermosetting extruded semi-conducting

compound (easy strippable), having an intimate contact with the cable insulation and the semi
conductive swellable tape. The nominal thickness of this layer is 0.7 mm.

Metallic Layer
The metallic layer shall be constructed of annealed high-conductivity copper wires and tape in
accordance with IEC 60228 and other related standard.

7
semi-conducting insulation screening shall have a supplementary copper wire screen helically
applied in intimate contact with the non-metallic semi-conducting screening.

A copper tape counter-helix shall be applied over the copper wires.

The nominal cross section of the metallic screen for each cable shall not be less than 50mm 2
excluding copper tape. The metallic layer should have an earth fault current carrying capacity of
7 KA for one second.

The minimum size of copper tape binder shall be 0.1 x 15 mm2.

Water Swelling Tape

The screen area shall be watertight in the longitudinal direction by means of two layers of semi
conductive swellable tapes with one layer under and the second layer over the metallic screen.

Identification of Cores
The cores of all three core power cables shall be identified by colors as follows:-

COLOR
RED
YELLOW
BLUE
While black coloured for single core cables

Separation Sheath (Bedding)

The inner covering (Separation sheath) material shall be PVC compound for Al cables and single
phase Cu cables, while it should be PE for three phase Cu cables (PVC to be replaced by PE
compound is acceptable), and should be applied under the armour. The nominal thickness of this
sheath shall conform to IEC 60502/ other approved standards, while the minimum accepted value
shall be 2mm for nonarmoured cables.
Fillers Requirements
Fillers shall be of materials suitable for the operating temperature of the cable and compatible
with the insulation. The fillers shall be non-hygroscopic.

Armour
Armour for multicore cables shall consist of a layer of round or flat galvanized steel wires
applied over an approved bedding. While for single core cables it should be of hard drawn
aluminum wires.

The dimensions of the armour wires, shall conform to IEC 60502/other approved Standards.

OverSheath
The outer sheath shall consist of :

 extruded continuous black PVC type ST2 for armoured, Cu, three phase cables.

 for armoured, Cu, single phase cables, and Al single and three phase cables :

 The outer sheath to be PE if the inner sheath is PVC or the outer sheath PVC ST2 if the
inner sheath is PE

8
  HDPE ST7 for nonarmoured.

according to IEC 60502 or equivalent standard. As a protection against termite attack, the outer
covering shall contain an evenly dispersed mixture of an approved antitermite deterrent. The
Tenderer shall state in this offer the types and amounts of chemicals he intends to add. The
Contractor shall state on the cable test certificate the amounts of insecticides added. The Engineer
reserves the right to select samples of such outer covering for analysis to check the quantities
added.

The nominal thickness of the sheath shall be in accordance with IEC 60502 or other approved
Standards, while the min nominal value for nonarmoured cables should not be less than 2.5 mm.

The extruded over sheaths of cables shall be embossed with the following:-

cable voltage designation, the conductor size, and the words "ELECTRIC CABLE” in English,
the number of tender, the manufacturer name, year of manufacture and EDCO name. The length
in meters shall be also embossed on the outer sheath all along each cable length at each three
meter. The letters and figures shall consist of upright block characters arranged along two or
more lines approximately equally spaced around the circumference of the cable. The maximum
height of the characters shall be 13 mm and the minimum size 15 per cent of the approximate
overall diameter of the cable or 3 mm whichever is the greater. The space between the end of one
set of engraved characters and the beginning of the next shall not be greater than 150 mm

Current Carrying Capacity and Design Parameters

The maximum continuous current carrying capacity, the maximum permissible continuous
conductor temperature, and the factors for determining such rating and temperature shall be
based on IEC 60287 and subsequent amendments/ other approved Standards.

- A sample of each type should be submitted with the offer and any offer
received without drawings and samples will be rejected during evaluation
without any prior notice.
- The Tendrer shall be provide a list of the component for the offered Joints

9
SCHEDULE NO. DESCRIPTION

A Schedule of Requirements

B Price Schedule

C Guaranteed Delivery Periods and manufacturer

Schedule

D Deviations From Specification

E List Of Type Test Certificates

F Service Experience

14
 SCHEDULE (A)
SCHEDULE OF REQUIREMENTS
Item Description Quantity
No. Unit
1 Straight joint heat shrinkable For 6/10 (12) kV, 150 mm2 Cu., 150 KIT*
3-Core, copper wire and tape screened, XLPE cable.
Armoured(galvanized SWA)
2 Straight joint heat shrinkable For 19/33 (36) kV, 150 mm2 150 KIT*
Cu., 3-Core, copper wire and tape screened, XLPE cable.
Armoured(galvanized (SWA)
3 Indoor type termination For 6/10 (12) kV, 150 mm2 Cu., 3- 50 KIT*
Cores, copper wire and tape screened, XLPE cable. Armoured
(galvanized SWA)
4 Indoor type termination For 19/33 (36) kV, 150 mm2 Cu., 3- 70 KIT*
Cores, copper wire and tape screened, XLPE cable. Armoured
(galvanized SWA)
5 Outdoor type termination For 6/10 (12) kV, 150 mm2 Cu., 3- 50 KIT*
Core, copper wire and tape screened, XLPE cable. Armoured
(galvanized SWA)
6 Outdoor type termination For 19/33 (36) kV, 150 mm2 Cu., 54 KIT*
3-Core, copper wire and tape screened, XLPE cable.
Armoured (galvanized SWA)
7 Outdoor type termination For 19/33 (36) kV, 120 mm2 Cu., 20 KIT
1-Core, copper wire and tape screened, XLPE cable.
Armoured (galvanized AWA)
8 Comprehensive training for termination right erecting.

