Engineering Procurement and Construction (EPC)

Agreement

For

Reconstruction/Widening work from KM 49.00 to Km

52.80 of NH-220 in the State of Jharkhand on EPC
mode.(Job No. – NH-220(AP)2023-24/346)

Ministry of Road Transport & Highways

(MoRT&H)

1
 Table of Contents
Part I 1

Preliminary 1

1 Definitions and Interpretations 4

1.1 Definitions 4
1.2 Interpretation 12
1.3 Measurements and arithmetic conventions 14
1.4 Priority of agreements and errors/discrepancies 14
1.5 Joint and several liability 15
Part II 16

Scope of Project 17

2 Scope of the Project 17

2.1 Scope of the Project 17

3 Obligations of the Authority 18

3.1 Obligations of the Authority 18

3.2 Maintenance obligations prior to the Appointed Date 20
3.3 Environmental Clearances 20
3.4 Deemed Termination upon delay 20
4 Obligations of the Contractor 21

4.1 Obligations of the Contractor 21

4.2 Obligations relating to sub-contracts and any other agreements 23
4.3 Employment of foreign nationals 24
4.4 Contractor’s personnel 24
4.5 Advertisement on Project Highway 25
4.6 Contractor's care of the Works 25
4.7 Electricity, water and other services 25
4.8 Unforeseeable difficulties 25
4.9 Co-ordination of the Works 25
4.10 Environmental Measures 26
4.11 Site Data 26
4.12 Sufficiency of Contract Price 27
I

1
 4.13 Clearance of the Site 27
5 Representations and Warranties 28

5.1 Representations and warranties of the Contractor 28

5.2 Representations and warranties of the Authority 31
5.3 Disclosure 32
6 Disclaimer 33

6.1 Disclaimer 33
Part III 34

Construction and Maintenance 34

7 Performance Security 35

7.1 Performance Security 35

7.2 Extension of Performance Security and Additional Performance Security 36
7.3 Appropriation of Performance Security 36
7.4 Release of Performance Security 36
7.5 Retention Money 37
8 Right of Way 38

8.1 The Site 38

8.2 Procurement of the Site 38
8.3 Damages for delay in handing over the Site 39
8.4 Site to be free from Encumbrances 40
8.5 Protection of Site from encroachments 41
8.6 Special/ temporary Right of Way 42
8.7 Access to the Authority and the Authority’s Engineer 42
8.8 Geological and archaeological finds 42
9 Utilities and Trees 43

9.1 Existing utilities and roads 43

9.2 Shifting of obstructing utilities 43
9.3 New utilities 43
9.4 Felling of trees 44
9.5 Dismantling of structures 44
9.6 Development Period 45

ii

2
10 Design and Construction of the Project Highway 46
10.1 Obligations prior to commencement of Works 46
10.2 Design and Drawings 48
10.3 Construction of the Project Highway 50
10.4 Maintenance during Construction Period 51
10.5 Extension of time for completion 52
10.6 Incomplete Works 53
10.7 Maintenance Manual 54
10.8 As-Built Records 54
10.9 Contractor's Use of Authority’s Documents 54
11 Quality Assurance, Monitoring and Supervision 55

11.1 Quality of Materials and workmanship 55

11.2 Quality control system 55
11.3 Methodology 55
11.4 Inspection and technical audit by the Authority 56
11.5 External technical audit 56
11.6 Inspection of construction records 56
11.7 Monthly progress reports 56
11.8 Inspection 57
11.9 Samples 58
11.10 Tests 58
11.11 Examination of work before covering up 58
11.12 Rejection 59
11.13 Remedial work 59
11.14 Delays during construction 60
11.15 Quality control records and Documents 60
11.16 Video recording 60
11.17 Suspension of unsafe Construction Works 60
11.18 Staff and Labour 61
12 Completion Certificate 64

12.1 Tests on Completion 64

12.2 Completion Certificate 64
12.3 Rescheduling of Tests 65
Iii

3
13 Change of Scope 66
13.1 Change of Scope 66
13.2 Procedure for Change of Scope 66
13.3 Payment for Change of Scope 68
13.4 Restrictions on Change of Scope 68
13.5 Power of the Authority to undertake Works 69
14 Maintenance 70

14.1 Maintenance obligations of the Contractor 70

14.2 Maintenance Requirements 71
14.3 Maintenance Programme 71
14.4 Safety, vehicle breakdowns and accidents 72
14.5 Lane closure 72
14.6 Reduction of payment for non-performance of Maintenance obligations 72
14.7 Authority’s right to take remedial measures 73
14.8 Restoration of loss or damage to Project Highway 73
14.9 Overriding powers of the Authority 73
14.10 Taking over Certificate 74
15 Supervision and Monitoring during Maintenance 75

15.1 Inspection by the Contractor 75

15.2 Inspection and payments 75
15.3 Tests 76
15.4 Reports of unusual occurrence 76
16 Traffic Regulation 77

16.1 Traffic regulation by the Contractor 77

17 Defects Liability 78

17.1 Defects Liability Period 78

17.2 Remedying Defects 78
17.3 Cost of remedying Defects 79
17.4 Contractor’s failure to rectify Defects 79
17.5 Extension of Defects Liability Period 79

iv

4
18 Authority’s Engineer 80
18.1 Appointment of the Authority’s Engineer 80
18.2 Duties and authority of the Authority’s Engineer 80
18.3 Delegation by the Authority’s Engineer 81
18.4 Instructions of the Authority’s Engineer 81
18.5 Determination by the Authority’s Engineer 82
18.6 Remuneration of the Authority’s Engineer 82
18.7 Termination of the Authority’s Engineer 82
Part IV 83

Financial Covenants 83

19 Payments 84

19.1 Contract Price 84

19.2 Advance Payment 84
19.3 Procedure for estimating the payment for the Works 86
19.4 Stage Payment Statement for Works 87
19.5 Stage Payment for Works 87
19.6 Monthly Maintenance Statement of the Project Highway 87
19.7 Payment for Maintenance of the Project Highway 88
19.8 Payment of Damages 88
19.9 Time of payment and interest 89
19.10 Price adjustment for the Works 89
19.11 Restrictions on price adjustment 92
19.12 Price adjustment for Maintenance of Project Highway 92
19.13 Final Payment Statement 93
19.14 Discharge 93
19.15 Final Payment Certificate 93
19.16 Final payment statement for Maintenance 94
19.17 Change in law 94
19.18 Correction of Interim Payment Certificates 95
19.19 Authority’s claims 95
19.20 Bonus for early completion 95

5
20 Insurance 96
20.1 Insurance for Works and Maintenance 96
20.2 Notice to the Authority 97
20.3 Evidence of Insurance Cover 97
20.4 Remedy for failure to insure 97
20.5 Waiver of subrogation 98
20.6 Contractor’s waiver 98
20.7 Cross liabilities 98
20.8 Accident or injury to workmen 98
20.9 Insurance against accident to workmen 98
20.10 Application of insurance proceeds 99
20.11 Compliance with policy conditions 99
20.12 General Requirements of Insurance Policies 99
Part V 101

Force Majeure and Termination 102

21 Force Majeure 102

21.1 Force Majeure 102

21.2 Non-Political Event 102
21.3 Indirect Political Event 102
21.4 Political Event 103
21.5 Duty to report Force Majeure Event 103
21.6 Effect of Force Majeure Event on the Agreement 104
21.7 Termination Notice for Force Majeure Event 105
21.8 Termination Payment for Force Majeure Event 105
21.9 Dispute resolution 106
21.10 Excuse from performance of obligations 106
22 Suspension of Contractor’s Rights 107

22.1 Suspension upon Contractor Default 107

22.2 Authority to act on behalf of Contractor 107
22.3 Revocation of Suspension 107
22.4 Termination 107

vi

6
23 Termination 109
23.1 Termination for Contractor Default 109
23.2 Termination for Authority Default 111
23.3 Termination for Authority’s convenience 112
23.4 Requirements after Termination 112
23.5 Valuation of Unpaid Works 113
23.6 Termination Payment 113
23.7 Other rights and obligations of the Parties 114
23.8 Survival of rights 115
23.9 Foreclosure with mutual consent 115
Part VI 117

Other Provisions 117

24 Assignment and Charges 117

24.1 Restrictions on assignment and charges 117

24.2 Hypothecation of Materials or Plant 117
25 Liability and Indemnity 118

25.1 General indemnity 118

25.2 Indemnity by the Contractor 118
25.3 Notice and contest of claims 119
25.4 Defence of claims 119
25.5 Survival on Termination 120
26 Dispute Resolution 121

26.1 Dispute Resolution 121

26.2 Conciliation 121
26.3 Arbitration 121
26.4 Adjudication by Regulatory Authority, Tribunal or Commission 122
27 Miscellaneous 123

27.1 Governing law and jurisdiction 123

27.2 Waiver of immunity 123
27.3 Delayed payments 123
27.4 Waiver 123

vii

7
 27.5 Liability for review of Documents and Drawings 124
27.6 Exclusion of implied warranties etc. 124
27.7 Survival 124
27.8 Entire Agreement 125
27.9 Severability 125
27.10 No partnership 125
27.11 Third parties 125
27.12 Successors and assigns 125
27.13 Notices 126
27.14 Language 126
27.15 Counterparts 126
27.16 Confidentiality 126
27.17 Copyright and Intellectual Property rights 127
27.18 Limitation of Liability 127
27.19 Care and Supply of Documents 128
27.20 Authority’s Use of Contractor’s Documents. 128
27.21 Contractor’s Use of Authority’s Documents 128
27.22 Access to the Site by Others 129
27.23 Term 129
27.24 Amendments 129
27.25 Representation and Bribes 129
27.26 No Agency 129
Schedules

Schedule-A

Site of the Project

1 The Site 131

Annex-I : Site 132

Annex-II : Dates for providing Right of Way of Construction Zone 137
Annex-III : Alignment Plans 138
Annex-IV : Environment Clearances 140

viii

8
Schedule – B 138
Development of the Project Highway 138

1. Development of the Project Highway 138

2. [Rehabilitation and augmentation] 138

3. Specifications and Standards 138
Annex-I : Description of [Two-Laning] 139
Schedule – C 165

Project Facilities 165

1. Project Facilities 165

2. Description of Project Facilities 165

Schedule – D 167

Specifications and Standards 167

1. Construction 167

2. Design Standards 167

Annex-I : Specifications and Standards for Construction 168
Schedule – E 170

Maintenance Requirements 170

1. Maintenance Requirements 170

2. Repair/rectification of Defects and deficiencies 170

3. Other Defects and deficiencies 170
4. Extension of time limit 171
5. Emergency repairs/restoration 171
6. Daily inspection by the Contractor 171
7. Pre-monsoon inspection / Post-monsoon inspection 171
8. Repairs on account of natural calamities 171
Annex-I : Repair/rectification of Defects and deficiencies 172
Schedule – F 217

Applicable Permits 217

1. Applicable Permits 217

Ix

9
Schedule – G 218
Annex-I : Form of Bank Guarantee 218

Annex-II : Form for Guarantee for Advance Payment 220

Schedule - H 224

Contract Price Weightages

Schedule - I 254

Drawings 254

1. Drawings 254

2. Additional Drawings 254

Annex-I : List of Drawings 255
Schedule - J 256

Project Completion Schedule 256

1. Project Completion Schedule 256

2. Project Milestone-I 256

3. Project Milestone-II 256
4. Project Milestone-III 256
5. Scheduled Completion Date 256
6. Extension of time 256
Schedule - K 258

Tests on Completion 258

1. Schedule for Tests 258

2. Tests 258
3. Agency for conducting Tests 259
4. Completion Certificate 259
Schedule - L 260

Completion Certificate 260

10
Schedule – M 262
Payment Reduction for Non-Compliance 262

1. Payment reduction for non-compliance with the Maintenance Requirements 262

2. Percentage reductions in lump sum payments on monthly basis 262

Schedule – N 264

Selection of Authority’s Engineer 264

1. Selection of Authority’s Engineer 264

2. Terms of Reference 264

3. Appointment of Government entity as Authority’s Engineer 265
Annex-I : Terms of Reference for Authority’s Engineer 265
Schedule – O 271

Forms of Payment Statements 271

1. Stage Payment Statement for Works 271

2. Monthly Maintenance Payment Statement 271

3. Contractor’s claim for Damages 271
Schedule – P 272

Insurance 272

1. Insurance during Construction Period 272

2. Insurance for Contractor's Defects Liability 272

3. Insurance against injury to persons and damage to property 272
4. Insurance to be in joint names 273
Schedule-Q 274

Tests on Completion of Maintenance Period 274

1. Riding Quality test: 274

2. Visual and physical test: 274

Schedule-R 275

Taking Over Certificate 275

xi

11
 Part I

Preliminary

1
 Engineering, Procurement and Construction Agreement

THIS AGREEMENT1 is entered into on this the ……….. day of ………, 20…..

Between

[The President of India through the Ministry of Road Transport & Highways,
Government of India represented by:

Director General (Road Development) & Special Secretary, Ministry of Road Transport
& Highways, Transport Bhawan, 1, Parliament Street, New Delhi 110001/
CE (NH) PWD, State of Jharkhand, National Highway Wing, Ranchi-834004
Chairman, National Highways Authority of India, G-5 & 6, Sector 10, Dwarka, New
Delhi-110075/MD, NHIDCL, PTI Building, Parliament Street, New Delhi/DGBR
<.....address>]

(strike out whichever is not applicable)

(hereinafter referred to as the “Authority” which expression shall, unless repugnant

to the context or meaning thereof, include its administrators, successors and assigns)
of One Part;

And

<insert name of party>,2 the selected bidder3 having its registered office at <insert
registered office address of the party>, (hereinafter referred to as the “Contractor”
which expression shall, unless repugnant to the context or meaning thereof, include
its successors and permitted assigns) of the Other Part.

Whereas:

A. The Government of India entrusted the development, maintenance and management

Reconstruction/Widening work from Km 49.00 to 52.800 of NH-220 the state of Jharkhand on EPC
mode.)]5 to the Authority;

1 Serially numbered footnotes in this Agreement are for guidance of the Authority and should be omitted
from the draft Agreement forming part of Bid Documents. Footnotes marked “$” shall be retained in the
draft Agreement.

2 All provisions enclosed in curly parenthesis shall be retained in the Bid Documents and shall be
modified as required after the selected bidder has been identified.

3 Refers to the single entity or the lead member of the joint venture, which is the selected bidder under
the RFP.

4 All asterisks in this Model Agreement should be substituted by project-specific particulars in the draft
Agreement forming part of Bid Documents.

5 All project-specific provisions in this Model EPC Agreement have been enclosed in square parenthesis
and may be modified, as necessary, before issuing the draft Agreement forming part of Bid Documents.

2
B. The Authority resolved to rehabilitate and augment the -to [Reconstruction/Widening
work from Km 49.00 to 52.800 of NH-220 the state of Jharkhand on EPC mode. (Job No. NH-
220(AP)2023-24/346)] on Engineering, Procurement, Construction (“EPC”) basis in
accordance with the terms and conditions to be set forth in an agreement to be
entered into.

C. The Authority accordingly invited the proposals (the “Request for Proposals” or
“RFP”) from the eligible bidders as per the technical and commercial terms and
conditions prescribed in the RFP for undertaking the Project.

D. After evaluation of the bids received, the Authority accepted the bid of the selected
bidder and issued its Letter of Acceptance No. <insert details> dated <insert date>
(hereinafter called the “LOA”) to the selected bidder for [rehabilitation and
augmentation of the above section of [NH220] at the Contract Price specified
hereinafter, requiring the selected bidder to inter alia:

(i) to give his consent to enter into this Agreement and the enforceability of the
provisions thereof, within 10 (ten) days of the date of issue of LOA;

(ii) submit Performance Security and Additional Performance Security (if any) as
per RFP requirements, and
(iii) execute this Agreement within 30 (thirty) days of the date of issue of LOA.

E. The Contractor has fulfilled the requirements specified in Recital (D) above;

NOW, THEREFORE, in consideration of the foregoing and the respective covenants set
forth in this Agreement, the sufficiency and adequacy of which is hereby
acknowledged, the Authority hereby covenants to pay the Contractor, in
consideration of the obligations specified herein, the Contract Price or such other sum
as may become payable under the provisions of the Agreement at the times and in the
manner specified by the Agreement and intending to be legally bound hereby, the
Parties agree as follows:

3
 Article 1

Definitions and Interpretations

1.1 Definitions

(i) The words and expressions beginning with capital letters and defined in this
Agreement shall, unless the context otherwise requires, have the meaning ascribed
thereto herein, and the words and expressions defined in the Schedules and used
therein shall have the meaning ascribed thereto in the Schedules.

(ii) In this Agreement, the following words and expressions shall, unless repugnant to the
context or meaning thereof, have the meaning hereinafter respectively assigned to
them:

“Accounting Year” means the financial year commencing from the first day of April of
any calendar year and ending on the thirty-first day of March of the next calendar
year;

“Advance Payment” shall have the meaning set forth in Clause 19.2;

“Affected Party” shall have the meaning set forth in Clause 21.1;

“Affiliate” means, in relation to either Party {and/or Members}, a person who

controls, is controlled by, or is under the common control with such Party {or
Member} (as used in this definition, the expression “control” means, with respect to a
person which is a company or corporation, the ownership, directly or indirectly, of
more than 50% (fifty per cent) of the voting shares of such person, and with respect
to a person which is not a company or corporation, the power to direct the
management and policies of such person, whether by operation of law or by contract
or otherwise);

“Agreement” means this Agreement, its Recitals, the Schedules hereto and any
amendments thereto, or any supplementary agreement made in accordance with the
provisions contained in this Agreement;

“Applicable Laws” means all laws, brought into force and effect by the GOI or the State
Government including rules, regulations and notifications made there under, and
judgments, decrees, injunctions, writs and orders of any court of record, applicable to
this Agreement and the exercise, performance and discharge of the respective rights
and obligations of the Parties hereunder, as may be in force and effect during the
subsistence of this Agreement;

“Applicable Permits” means all clearances, licenses, permits, authorizations, no

objection certificates, consents, approvals and exemptions required to be obtained or
maintained under Applicable Laws in connection with the construction, operation and
maintenance of the Project Highway during the subsistence of this Agreement;

4
“Appointed Date” means the date declared by the Authority as the project
commencement date with the consent of the contractor, as per the process prescribed
in Article 3 and 8 of this Agreement;

“Arbitration Act” means the Arbitration and Conciliation Act, 1996, with all its
subsequent amendments;

“Authority” shall have the meaning attributed thereto in the array of Parties
hereinabove as set forth in the Recitals;

“Authority Default” shall have the meaning set forth in Clause 23.2;

“Authority’s Engineer” shall have the meaning set forth in Clause 18.1;

“Authority Representative” means such person or persons as may be authorized in

writing by the Authority to act on its behalf under this Agreement and shall include
any person or persons having authority to exercise any rights or perform and fulfill
any obligations of the Authority under this Agreement;

“Bank” means a bank incorporated in India and recognized by the Reserve Bank of
India

“Base Rate” means the floor rate of interest announced by the State Bank of India for
all its lending operations;

“Base Date” means the last date of the calendar month, which precedes the Bid Due
Date by at least 28 (twenty eight) days;

“Bid” means the documents in their entirety comprised in the bid submitted by the
[selected bidder/ Joint venture] in response to the Request for Proposal in
accordance with the provisions thereof;

“Bid Security” means the bid security provided by the Contractor to the Authority in
accordance with the Request for Proposal, and which is to remain in force until
substituted by the Performance Security;

“Change in Law” means the occurrence of any of the following after the Base Date:

(a) the enactment of any new Indian law;

(b) the repeal, modification or re-enactment of any existing Indian law;

(c) the commencement of any Indian law which has not come into effect until the
Base Date; or

(d) a change in the interpretation or application of any Indian law by a judgment

of a court of record which has become final, conclusive and binding, as
compared to such interpretation or application by a court of record prior to
the Base Date.

“Change of Scope” shall have the meaning set forth in Article 13;

5
“Change of Scope Notice” shall have the meaning set forth in Clause 13.2 (i);

“Change of Scope Request” shall have the meaning set forth in Clause 13.2 (ii);

“Change of Scope Order” shall have the meaning set forth in Clause 13.2 (iv);

“Completion Certificate” shall have the meaning set forth in Clause 12.2;

“Construction” shall have the meaning set forth in Clause 1.2 (f);

“Construction Period” means the period commencing from the Appointed Date and
ending on the date of the Completion Certificate;

“Construction Zone” shall have the meaning set forth in Clause 8.3 (i);

“Contract Price” means the amount specified in Clause 19.1 (i);

“Contractor” shall have the meaning attributed thereto in the array of Parties
hereinabove as set forth in the Recitals;

“Contractor Default” shall have the meaning set forth in Clause 23.1;

“Cure Period” means the period specified in this Agreement for curing any breach or
default of any provision of this Agreement by the Party responsible for such breach or
default and shall:

(a) commence from the date on which a notice is delivered by one Party to the
other Party asking the latter to cure the breach or default specified in such
notice;

(b) not relieve any Party from liability to pay Damages or compensation under
the provisions of this Agreement; and

(c) not in any way be extended by any period of Suspension under this
Agreement; provided that if the cure of any breach default by the Contractor
requires any reasonable action by the Contractor that must be approved by
the Authority or the Authority’s Engineer hereunder, the applicable Cure
Period shall be extended by the period taken by the Authority or the
Authority’s Engineer to accord their approval;

“Damages” shall have the meaning set forth in paragraph (w) of Clause 1.2;

“Defect” means any defect or deficiency in Construction of the Works or any part
thereof, which does not conform with the Specifications and Standards, and in the
case of Maintenance, means any Defect or deficiency which is specified in Schedule-E;