* Each KIT shall be suitable for 3 core cables

(**):
 All required training materials are supplier responsibility.
 Training shall be onsite(s) Aqaba, Maan, Al-Karak and Al-Tafilah ( upon EDCO needs)
 Training Duration : Minimum three working days.
 Instructor CV and Training schedule shall be submitted for EDCO approval.
 Trainees are EDCO staff (Engineers and Technicians)
 Training certificate is required.

11
 SHEDULE (B)
PRICE SCHEDULE
Description Quantity UNIT PRICE & TOTAL
CURRENCY PRICE
Item FOB C&F C&F
No. AQABA AQABA-
JORDAN
1 Straight joint heat shrinkable For 6/10 150 KIT*
(12) kV, 150 mm2 Cu., 3-Core, copper
wire and tape screened, XLPE cable.
Armoured(galvanized SWA)
2 Straight joint heat shrinkable For 19/33 150 KIT*
(36) kV, 150 mm2 Cu., 3-Core, copper
wire and tape screened, XLPE cable.
Armoured(galvanized (SWA)
3 Indoor type termination For 6/10 (12) kV, 50 KIT*
150 mm2 Cu., 3-Cores, copper wire and
tape screened, XLPE cable. Armoured
(galvanized SWA)

4 Indoor type termination For 19/33 (36) 70 KIT*

kV, 150 mm2 Cu., 3-Cores, copper wire
and tape screened, XLPE cable.
Armoured (galvanized SWA)

5 Outdoor type termination For 6/10 (12) 50 KIT*

kV, 150 mm2 Cu., 3-Core, copper wire
and tape screened, XLPE cable.
Armoured (galvanized SWA)
6 Outdoor type termination For 19/33 (36) 54 KIT*
kV, 150 mm2 Cu., 3-Core, copper wire
and tape screened, XLPE cable.
Armoured (galvanized SWA)
7 Outdoor type termination For 19/33 (36) 20 KIT
kV, 120 mm2 Cu., 1-Core, copper wire
and tape screened, XLPE cable.
Armoured (galvanized AWA)
8 Comprehensive training for termination
right erecting.

IMPORTANT NOTES:

1. THE REQUIRED TYPE OF STRAIGHT JOINTS AND TERMINATIONS ARE HEAT

SHRINKABLE, WHERE OTHER PROPOSED TYPE COULD BE ACCEPTED.

2. EDCO HAS THE RIGHT TO ACCEPT PARTIAL OFFERS AND TO AWARD PART
OF THE ITEMS QUANTITIES WITHOUT ANY LIMIT OR NOTICE.

3. FAILURE TO SUBMIT SUCH SAMPLE, EDCO HAS THE RIGHT TO REJECT THE
OFFER.
12
 4. EDCO HAS THE RIGHT TO REJECT ANY OFFER BASED ON EVALUATION THE
SUBMITTED SAMPLE IN TERMS OF THE QUALITY, LIABILITY AND WELL-
KNOWN AND REPUTABLE MANUFACTURERS.

SCHEDULE (C)
MANUFACTURERS & GUARANTEED DELIVERY PERIODS
The Tenderer shall state the country where manufacture and the delivery periods entered shall be
binding on the Contractor.
Item Description MANUFACTURER DELIVERY
No. Unit PERIOD C & F
AQABA PORT-
JORDAN
1 Straight joint heat shrinkable For
6/10 (12) kV, 150 mm2 Cu., 3-
Core, copper wire and tape
screened, XLPE cable.
Armoured(galvanized SWA)

2 Straight joint heat shrinkable For

19/33 (36) kV, 150 mm2 Cu., 3-
Core, copper wire and tape
screened, XLPE cable.
Armoured(galvanized (SWA)

3 Indoor type termination For 6/10

(12) kV, 150 mm2 Cu., 3-Cores,
copper wire and tape screened,
XLPE cable. Armoured
(galvanized SWA)

4 Indoor type termination For 19/33

(36) kV, 150 mm2 Cu., 3-Cores,
copper wire and tape screened,
XLPE cable. Armoured
(galvanized SWA)

5 Outdoor type termination For 6/10

(12) kV, 150 mm2 Cu., 3-Core,
copper wire and tape screened,
XLPE cable. Armoured
(galvanized SWA)

Outdoor type termination For

6 19/33 (36) kV, 150 mm2 Cu., 3-
Core, copper wire and tape
screened, XLPE cable. Armoured
(galvanized SWA)

Outdoor type termination For

7 19/33 (36) kV, 120 mm2 Cu., 1-
Core, copper wire and tape
screened, XLPE cable. Armoured
(galvanized AWA)
13
 SCHEDULE (D)

DEVIATIONS FROM SPECIFICATION IF ANY

TO BE COMPLETED BY THE TENDERER

TEM
NO. BREIF DESCRIPTION DEVIATIONS

14
 SCHEDULE (E)

TYPE TEST CERTIFICATE

TO BE COMPLETED BY THE TENDERER

TEM
NO. BREIF DESCRIPTION CERTIFICATE

15
 SCHEDULE (F)

SERVICE EXPERIENCE OF termination and joints

Tenderers shall provide the information required below for the past five years for
the same materials in the Middle East Area, End user certificate shall be submitted
with the tender.

Customer No. of units Rated No. of years in

supply voltage service

16