“Defects Liability Period” shall have the meaning set forth in Clause 17.1;

“Dispute” shall have the meaning set forth in Clause 26.1;

6
“Dispute Resolution Procedure” means the procedure for resolution of Disputes set forth in
Article 26;

“Drawings” means all of the drawings, calculations and documents pertaining to the Project
Highway as set forth in Schedule-I, and shall include ‘as built’ drawings of the Project Highway;

“Document” or “Documentation” means documentation in printed or written form, or in tapes,

discs, drawings, computer programmes, writings, reports, photographs, films, cassettes, or
expressed in any other written, electronic, audio or visual form;

“Emergency” means a condition or situation that is likely to endanger the safety or security of
the individuals on or about the Project Highway, including Users thereof, or which poses an
immediate threat of material damage to any of the Project Assets;

“Encumbrances” means, in relation to the Project Highway, any encumbrances such as

mortgage, charge, pledge, lien, hypothecation, security interest, assignment, privilege or
priority of any kind having the effect of security or other such obligations, and shall include any
designation of loss to payees or beneficiaries or any similar arrangement under any insurance
policy pertaining to the Project Highway, where applicable herein but excluding utilities
referred to in Clause 9.1;

“EPC” means engineering, procurement and construction;

“Final Payment Certificate” shall have the meaning set forth in Clause 19.15;

“Final Payment Statement” shall have the meaning set forth in Clause 19.13;

“Force Majeure” or “Force Majeure Event” shall have the meaning ascribed to it in Clause 21.1;

“GAD” or “General Arrangement Drawings” shall have the meaning set forth in Clause 3.1 (iii)
(b);

“GOI” or “Government” means the Government of India;

“Good Industry Practice” means the practices, methods, techniques, designs, standards, skills,
diligence, efficiency, reliability and prudence which are generally and reasonably expected
from a reasonably skilled and experienced contractor engaged in the same type of undertaking
as envisaged under this Agreement and which would be expected to result in the performance
of its obligations by the Contractor in accordance with this Agreement, Applicable Laws and
Applicable Permits in reliable, safe, economical and efficient manner;

“Government Instrumentality” means any department, division or sub- division of the

Government or the State Government and includes any commission, board, authority, agency
or municipal and other local authority or statutory body including panchayat under the control
of the Government or the State Government, as the case may be, and having jurisdiction over
all or any part of the Project Highway or the

7
performance of all or any of the services or obligations of the Contractor under or
pursuant to this Agreement;

“Handover Memorandum” shall have the meaning set forth in Clause 8.2;

“IRC” means the Indian Roads Congress;

“Indemnified Party” means the Party entitled to the benefit of an indemnity pursuant
to Article 25;

“Indemnifying Party” means the Party obligated to indemnify the other Party
pursuant to Article 25;

“Indirect Political Event” shall have the meaning set forth in Clause 21.3;

“Insurance Cover” means the aggregate of the maximum sums insured under the
insurance taken out by the Contractor pursuant to Article 20, and includes all
insurances required to be taken out by the Contractor under Clauses 20.1 and 20.9
but not actually taken, and when used in the context of any act or event, it shall mean
the aggregate of the maximum sums insured and payable or deemed to be insured
and payable in relation to such act or event;

“Intellectual Property” means all patents, trademarks, service marks, logos, get-up,
trade names, internet domain names, rights in designs, blue prints, programmes and
manuals, drawings, copyright (including rights in computer software), database
rights, semi-conductor, topography rights, utility models, rights in know-how and
other intellectual property rights, in each case whether registered or unregistered and
including applications for registration, and all rights or forms of protection having
equivalent or similar effect anywhere in the world;

“Interim Payment Certificate” or “IPC” means the interim payment certificate issued
by the Authority’s Engineer for payment to the Contractor in respect of Contractor’s
claims for payment raised in accordance with the provisions of this Agreement;

“Joint Venture” means the group of entities which have come together for
implementation of this Project;

“Lead Member” shall, in the case of a joint venture, mean the member of such joint
venture who shall have the authority to bind the contractor and each member of the
Joint venture; and shall be deemed to be the Contractor for the purposes of this
Agreement; the Lead Member shall itself undertake and perform at least 51% (fifty
one per cent) of the total length of the Project Highway;

“LOA” or “Letter of Acceptance” means the letter of acceptance issued by the

Authority as referred to in Recital (D);

“Maintenance” means the maintenance of the Project Highway as set forth in Article
14 for the period specified therein;

8
“Maintenance Inspection Report” shall have the meaning set forth in Clause 15.2;

“Maintenance Manual” shall have the meaning ascribed to it in Clause 10.7;

“Maintenance Programme” shall have the meaning set forth in Clause 14.3;

“Maintenance Period” shall have the meaning set forth in Clause 14.1;

“Maintenance Requirements” shall have the meaning set forth in Clause 14.2;

“Major Bridge” means a bridge having a total length of more than 60 (sixty) meters
between the inner faces of the dirt walls as specified in IRC:5;

“Manual” shall mean the Manual of Standards and Specifications for Project
Highways;

“Material Adverse Effect” means a material adverse effect of any act or event on the
ability of either Party to perform any of its obligations under and in accordance with
the provisions of this Agreement and which act or event causes a material financial
burden or loss to either Party;

“Materials” comprise of all the supplies used by the Contractor used in the Works or
for the maintenance of the Project Highway;

“Monthly Maintenance Statement shall have the meaning set forth in Clause 19.6;

“MORTH” means the Ministry of Road Transport and Highways or any substitute
thereof dealing with Highways;

“Non-Political Event” shall have the meaning set forth in Clause 21.2;

“Parties” means the parties to this Agreement collectively and “Party” shall mean any
of the parties to this Agreement individually;

“Performance Security” and “Additional Performance Security” shall have the

meaning set forth in Clause 7.1;

“Plant” means the apparatus and machinery intended to form or forming part of the
works of the Works;

“Political Event” shall have the meaning set forth in Clause 21.4;

“Programme” shall have the meaning set forth in Clause 10.1 (iii);

“Project” means the construction and maintenance of the Project Highway in

accordance with the provisions of this Agreement, and includes all works, services
and equipment relating to or in respect of the Scope of the Project;

“Project Assets” means all physical and other assets relating to (a) tangible assets
such as civil works and equipment including foundations, embankments, pavements,

9
road surface, interchanges, bridges, culverts, road over-bridges, drainage works,
traffic signals, sign boards, kilometer-stones, [toll plaza(s)], electrical systems,
communication systems, rest areas, relief centers, maintenance depots and
administrative offices; and (b) Project Facilities situated on the Site;

“Project Completion Date” means the date on which the Completion Certificate is
issued;

“Project Completion Schedule” means the progressive Project Milestones set forth in
Schedule-J for completion of the Project Highway on or before the Scheduled
Completion Date;

“Project Facilities” means all the amenities and facilities situated on the Site, as
described in Schedule-C;

“Project Highway” means the Site comprising the existing road {, proposed bypasses
andtunnels} forming part of [NH-220 from km 49.00 to km 52.80] and all Project Assets,
and its subsequent development and augmentation in accordance with this
Agreement;

“Project Milestone” means the project milestone set forth in Schedule-J;

“Proof Consultant” shall have the meaning set forth in Clause 10.2;

“Quality Assurance Plan” or “QAP” shall have the meaning set forth in Clause 11.2;

“Re.”, “Rs.” or “Rupees” or “Indian Rupees” or “INR” means the lawful currency of the
Republic of India;

“Request for Proposals” or “RFP” shall have the meaning set forth in Recital ‘C’;

“Retention Money” shall have the meaning set forth in Clause 7.5;

“Right of Way” means and refers to the total land required and acquired for the
project, both in its width and length, together with all way leaves, easements,
unrestricted access and other rights of way, howsoever described, necessary for
construction and maintenance of the Project Highway in accordance with this
Agreement;

“Safety Consultant” shall have the meaning set forth in Clause 10.1;

“Scheduled Completion Date” shall be the date set forth in Clause 10.3;

“Scheduled Construction Period” means the period commencing from the Appointed
Date and ending on Scheduled Completion Date;

“Scope of the Project” shall have the meaning set forth in Clause 2.1;

“Section” means a part of the Project Highway;

“Site” shall have the meaning set forth in Clause 8.1;

10
“Specifications and Standards” means the specifications and standards relating to the
quality, quantity, capacity and other requirements for the Project Highway, as set
forth in Schedule-D, and any modifications thereof, or additions thereto, as included in
the design and engineering for the Project Highway submitted by the Contractor to,
and expressly approved by, the Authority;

"Stage Payment Statement" shall have the meaning set forth in Clause 19.4;

“Structures” means an elevated road or a flyover, as the case may be;

“Sub-contractor” means any person or persons to whom a part of the Works or the
Maintenance has been subcontracted by the Contractor and the permitted legal
successors in title to such person, but not an assignee to such person;

“Suspension” shall have the meaning set forth in Article 22;

“Taking over Certificate” shall have the meaning set forth in Clause 14.10;

“Taxes” means any Indian taxes including GST, excise duties, customs duties, value
added tax, sales tax, local taxes, cess and any impost or surcharge of like nature
(whether Central, State or local) on the goods, Materials, equipment and services
incorporated in and forming part of the Project Highway charged, levied or imposed
by any Government Instrumentality, but excluding any interest, penalties and other
sums in relation thereto imposed on any account whatsoever. For the avoidance of
doubt, Taxes shall not include taxes on corporate income;

“Termination” means the expiry or termination of this Agreement;

“Termination Notice” means the communication issued in accordance with this

Agreement by one Party to the other Party terminating this Agreement;

“Termination Payment” means the amount payable by either Party to the other upon
Termination in accordance with Article 23;

“Terms of Reference” or “TOR” shall have the meaning set forth in Clause 18.2;

“Tests” means the tests set forth in Schedule-K to determine the completion of Works
in accordance with the provisions of this Agreement;

“Time Extension” shall have the meaning set forth in Clause 10.5;

“User” means a person who travels or intends to travel on the Project Highway or any
part thereof in/on any vehicle;

“Valuation of Unpaid works” shall have the meaning set forth in Clause 23.5;

“Works” means all works including survey and investigation, design, engineering,
procurement, construction, Plant, Materials, maintenance, temporary works and

11
 other things necessary to complete the Project Highway in accordance with this
Agreement; and

“WPI” means the wholesale price index for various commodities as published by the
Ministry of Commerce and Industry, GOI and shall include any index which
substitutes the WPI, and any reference to WPI shall, unless the context otherwise
requires, be construed as a reference to the WPI published for the period ending with
the preceding month.

1.2 Interpretation

(i) In this Agreement, unless the context otherwise requires,

(a) references to any legislation or any provision thereof shall include

amendment or re-enactment or consolidation of such legislation or any
provision thereof so far as such amendment or re-enactment or consolidation
applies or is capable of applying to any transaction entered into hereunder;

(b) references to laws of India or Indian law or regulation having the force of law
shall include the laws, acts, ordinances, rules, regulations, bye laws or
notifications which have the force of law in the territory of India and as from
time to time may be amended, modified, supplemented, extended or re-
enacted;

(c) references to a “person” and words denoting a natural person shall be

construed as a reference to any individual, firm, company, corporation,
society, trust, government, state or agency of a state or any association or
partnership (whether or not having separate legal personality) of two or more
of the above and shall include successors and assigns;

(d) the table of contents, headings or sub-headings in this Agreement are for
convenience of reference only and shall not be used in, and shall not affect, the
construction or interpretation of this Agreement;

(e) the words “include” and “including” are to be construed without limitation
and shall be deemed to be followed by “without limitation” or “but not limited
to” whether or not they are followed by such phrases;

(f) references to “construction” or “building” include, unless the context

otherwise requires, survey and investigation, design, developing, engineering,
procurement, supply of plant, materials, equipment, labor, delivery,
transportation, installation, processing, fabrication, testing, and
commissioning of the Project Highway, including maintenance during the
Construction Period, removing of defects, if any, and other activities incidental
to the construction and “construct” or “build” shall be construed accordingly;

(g) references to “development” include, unless the context otherwise requires,

construction, renovation, refurbishing, augmentation, up- gradation and other
activities incidental thereto during the Construction Period, and “develop”
shall be construed accordingly;

12
(h) any reference to any period of time shall mean a reference to that according to
Indian standard time;
(i) any reference to day shall mean a reference to a calendar day;

(j) references to a “business day” shall be construed as a reference to a day (other

than a Sunday) on which banks in Delhi are generally open for business;

(k) any reference to month shall mean a reference to a calendar month as per the
Gregorian calendar;

(l) references to any date, period or Project Milestone shall mean and include
such date, period or Project Milestone as may be extended pursuant to this
Agreement;

(m) any reference to any period commencing “from” a specified day or date and
“till” or “until” a specified day or date shall include both such days or dates;
provided that if the last day of any period computed under this Agreement is
not a business day, then the period shall run until the end of the next business
day;
(n) the words importing singular shall include plural and vice versa;
(o) references to any gender shall include the other and the neutral gender;

(p) “lakh” means a hundred thousand (100,000) and “crore” means ten million
(10,000,000);

(q) “indebtedness” shall be construed so as to include any obligation (whether

incurred as principal or surety) for the payment or repayment of money,
whether present or future, actual or contingent;

(r) references to the “winding-up”, “dissolution”, “insolvency”, or “reorganization”

of a company or corporation shall be construed so as to include any equivalent
or analogous proceedings under the law of the jurisdiction in which such
company or corporation is incorporated or any jurisdiction in which such
company or corporation carries on business including the seeking of
liquidation, winding-up, reorganization, dissolution, arrangement, protection
or relief of debtors;

(s) save and except as otherwise provided in this Agreement, any reference, at
any time, to any agreement, deed, instrument, license or document of any
description shall be construed as reference to that agreement, deed,
instrument, license or other document as amended, varied, supplemented,
modified or suspended at the time of such reference; provided that this Clause
shall not operate so as to increase liabilities or obligations of the Authority
hereunder or pursuant hereto in any manner whatsoever;

(t) any agreement, consent, approval, authorization, notice, communication,

information or report required under or pursuant to this Agreement from or
by any Party or the Authority’s Engineer shall be valid and effective only if it is
in writing under the hand of a duly authorized representative of such Party or
the Authority’s Engineer, as the case may be, in this behalf and not otherwise;

13
 (u) the Schedules and Recitals to this Agreement form an integral part of this
Agreement and will be in full force and effect as though they were expressly
set out in the body of this Agreement;

(v) references to Recitals, Articles, Clauses, Sub-clauses or Schedules in this

Agreement shall, except where the context otherwise requires, mean
references to Recitals, Articles, Clauses, Sub-clauses and Schedules of or to this
Agreement, and references to a Paragraph shall, subject to any contrary
indication, be construed as a reference to a Paragraph of this Agreement or of
the Schedule in which such reference appears;

(w) the damages payable by either Party to the other of them, as set forth in this
Agreement, whether on per diem basis or otherwise, are mutually agreed
genuine pre-estimated loss and damage likely to be suffered and incurred by
the Party entitled to receive the same and are not by way of penalty or
liquidated damages (the “Damages”); and

(x) time shall be of the essence in the performance of the Parties’ respective
obligations. If any time period specified herein is extended for the reasons
specified in the Agreement, such extended time shall also be of the essence.

(ii) Unless expressly provided otherwise in this Agreement, any Documentation required
to be provided or furnished by the Contractor to the Authority shall be provided free
of cost and in three copies, and if the Authority is required to return any such
Documentation with its comments and/or approval, it shall be entitled to retain two
copies thereof.

(iii) The rule of construction, if any, that a contract should be interpreted against the
parties responsible for the drafting and preparation thereof, shall not apply.

(iv) Any word or expression used in this Agreement shall, unless otherwise defined or
construed in this Agreement, bear its ordinary English meaning and, for these
purposes, the General Clauses Act, 1897 shall not apply.

1.3 Measurements and arithmetic conventions

All measurements and calculations shall be in the metric system and calculations
done to 2 (two) decimal places, with the third digit of 5 (five) or above being rounded
up and below 5 (five) being rounded down.

1.4 Priority of agreements and errors/discrepancies

(i) This Agreement, and all other agreements and documents forming part of or referred
to in this Agreement are to be taken as mutually explanatory and, unless otherwise
expressly provided elsewhere in this Agreement, the priority of this Agreement and
other documents and agreements forming part hereof or referred to herein shall, in
the event of any conflict between them, be in the following order:

(a) this Agreement; and

14
 (b) all other agreements and documents forming part hereof or referred to
herein; i.e. this Agreement at (a) above shall prevail over the agreements and
documents at (b).

(ii) Subject to the provisions of Clause 1.4 (i), in case of ambiguities or discrepancies
within this Agreement, the following shall apply:

(a) between two or more Clauses of this Agreement, the provisions of a specific
Clause relevant to the issue under consideration shall prevail over those in
other Clauses;

(b) between the Clauses of this Agreement and the Schedules, the Clauses shall
prevail and between Schedules and Annexes, the Schedules shall prevail;
(c) between any two Schedules, the Schedule relevant to the issue shall prevail;

(d) between the written description on the Drawings and the Specifications and
Standards, the latter shall prevail;

(e) between the dimension scaled from the Drawing and its specific written
dimension, the latter shall prevail; and

(f) between any value written in numerals and that in words, the latter shall
prevail.

1.5 Joint and several liability

(i) If the Contractor has formed a Joint Venture of two or more persons for implementing
the Project:

(a) these persons shall, without prejudice to the provisions of this Agreement or
any other agreement, be deemed to be jointly and severally liable to the
Authority for the performance of the Agreement; and

(b) the Contractor shall ensure that no change in the composition of the Joint
Venture is effected without the prior consent of the Authority.

(ii) Without prejudice to the joint and several liability of all the members of the Joint
Venture, the Lead Member shall represent all the members of the Joint Venture and
shall always be liable and responsible for discharging the functions and obligations of
the Contractor. The Contractor shall ensure that each member of the Joint Venture
shall be bound by any decision, communication, notice, action or inaction of the Lead
Member on any matter related to this Agreement and the Authority shall be entitled
to rely upon any such action, decision or communication of the Lead Member. The
Authority shall have the right to release payments solely to the Lead Member and
shall not in any manner be responsible or be held liable for the inter se allocation of
payments among members of the Joint venture.6

6 This Clause 1.5 may be omitted if the Contractor is not a Joint venture. Even if the Contractor is a Joint
venture, the Authority may, at its discretion, delete this provision.

15
 Part II

Scope of Project

16
 Article 2

Scope of the Project

2.1 Scope of the Project

Under this Agreement, the scope of the Project (the “Scope of the Project”) shall mean
and include:

(a) construction of the Project Highway on the Site set forth in Schedule- A and as
specified in Schedule-B together with provision of Project Facilities as
specified in Schedule-C, and in conformity with the Specifications and
Standards set forth in Schedule-D;

(b) maintenance of the Project Highway in accordance with the provisions of this
Agreement and in conformity with the requirements set forth in Schedule-E;
and

(c) performance and fulfillment of all other obligations of the Contractor in

accordance with the provisions of this Agreement and matters incidental
thereto or necessary for the performance of any or all of the obligations of the
Contractor under this Agreement.

17
 Article 3

Obligations of the Authority

3.1 Obligations of the Authority

(i) The Authority shall, at its own cost and expense, undertake, comply with and perform
all its obligations set out in this Agreement or arising hereunder.

(ii) The Authority shall be responsible for the correctness of the Scope of the Project,
Project Facilities, Specifications and Standards and the criteria for testing of the
completed Works.

(iii) The Authority shall, upon submission of the Performance Security as per the RFP by
the Contractor, shall provide to the Contractor:

(a) No less than 90% (ninety per cent) of the required Right of Way of the
Construction Zone of total length of the Project Highway within a period of 30
(thirty) days from the date of this Agreement, which shall be in contiguous
stretches of length not less than 5 (five) kilometer.
(b) approval of the general arrangement drawings (the “GAD”) from railway
authorities to enable the Contractor to construct road over- bridges/ under-
bridges at level crossings on the Project Highway in accordance with the
Specifications and Standards, and subject to the terms and conditions
specified in such approval, within a period of 60 (sixty) days from the
Appointed Date, and reimbursement of all the costs and expenses paid by the
Contractor to the railway authorities for and in respect of the road over-
bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8

(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the
case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the
Contractor to Damages in a sum calculated in accordance with the provisions of
Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of
Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the
Damages for delay in approval of GAD by the railway authorities for a particular road
over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under
the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two)
kilometre for each such road over-bridge/ under-bridge.

7 Clause (b) may be omitted if the Project does not include a road over-bridge/under-bridge.
8 Clause 3.1 (iii) (c) may be suitably modified in the event that all the environmental clearances for the
Project Highway have been received or are not required. It should be clearly stated that all the
environmental clearances for the Project Highway have been received; or such environmental clearances
for the Project Highway are not required.

18
(v) Notwithstanding anything to the contrary contained in this Agreement, the Parties
expressly agree that the aggregate Damages payable under Clauses 3.1 (iv), 8.3 and
9.5 shall not exceed 1% (one per cent) of the Contract Price. For the avoidance of
doubt, the Damages payable by the Authority under the aforesaid Clauses shall not be
additive if they arise concurrently from more than one cause but relate to the same
part of the Project Highway.

Both the parties agree that payment of such Damages shall be full and final settlement
of all claims of the Contractor and such compensation shall be the sole remedy against
delays of the Authority and both parties further agree that the payment of Damages
shall be the final cure for the Contractor against delays of the Authority, without
recourse to any other payments.

(vi) The Authority agrees to provide support to the Contractor and undertakes to observe,
comply with and perform, subject to and in accordance with the provisions of this
Agreement and the Applicable Laws, the following:

(a) upon written request from the Contractor, and subject to the Contractor
complying with Applicable Laws, provide reasonable support to the
Contractor in procuring Applicable Permits required from any Government
Instrumentality for implementation of the Project;

(b) upon written request from the Contractor, provide reasonable assistance to
the Contractor in obtaining access to all necessary infrastructure facilities and
utilities, including water and electricity at rates and on terms no less favorable
than those generally available to commercial customers receiving
substantially equivalent services;

(c) procure that no barriers that would have a material adverse effect on the
works are erected or placed on or about the Project Highway by any
Government Instrumentality or persons claiming through or under it, except
for reasons of Emergency, national security, law and order or collection of
inter-state taxes;

(d) not do or omit to do any act, deed or thing which may in any manner violate
any provisions of this Agreement;

(e) support, cooperate with and facilitate the Contractor in the implementation of
the Project in accordance with the provisions of this Agreement; and

(f) upon written request from the Contractor and subject to the provisions of
Clause 4.3, provide reasonable assistance to the Contractor and any expatriate
personnel of the Contractor or its Sub-contractors to obtain the applicable
visas and the requisite work permits for the purposes of discharge by the
Contractor or its Sub-contractors of their obligations under this Agreement
and the agreements with the Sub-contractors.

19
3.2 Maintenance obligations prior to the Appointed Date

The Authority shall, prior to the Appointed Date, maintain the Project Highway, at its
own cost and expense, so that its traffic worthiness and safety are at no time
materially inferior as compared to its condition 10 (ten) days prior to the last date for
submission of the Bid, and in the event of any material deterioration or damage other
than normal wear and tear, undertake repair thereof. For the avoidance of doubt, the
Authority shall undertake only routine maintenance prior to the Appointed Date, and
it shall undertake special repairs only in the event of excessive deterioration or
damage caused due to unforeseen events such as floods or earthquake.

3.3 Environmental Clearances

The Authority represents and warrants that the environmental clearances required
for construction of the Project shall be procured by the Authority prior to the date of
issue of LOA. For the avoidance of doubt, the present status of environmental
clearances is specified in Schedule-A.9

3.4 Deemed Termination upon delay

Without prejudice to the provisions of Clauses 8.3, and subject to the provisions of
Clause 7.3, the Parties expressly agree that in the event the Appointed Date does not
occur, for any reason whatsoever, within 90 days of signing of the Agreement and
submission of the full Performance Security by the Contractor, the Agreement shall be
deemed to have been terminated. The Authority shall pay damages to the Contractor
equivalent to 1% of the Contract Price (3% in case of standalone bridge projects). All
other rights, privileges, claims and entitlements of the Contractor under or arising out
of this Agreement shall be deemed to have been waived by, and to have ceased. The
Contractor shall hand over all information in relation to the Highway, including but
not limited to any data, designs, drawings, structures, information, plans, etc.
prepared by them for the Highway, to the Authority.

9 Clause 3.3 may be suitably modified in the event that all the environmental clearances for the Project
Highway have been received or are not required. It should be clearly stated that all the environmental
clearances for the Project Highway have been received; or such environmental clearances for the Project
Highway are not required.

20
 Article 4

Obligations of the Contractor

4.1 Obligations of the Contractor

(i) Subject to and on the terms and conditions of this Agreement, the Contractor shall
undertake the survey, investigation, design, engineering, procurement, construction,
and maintenance of the Project Highway and observe, fulfil, comply with and perform
all its obligations set out in this Agreement or arising hereunder.

(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits
(including renewals as required) in the performance of its obligations under this
Agreement.

(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge
its obligations in accordance with Good Industry Practice and as a reasonable and
prudent person.

(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project
Highway from the Appointed Date until the end of the Construction Period at the
Contractor’s cost, save and except to the extent that any such loss, defect, or damage
shall have arisen from any willful default or neglect of the Authority.

(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway
during the Defects Liability Period at the Contractor’s cost to the extent that such loss,
defect or damage shall have arisen out of the reasons specified in Clause 17.3.

(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during
the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1
(ii), save and except to the extent that any such loss or damage shall have arisen on
account of any wilful default or neglect of the Authority or on account of a Force
Majeure Event.

(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation
of its obligations elsewhere set out in this Agreement:

(a) make, or cause to be made, necessary applications to the relevant Government

Instrumentalities with such particulars and details as may be required for
obtaining Applicable Permits set forth in Schedule-F and obtain and keep in
force and effect such Applicable Permits in conformity with the Applicable
Laws;

(b) procure, as required, the appropriate proprietary rights, licenses, agreements

and permissions for Materials, methods, processes and systems used or
incorporated into the Project Highway;

21
 (c) make reasonable efforts to maintain harmony and good industrial relations
among the personnel employed by it or its Sub-contractors in connection with
the performance of its obligations under this Agreement;

(d) ensure and procure that its Sub-contractors comply with all Applicable
Permits and Applicable Laws in the performance by them of any of the
Contractor’s obligations under this Agreement;

(e) not do or omit to do any act, deed or thing which may in any manner violate
any provisions of this Agreement;

(f) support, cooperate with and facilitate the Authority in the implementation
and operation of the Project in accordance with the provisions of this
Agreement;

(g) ensure that the Contractor and its Sub-contractors comply with the safety and
welfare measures for labor in accordance with the Applicable Laws and Good
Industry Practice;

(h) keep, on Site, a copy of this Agreement, publications named in this Agreement,
the Drawings, Documents relating to the Project, and Change of Scope orders
and other communications given under this Agreement. The Authority’s
Engineer and its authorized personnel shall have the right of access to all
these documents at all reasonable times;

(i) cooperate with other contractors employed by the Authority and personnel of
any public authority; and

(j) not interfere unnecessarily or improperly with the convenience of the public,
or the access to and use and occupation of all roads and footpaths, irrespective
of whether they are public or in the possession of the Authority or of others.

(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct,
manage, inspect and test the Works. The Contractor shall provide all necessary
superintendence of the Works for the proper fulfilling of the Contractor's obligations
under the Agreement. Such superintendence shall be given by competent person
having adequate knowledge of the operations to be carried out (including the
methods and techniques required, the hazards likely to be encountered and methods
of preventing accidents) for the satisfactory and safe execution of the Works.

(ix) The Contractor shall obtain and maintain a project related bank account operational
at site where all transactions related to the payment of work will be done. The
Contractor shall submit a monthly account statement and a detailed report on
utilization of funds transferred to this project related bank account to Authority’s
Engineer. Notwithstanding anything contrary to this agreement, the authority, in the
interest and to ensure timely completion of the work, reserves the right to audit such
bank accounts to ensure that there is no diversion of funds from this project specific
account to any other project being implemented by the Contractor.

22
(x) The Contractor shall provide the documents of the Contractor specified in the
Agreement, and all Contractors' personnel; Goods, consumables and other things and
services, whether of a temporary or permanent nature, required in and for the
execution, completion of Works and remedying defects.

(xi) The Contractor shall perform the Works in conformity with the Project requirements
and other requirements and standards prescribed under or pursuant to the
Agreement.

(xii) The Contractor shall carry out such work incidental and contingent to the original
Scope of the Project to comply with Good Industry Practices.

(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment
and materials within the reach of the Site during the Defects Liability Period so that
any defects arising are promptly attended.

4.2 Obligations relating to sub-contracts and any other agreements

(i) The Contractor, whether Joint Venture or sole, shall not sub-contract any Works in
more than 49% (forty nine per cent) of the Contract Price and shall carry out Works
directly under its own supervision and through its own personnel and equipment in
at least 51% (fifty one per cent) of the Contract Price. Further, in case the
Contractor is a Joint Venture, then the Lead Member shall carry out Works directly
through its own resources (men, material and machines etc.) in at least 51% (fifty one
per cent) of total length of the Project Highway. Provided, however, that in respect of
the Works carried out directly by the Contractor, it may enter into contracts for the
supply and installation of Materials, Plant, equipment, road furniture, safety devices
Andlabour, as the case may be, for such Works. For the avoidance of doubt, the Parties
agree that the Contractor may sub-divide the aforesaid length of 51% (fifty one per
cent) in no more than 5 (five) sections of the Project Highway. The Parties further
agree that all obligations and liabilities under this Agreement for the entire project
Highway shall at all times remain with the Contractor.

(ii) In the event any sub-contract for Works, or the aggregate of such sub-contracts with
any Sub-contractor, exceeds 5% (five percent) of the Contract Price, the Contractor
shall communicate the name and particulars, including the relevant experience of the
Sub-contractor, to the Authority prior to entering into any such sub-contract. The
Authority shall examine the particulars of the Sub- contractor from the national
security and public interest perspective and may require the Contractor, no later than
15 (fifteen) business days from the date of receiving the communication from the
Contractor, not to proceed with the sub-contract, and the Contractor shall comply
therewith.

(iii) In the event any sub-contract referred to in Clause 4.2 (ii) relates to a Sub- contractor
who has, over the preceding 3 (three) years, not undertaken at least one work of a
similar nature with a contract value exceeding 40% (forty per cent) of the value of the
sub-contract to be awarded hereunder, and received payments in respect thereof for
an amount equal to at least such 40% (forty per cent), the Authority may, no later

23
 than 15 (fifteen) business days from the date of receiving the communication from
the Contractor, require the Contractor not to proceed with such sub-contract, and the
Contractor shall comply therewith without delay or demur.

(iv) It is expressly agreed that the Contractor shall, at all times, be responsible and liable
for all its obligations under this Agreement notwithstanding anything contained in the
agreements with its Sub-contractors or any other agreement that may be entered into
by the Contractor, and no default under any such agreement shall excuse the
Contractor from its obligations or liability under this Agreement. However, in case of
non-compliance of the Contractor towards his obligations for payments to the
approved Sub-contractor(s), which is likely to affect the progress of works, the
authority reserves the right to intervene and direct the Contractor to release such
outstanding payments to approved Sub-contractor(s) out of the payments due for the
completed Works in the interest of work.

4.3 Employment of foreign nationals

The Contractor acknowledges, agrees and undertakes that employment of foreign

personnel by the Contractor and/or its Sub-contractors and their sub- contractors
shall be subject to grant of requisite regulatory permits and approvals including
employment/ residential visas and work permits, if any required, and the obligation
to apply for and obtain the same shall always rest with the Contractor.
Notwithstanding anything to the contrary contained in this Agreement, refusal of or
inability to obtain any such permits and approvals by the Contractor or any of its Sub-
contractors or their sub-contractors shall not constitute a Force Majeure Event, and
shall not in any manner excuse the Contractor from the performance and discharge it
of its obligations and liabilities under this Agreement, and the Contractor’s liabilities
hereunder shall remain unaffected by such failure, refusal or inability.

4.4 Contractor’s personnel

(i) The Contractor shall ensure that the personnel engaged by it or by its Sub-contractors
in the performance of its obligations under this Agreement are at all times
appropriately and adequately qualified, skilled and experienced in their respective
functions in conformity with Good Industry Practice. The Contractor will try to hire at
least 10% (ten percent) trained workmen as per the National Skills Qualifications
Framework. If necessary, the requisite workmen may be got trained by the Contractor
at his cost through authorized training centers of the Directorate General of Training
(DGT). The Contractor will organize training at project site/ sites for the trainees as
and when required as per the training schedule finalized in consultation with the
training centers. The trainees shall be paid stipend by the Contractor (subject to a
maximum of Rs. 15,000/- per person) on the basis of minimum wages to compensate
for loss of income during the training period.

(ii) The Authority’s Engineer may, for reasons to be specified in writing, direct the
Contractor to remove any member of the Contractor’s or Sub-contractor’s personnel.
Provided that any such direction issued by the Authority’s Engineer shall specify the
reasons for the removal of such person.

24
(iii) The Contractor shall on receiving such a direction from the Authority’s Engineer
order for the removal of such person or persons with immediate effect. It shall be the
duty of the Contractor to ensure that such persons are evicted from the Site within 10
(ten) days of any such direction being issued in pursuance of Clause 4.4 (ii). The
Contractor shall further ensure that such persons have no further connection with the
Works or Maintenance under this Agreement. The Contractor shall then appoint (or
cause to be appointed) a replacement.

4.5 Advertisement on Project Highway

The Project Highway or any part thereof shall not be used in any manner to advertise
any commercial product or services.

4.6 Contractor's care of the Works

The Contractor shall bear full risk in, and take full responsibility for, the care of the
Works, and of the Materials, goods and equipment for incorporation therein, from the
Appointed Date until the date of Completion Certificate, save and except to the extent
that any such loss or damage shall have arisen from any wilful default or gross neglect
of the Authority.

4.7 Electricity, water and other services

The Contractor shall be responsible for procuring of all utilities as may be required,
including without limitation, adequate power, water and other services.

4.8 Unforeseeable difficulties

Except as otherwise stated in the Agreement:

(a) the Contractor accepts complete responsibility for having foreseen all
difficulties and costs of successfully completing the Works;

(b) the Contract Price shall not be adjusted to take account of any unforeseen
difficulties or costs; and

(c) the Scheduled Completion Date shall not be adjusted to take account of any
unforeseen difficulties or costs.

4.9 Co-ordination of the Works

(i) The Contractor acknowledges that in addition to the Agreement, it is also aware of
terms of the other Project contracts and other agreements the Authority has
negotiated and entered into for performance of its obligations under the Agreement (
copies of other contracts and other agreements are made available to the Contractor
from time to time) and that the Contractor is fully aware of the consequences to the
Authority which would or are likely to result from a breach by the Contractor of its
obligations under the Agreement. In the event the actions of the Contractor result in
the breach by the Authority of any or all of the other Project contracts and such
breach imposes any liability on the Authority, the Contractor shall: (a) undertake all

25
 steps as may be possible to mitigate or neutralize the liability that has arisen, and (b)
indemnify the Authority against any such liability and compensate the Authority to
that extent.

(ii) The Contractor shall be responsible for the co-ordination and proper provision of the
Works, including co-ordination of other Contractors or Sub-contractors for the
Project. The Contractor shall co-operate with the Authority in the co- ordination of the
Works with the works under the other Project contracts. The Contractor shall provide
all reasonable support for carrying out their work to:

(a) any other contractors employed by the Authority;

(b) the workmen of the Authority;

(c) the workmen of any Governmental Instrumentality who may be employed in

the execution of work on or near the Site; and

(d) such other persons as is required in the opinion of the Authority for successful
completion of the Project.

4.10 Environmental Measures

(i) The Contractor agrees to conduct its activities in connection with the Agreement in
such a manner so as to comply with the environmental requirements which includes,
inter alia, all the conditions required to be satisfied under the
environmentalclearances and applicable law, and assumes full responsibility for
measures which are required to be taken to ensure such compliance.

4.11 Site Data

(i) The Contractor shall be deemed to have inspected and examined the Site and its
surroundings and to have satisfied himself before entering into the Agreement in all
material respects including but not limited to:

(a) the form and nature of the Site (including, inter-alia, the surface and sub-
surface conditions and geo-technical factors);
(b) the hydrological and climatic conditions;

(c) the extent and nature of the works already completed and Materials necessary
for the execution and completion of the Works and the remedying of any
defects that includes already executed part also.
(d) the suitability and the adequacy of the Site for the execution of the Works;

(e) the means of access to the Site and the accommodation the Contractor may
require;
(f) arranging permits as required as per [.] of the Agreement.
(g) the requirements of operation and maintenance; and

(h) all other factors and circumstances affecting the Contractor's rights and
obligations under the Agreement, the Contract Price and Time for Completion.

26
4.12 Sufficiency of Contract Price

The Contractor shall have satisfied itself as to the correctness and sufficiency of the
Contract Price. The Contract Price shall cover all its obligations under the Agreement,
in addition to all risks the Contractor has agreed to undertake under the Agreement,
including those associated with the performance of its obligations under the
Agreement and all things necessary for the provision of the Works in a manner
satisfactory to the Authority and in accordance with this Agreement.

4.13 Clearance of the Site

During the provision of the Works, and as a pre-condition to the issue of the Taking-
Over Certificate, the Contractor shall clear away and remove from the Site, all
Contractor's equipment, surplus material, wreckage, rubbish and temporary Works,
and shall keep the Site free from all unnecessary obstructions, and shall not store or
dispose of any Contractor's equipment or surplus materials on the Site. The
Contractor shall promptly clear away and remove from the Site any wreckage,
rubbish or temporary Works no longer required and leave the Site and the Works in a
clean and safe condition to the sole satisfaction of the Authority.

4.14 Obligations relating to Local Content

The Contractor [Class –I Local Supplier/ Class –II Local Supplier/ Non Local Supplier]
undertake to ensure minimum Local Content in the Project Highway of at least
[50%/20%] duly complying with the provisions of Department for Promotion of
Industry and internal Trade, Ministry of Commerce and Industry, Government of India
Order No. P-45021/2/2017-PP (BE-II) dated September 16, 2020, as amended or
modified till Bid due Date and the provisions under Rule 144(xi) of GFR, 2017

27
 Article 5

Representations and Warranties

5.1 Representations and warranties of the Contractor

(i) The Contractor represents and warrants to the Authority that:

(a) it is duly organized and validly existing under the laws of India, and has full
power and authority to execute and perform its obligations under this
Agreement and to carry out the transactions contemplated hereby;

(b) it has taken all necessary corporate and/or other actions under Applicable
Laws to authorize the execution and delivery of this Agreement and to validly
exercise its rights and perform its obligations under this Agreement;

(c) this Agreement constitutes its legal, valid and binding obligation, enforceable
against it in accordance with the terms hereof, and its obligations under this
Agreement will be legally valid, binding and enforceable against it in
accordance with the terms hereof;

(d) it is subject to the laws of India, and hereby expressly and irrevocably waives
any immunity in any jurisdiction in respect of this Agreement or matters
arising there under including any obligation, liability or responsibility
hereunder;

(e) the information furnished in the Bid, Request for Qualification and Request for
Proposals or otherwise and as updated on or before the date of this
Agreement is true and accurate in all respects as on the date of this
Agreement;

(f) the execution, delivery and performance of this Agreement will not conflict
with, or result in the breach of, or constitute a default under, or accelerate
performance required by any of the terms of its memorandum and articles of
association or any Applicable Laws or any covenant, contract, agreement,
arrangement, understanding, decree or order to which it is a party or by
which it or any of its properties or assets is bound or affected;

(g) there are no actions, suits, proceedings, or investigations pending or, to its
knowledge, threatened against it at law or in equity before any court or before
any other judicial, quasi-judicial or other authority, the outcome of which may
result in the breach of this Agreement or which individually or in the
aggregate may result in any material impairment of its ability to perform any
of its obligations under this Agreement;

(h) it has no knowledge of any violation or default with respect to any order, writ,
injunction or decree of any court or any legally binding order of any
Government Instrumentality which may result in any material adverse effect
on its ability to perform its obligations under this Agreement and no fact or

28
 circumstance exists which may give rise to such proceedings that would
adversely affect the performance of its obligations under this Agreement;

(i) it has complied with Applicable Laws in all material respects and has not been
subject to any fines, penalties, injunctive relief or any other civil or criminal
liabilities which in the aggregate have or may have a material adverse effect
on its ability to perform its obligations under this Agreement;

(j) no representation or warranty by it contained herein or in any other

document furnished by it to the Authority or to any Government
Instrumentality in relation to Applicable Permits contains or will contain any
untrue or misleading statement of material fact or omits or will omit to state a
material fact necessary to make such representation or warranty not
misleading;

(k) no sums, in cash or kind, have been paid or will be paid, by it or on its behalf,
to any person by way of fees, commission or otherwise for securing the
contract or entering into this Agreement or for influencing or attempting to
influence any officer or employee of the Authority in connection therewith;

(l) nothing contained in this Agreement shall create any contractual relationship
or obligation between the Authority and any Sub- contractors, designers,
consultants or agents of the Contractor;

(m) it is adequately financed has the requisite knowledge, expertise, technical

know-how, experience, resources, infrastructure, licenses, patents, copy
rights, for designing, supplying/ procuring the goods and materials, and for
providing the installation and construction services required for completing
the construction of the Project Facilities; and

(ii) it represents the Authority that:

(a) it owns or has the right to use all “Intellectual Property” necessary to perform
the contractual obligations and to carry on the Works without conflict with
the right of others;

(b) All intellectual property rights necessary to perform the contractual

obligations and to carry on the Works are in full force and effect and are
vested in, and beneficially owned by the Contractor, and are free from
encumbrances.

(c) None of the intellectual property rights is being used, claimed, or posed or
attacked by any other person, nor does the use of such intellectual property
rights or any part of them infringe the intellectual property rights owned or
enjoyed by any third party.

(d) None of the intellectual property rights owned or used by the Contractor is the
subject of any claim, opposition, attack, assertion or other arrangement of
whatsoever nature which does or may impinge upon their use, validity,
enforceability or ownership by the Parties, and there are no grounds or other
circumstances which may give rise to the same.

29
 (e) No licenses or registered user or other rights have been granted or agreed to
be granted to any third party in respect of such intellectual property rights.

(f) No act has been done or has been omitted to be done to entitle any authority
or person to cancel, forfeit or modify any intellectual property rights.

(g) The Contractor shall notify the Authority of any adverse use of the intellectual
property rights or confusingly or deceptively similar to the intellectual
property rights.

(h) The Contractor shall recognize the Authority’s ownership and title to the
intellectual property rights and shall not at any time, either directly or
indirectly, put to issue the validity or ownership of the intellectual property
rights and it will not do any act or thing, either directly or indirectly, which in
anyway impairs the validity and ownership of the intellectual property rights.

(i) The Contractor shall, promptly execute, acknowledge and deliver all
documents which are requested by Authority to record with appropriate
governmental agencies and authorities the fact that the Authority has the right
to the use of the said intellectual property rights.

(j) The Contractor shall not, for any reason, object to, or interfere in any way with
the ownership, registration or use of the intellectual property rights by the
Authority (or its licensee or assigns) for any purpose whatsoever.

(iii) The Contractor is fully aware that the Agreement is inter linked with the other Project
contracts and the non-performance or deficient performance or default by the
Contractor and/or any of the Contractor’s personnel or Subcontractors under one
among the said contracts will have bearing on the other contracts and the evaluation
of the Contractor’s performance under the Agreement and the Project itself.

(iv) If at any time during the Defects Liability Period any item of the Works or Project
Facilities or any part thereof, do not conform to the Authority requirements and
Specifications and Standards, on being so notified by the Authority, the Contractor
shall promptly rectify/remedy such nonconformity to the satisfaction of the Authority
solely at the Contractor's expense; failing which the Authority may reject or revoke
Taking-Over Certificate, and the Authority may proceed to correct the Contractor's
nonconforming Work by the most expeditious means available, the costs of which
shall be to the Contractor's account; or the Authority may retain the non-conforming
Work and an equitable adjustment reducing the total Contract Price to reflect the
diminished value of such non-conforming Work will be made by written amendment.

(v) In addition to the other warranties, the Contractor represents and warrants as
follows:

(a) The Contractor has (or, if the technology does not currently exist, will have
granted at the time of passing to The Employer) in and to the technology used
in the equipment, materials, goods, Works, Contractor's documents, Drawings
and Manuals (“Technology") -
i. all right, title and interest free of any lien, claim or restriction; and

30
 ii. right to grant to the Authority the right to use the Technology for the
purpose of this contract, free of any lien, claim or restriction and on the
terms of license as required.

(b) The Contractor has granted (or, if the technology does not currently exist, will
grant at the time of passing to the Authority the property and title in and to
the equipment, materials, goods, Works, spares, Contractor's documents,
Drawings and Manuals in which it is used) to the Authority the right to use the
Technology, free of any lien, claim or restriction.

(vi) In addition to the other Warranties, the Contractor represents and warrants as
follows:

(a) No Technology contains any worm (i.e., a program that travels from one
computer to another computer but does not attach itself to the operating
system of the computer it enters), virus (i.e., a program that travels from one
computer to another computer that attaches itself to the operating system it
enters) or self-destruct capability.

(b) The Technology will not abnormally end or provide invalid or incorrect
results as a result of date-dependent data.

(c) The Technology can accurately recognize, manage, accommodate, and

manipulate date-dependent data, including single and multi-century formulas
and leap years.

(vii) No criminal proceedings instituted against any of the employees or Directors of the
Contractor.

(viii) Till date the services of the Contractor has not been terminated by any person for any
breach or non-performance or negligence by the Contractor.

5.2 Representations and warranties of the Authority

The Authority represents and warrants to the Contractor that:

(a) it has full power and authority to execute, deliver and perform its obligations
under this Agreement and to carry out the transactions contemplated herein
and that it has taken all actions necessary to execute this Agreement, exercise
its rights and perform its obligations, under this Agreement;

(b) it has taken all necessary actions under the Applicable Laws to authorise the
execution, delivery and performance of this Agreement;

(c) it has the financial standing and capacity to perform its obligations under this
Agreement;

(d) this Agreement constitutes a legal, valid and binding obligation enforceable
against it in accordance with the terms hereof;

(e) it has no knowledge of any violation or default with respect to any order, writ,
injunction or any decree of any court or any legally binding order of any

31
 Government Instrumentality which may result in any material adverse effect
on the Authority’s ability to perform its obligations under this Agreement;
(f) it has complied with Applicable Laws in all material respects;

(g) it has good and valid right to the Site and has the power and authority to grant
the Right of Way in respect thereof to the Contractor; and

(h) it has procured Right of Way and environment clearances such that the
Contractor can commence construction forthwith on 90% (ninety per cent) of
the total length of the Project Highway.

5.3 Disclosure

In the event that any occurrence or circumstance comes to the attention of either
Party that renders any of its aforesaid representations or warranties untrue or
incorrect, such Party shall immediately notify the other Party of the same. Such
notification shall not have the effect of remedying any breach of the representation or
warranty that has been found to be untrue or incorrect nor shall it adversely affect or
waive any obligation of either Party under this Agreement.

32
 Article 6

Disclaimer

6.1 Disclaimer

(i) The Contractor acknowledges that prior to the execution of this Agreement, the
Contractor has, after a complete and careful examination, made an independent
evaluation of the Request for Proposal, Scope of the Project, Specifications and
Standards of design, construction and maintenance, Site, local conditions, physical
qualities of ground, subsoil and geology, traffic volumes, suitability and availability of
access routes to the Site and all information provided by the Authority or obtained,
procured or gathered otherwise, and has determined to its satisfaction the accuracy
or otherwise thereof and the nature and extent of difficulties, risks and hazards as are
likely to arise or may be faced by it in the course of performance of its obligations
hereunder. Save as provided in Clause 3.1 and Clause 5.2, the Authority makes no
representation whatsoever, express, implicit or otherwise, regarding the accuracy,
adequacy, correctness, reliability and/or completeness of any assessment,
assumptions, statement or information provided by it and the Contractor confirms
that it shall have no claim whatsoever against the Authority in this regard.

(ii) The Contractor acknowledges and hereby accepts to have satisfied itself as to the
correctness and sufficiency of the Contract Price.

(iii) The Contractor acknowledges and hereby accepts the risk of inadequacy, mistake or
error in or relating to any of the matters set forth in Clause 6.1 (i) above and hereby
acknowledges and agrees that the Authority shall not be liable for the same in any
manner whatsoever to the Contractor, or any person claiming through or under any of
them, and shall not lead to any adjustment of Contract Price or Scheduled Completion
Date.

(iv) The Parties agree that any mistake or error in or relating to any of the matters set
forth in Clause 6.1 (i) above shall not vitiate this Agreement, or render it voidable.

(v) In the event that either Party becomes aware of any mistake or error relating to any
of the matters set forth in Clause 6.1 (i) above, that Party shall immediately notify the
other Party, specifying the mistake or error.

(vi) Except as otherwise provided in this Agreement, all risks relating to the Project shall
be borne by the Contractor; and the Authority shall not be liable in any manner for
such risks or the consequences thereof.

33
 Part III

Construction and Maintenance

34
 Article 7

Performance Security

7.1 Performance Security

(i) (A) Within 30 (thirty) days of receipt of Letter of Acceptance, the selected Bidder shall
furnish to the Authority in the form of Insurance Surety Bond in the set forth in AnnexIII
of Schedule-G, Account Payee Demand Draft Banker’s Cheque or irrevocable and
unconditional e-Bank Guranteefrom a Bank in the form set forth in Annex-I of Schedule-
G (the “Performance Security”) for an amount equal to 3% (Three percent) of its Bid
Price. In case of bids mentioned below, the Selected Bidder, along with the Performance
Security, shall also furnish to the Authority in the form of Insurance Surety Bond (in same
form given at AnnexIII of Schedule-G ), Account Payee Demand Draft Banker’s
Cheque or irrevocable and unconditional e-Bank Guranteefrom a Bank in the same
given atAnnex-I Schedule-G towards an Additional Performance Security (the “Additional
Performance Security”) for an amount calculated asunder:
(i) If the Bid Price offered by the Selected Bidder is lower than 20% of the estimated
project cost/cost put to tender, the Additional Performance Security shall be calculated
@20% of the difference in the (i) Estimated Project Cost (as mentioned in RFP)-20%
of the Estimated Project Cost and (ii) the Bid Price offered by the selectedBidder.

(ii) Maximum limit of additional performance security shall be limited to 3% of the Bid
price offered by the selected bidder.

(iii) This Additional Performance Security shall be treated as part of the Performance
Security.

(B) The Performance Security shall be valid until 60(sixty) days after the Defects
Liability Period. The Additional Performance Security shall be valid until 28 (twenty
eight) days after Project Completion Date.

(ii) The Selected Bidder has the option to provide 50% of the Performance Security and 50%
of the Additional Performance Security, if any, within 30 (thirty) days of receipt of Letter
of Acceptance, in any case before signing of the Contract Agreement and the remaining
Performance Security and Additional Performance
Security,ifany,shallbesubmittedwithin30daysofsigningoftheagreement.

(iii) In the event the Selected Bidder fails to provide the remaining Performance Security and
Additional Performance Security, if any, as prescribed herein, it may seek extension of
time for a further period upto 60 days by paying the Damages upfront along with the
request letter seeking the extension. The Damages shall be the sum calculated at the rate of
0.01% (zero point zero one per cent) of the Bid Price offered by the Selected Bidder for
each day until the Performance Security and Additional Performance Security, if any, is
provided in full as prescribed herein. The damages at full rate as given above shall be
applicable even if a part of the Performance Security and the Additional Performance
Security isprovided.

35
(iv) For avoidance of any doubt, in case of failure of submission of Performance Security and
Additional Performance Security, if any, within the additional 60 days’ time period, the
award shall be deemed to be cancelled/ withdrawn and the Bid Security shall be encashed
and the proceeds thereof appropriated by the Authority.Thereupon all rights, privileges,
claims and entitlements of the Contractor under or arising out of the Award shall be
deemed to have been waived by, and to have ceased with the concurrence of the
Contractor, and the Award shall be deemed to have been withdrawn by theAuthority

7.2 Extension of Performance Security and Additional Performance Security

The Contractor may initially provide the Performance Security for a period of 2 (two)
years; provided that it shall procure the extension of the validity of the Performance
Security, as necessary, at least 2 (two) months prior to the date of expiry thereof.
Upon the Contractor providing an extended Performance Security, the previous
Performance Security shall be deemed to be released and the Authority shall return
the same to the Contractor within a period of 7 (seven) business days from the date of
submission of the extended Performance Security.

7.3 Appropriation of Performance Security

(i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its
other rights and remedies hereunder or in law, be entitled to encash and appropriate
the relevant amounts from the Performance Security as Damages for such
Contractor’s Default.

(ii) Upon such encashment and appropriation from the Performance Security, the
Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial
appropriation, to its original level the Performance Security, and in case of
appropriation of the entire Performance Security provide a fresh Performance
Security, as the case may be, and the Contractor shall, within the time so granted,
replenish or furnish fresh Performance Security as aforesaid failing which the
Authority shall be entitled to terminate the Agreement in accordance with Article 23.
Upon replenishment or furnishing of a fresh Performance Security, as the case may be,
as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30
(thirty) days for remedying the Contractor’s Default, and in the event of the
Contractor not curing its default within such Cure Period, the Authority shall be
entitled to encash and appropriate such Performance Security as Damages, and to
terminate this Agreement in accordance with Article 23.

7.4 Release of Performance Security

(i) The Authority shall return the Performance Security to the Contractor within 60
(sixty) days of the expiry of the Maintenance Period or the Defects Liability Period,
whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties
agree that the Authority shall not be obliged to release the Performance Security until
all Defects identified during the Defects Liability Period have been rectified.

36
(ii) The Authority shall return the Additional Performance Security to the Contractor
within 28 (twenty eight) days from the date of issue of Completion Certificate under
Article 12 of this Agreement.

(iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any
delay in the return of Performance Security and Additional Performance Security, if
any, beyond the period prescribed above for the period of delay.

7.5 Retention Money10

(i) From every payment for Works due to the Contractor in accordance with the
provisions of Clause 19.5, the Authority shall deduct 6% (six per cent) thereof as
guarantee money for performance of the obligations of the Contractor during the
Construction Period (the “Retention Money”) subject to the condition that the
maximum amount of Retention Money shall not exceed 5% (five per cent) of the
Contract Price.

(ii) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its
other rights and remedies hereunder or in law, be entitled to appropriate the relevant
amounts from the Retention Money as Damages for such Contractor’s Default.

(iii) Within 15 (fifteen) days of the date of issue of the Completion Certificate, the
Authority shall refund the balance of Retention Money remaining with the Authority
after adjusting the amounts appropriated under the provisions of Clause 7.5 (ii).

(iv) The Parties agree that in the event of Termination of this Agreement, the Retention
Money specified in this Clause 7.5 shall be treated as if they are Performance Security
and shall be reckoned as such for the purposes of Termination Payment under Clause
23.6.

10 The Authority may, in its discretion, omit Clause 7.5 and in lieu thereof increase the Performance
Security under Clause 7.1 from 7.5% (seven point five per cent) to 10% (ten per cent).

37
 Article 8
Right of Way

8.1 The Site

The site of the Project Highway (the “Site”) shall comprise the site described in
Schedule-A in respect of which the Right of Way shall be provided by the Authority to
the Contractor. The Authority shall be responsible for:

(a) acquiring and providing Right of Way on the Site in accordance with the
alignment finalized by the Authority, free from all encroachments and
encumbrances, and free access thereto for the execution of this Agreement;
and

(b) obtaininglicenses and permits for environment clearance for the Project
Highway.

8.2 Procurement of the Site

(i) The Authority Representative, the Contractor and Authority’s Engineer shall, within
10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed
memorandum containing an inventory of the Site including the vacant and
unencumbered land, buildings, structures, road works, trees and any other
immovable property on or attached to the Site (hereinafter referred to as the
“Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover
Memorandum shall have appended thereto an appendix (the “Appendix”) specifying
in reasonable detail those parts of the Site to which vacant access and Right of Way
has not been given to the Contractor along with details of hindrances in the
Construction Zone. For sake of clarity the Handover Memorandum shall clearly
specify the parts of Site where work can be executed. Signing of the Handover
Memorandum, in three counterparts (each of which shall constitute an original), by
the authorized representatives of the Authority, Contractor and Authority’s Engineer
shall be deemed to constitute a valid evidence of giving the Right of Way to the
Contractor for discharging its obligations under and in accordance with the
provisions of this Agreement and for no other purpose whatsoever.

(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in
the Appendix, it shall inform the Contractor, by notice, of the proposed date and time
such of hand over. The Authority Representative and the Contractor shall, on the date
so notified, inspect the specified parts of the Site, and prepare a memorandum
containing an inventory of the vacant and unencumbered land, buildings, structures,
road works, trees and any other immovable property on or attached to the Site so
handed over. The signing of the memorandum, in three (3) counterparts (each of
which shall constitute an original), by the authorized representatives of the Parties
shall be deemed to constitute a valid evidence of giving the relevant Right of Way to
the Contractor.

38
 If the contractor fails to join for site inspection or disputes the parts of the site
available for work, the Authority’s Engineer shall decide the parts of the site where
work can be executed and notify to both the parties within 3 days of the proposed
date of inspection. The parties agree that such notification of the Authority’s Engineer
as mentioned hereinabove shall be final and binding on the parties.

(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land
included in the Appendix by the date specified in Schedule-A for those parts of the Site
referred to therein, and in the event of delay for any reason other than Force Majeure
or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages
in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall
not be entitled to claim any other damages on account of any such delay by the
Authority.

(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority
shall specify the parts of the Site, if any, for which Right of Way shall be provided to
the Contractor on the dates specified in Schedule-A. Such parts shall also be included
in the Appendix prepared in pursuance of Clause 8.2 (i).

(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it
shall have procured issuance of the statutory notification under Applicable Laws for
vesting of all the land comprising the Project in the Authority and has taken
possession of area for Construction Zone for at least 90% (ninety per cent) of the total
length of the Project Highway. The Parties also acknowledge and agree that the
conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either
Party.

(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no
event contain sections of the Project Highway the cumulative length of which exceeds
10% (ten percent) of the total length of the Project Highway.

(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall
submit to the Authority’s Engineer, a monthly land possession report till expiry of 180
(one hundred and eighty) days from Appointed Date, in respect of those parts of the
site to which vacant access and right of way was not given to the contractor and
included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying
the part of the site, if any, for which the right of way is yet to be handed over.

8.3 Damages for delay in handing over the Site

(i) In the event the Right of Way to any part of the Site is not provided by the Authority
on or before the date(s) specified in Clause 8.2 for any reason other than Force
Majeure or breach of this Agreement by the Contractor, the Authority shall pay
Damages to the Contractor a sum calculated in accordance with the following formula
for and in respect of those parts of the Site to which the Right of Way has not been
provided:

39
 Where,

C = the Contract Price;

L = length of the Project Highway in metres; and

N = Completion period in days (Appointed Date to Scheduled Completion Date)

In the event that any Damages are due and payable to the Contractor under the
provisions of this Clause 8.3 (i) for delay in providing the Right of Way, the Contractor
shall, subject to the provisions of Clause 10.5, be entitled to Time Extension equal to
the period for which the Damages have become due and payable under this Clause 8.3
(i), save and except that:

(a) if any delays involve time overlaps,

overlaps, the overlaps shall not be additive; and

(b) such Time Extension shall be restricted only to the Works which are affected
by the delay in providing the Right of Way.

For the avoidance of doubt, the Parties expressly agree that the Damages specified
hereunder and the Time Extension specified in Clause 10.5 shall be restricted only to
failure of the Authority to provide the Right of Way for and in respect of the
“Construction Zone” which shall comprise the following components:

Main in carriageway

dian (for 4 lane carriageway or more)

Median
Paved and earthen shoulders
Area for Structures including ROBs/RUBs.
Safety measures including Roadside Drains and Furniture.
A parallel working space for accommodating slopes/retaining structures etc.

(ii) Notwithstanding anything to the contrary contained in this Agreement, the Contractor
expressly agrees that Works on all parts of the Site for which Right of Way of
Construction Zone is granted on the Appointed Date, or with respect to the parts of
the Site provided in Schedule-A,
Schedule A, no later than the date(s) specified therein, as the case
may be, shall be completed before the Scheduled Completion Date and shall not
qualify for any Time Extension under the provisions of Clause 8.3 (iii).

(iii) (a) Notwithstanding anything

anything to the contrary contained in this Agreement, unless
covered under the deemed de-scoping
de in terms of sub-clause
clause 8.3 (iii) (b), the
Authority may at any time withdraw any Works forming part of this Agreement,
subject to such Works not exceeding an aggregate
aggregate value, such value to be determined
in accordance with Schedule-H,
Schedule H, equal to 10 (ten) percent of the Contract Price.

40
 (b) Provided that if any Works cannot be undertaken within the municipal limits
of a town or within any area falling in a reserved forest or wildlife sanctuary or the
stretches where vacant access and Right of Way could not be handed over, as the case
may be, because the requisite clearances or approvals or affected land parcels for
commencing construction of Works therein have not been given within 180 (one
hundred and eighty) days of the Appointed date, the affected Works shall be deemed
to be withdrawn under the provisions of this Clause 8.3.3. Such Works shall not be
computed for the purposes of the aforesaid ceiling of 10% (ten per cent) hereunder.
(c) Provided further that in case such stretches (as mentioned in Sub-Clause (b)
above) can be handed over to the Contractor before the expiry of the original
Scheduled Construction Period of the Project Highway, and the Contractor agrees to
take up the work, the same may be allowed to be executed by him with corresponding
Extension of Time, subject to the condition that the Contractor shall not be entitled to
raise any claims on account of prolongation costs in this behalf.
(iv) In the event of withdrawal of Works under Clause 8.3 (iii) (a), the Contract Price shall
be reduced by an amount equal to the percent of the value of the works withdrawn as
mentioned in the Table below and the Contractor shall not be entitled to any other
compensation or Damages for the withdrawal of Works.

Value of the works Percentage of value of works to be reduced from

withdrawn Contract Price
Upto Rs 100 Crore 90%
More than Rs. 100 Crore Rs. 90 Crore plus 95% of the amount greater than Rs. 100
Crore

Provided that if any Works are withdrawn after commencement of the Construction
of such works, the Authority shall pay to the Contractor 110% (one hundred and ten
per cent) of the fair value of the work done, as assessed by the Authority’ Engineer.

The parties expressly agree that the value of the Works withdrawn shall be
determined from the details available in Schedule-H. In the event that it is impossible
to determine the value from Schedule-H, then the value shall be determined in
accordance with the provisions of Clause 13.2 (iii).

8.4 Site to be free from Encumbrances

Subject to the provisions of Clause 8.2, the Site shall be made available by the
Authority to the Contractor pursuant hereto free from all Encumbrances and
occupations and without the Contractor being required to make any payment to the
Authority because of any costs, compensation, expenses and charges for the
acquisition and use of such Site for the duration of the Project Completion Schedule.
For the avoidance of doubt, it is agreed that the existing rights of way, easements,
privileges, liberties and appurtenances to the Site shall not be deemed to be
Encumbrances. It is further agreed that, unless otherwise specified in this Agreement,
the Contractor accepts and undertakes to bear any and all risks arising out of the
inadequacy or physical condition of the Site.

8.5 Protection of Site from encroachments

On and after signing the memorandum and/or subsequent memorandum referred to

in Clause 8.2, and until the issue of the Completion Certificate, the Contractor shall
maintain a round-the-clock vigil over the Site and shall ensure and procure that no
41
encroachment takes place thereon. During the Construction Period, the Contractor shall protect
the Site from any and all occupations, encroachments or Encumbrances, and shall not place or
create nor permit any Sub-contractor or other person claiming through or under the Agreement
to place or create any Encumbrance or security threat over all or any part of the Site or the
Project Assets, or on any rights of the Contractor therein or under this Agreement, save and
except as otherwise expressly set forth in this Agreement. In the event of any encroachment or
occupation on any part of the Site, the Contractor shall report such encroachment or occupation
forthwith to the Authority and undertake its removal at its own cost and expenses.

8.6 Special/ temporary Right of Way

The Contractor shall bear all costs and charges for any special or temporary right of
way required by it in connection with access to the Site. The Contractor shall obtain at
its cost such facilities on or outside the Site as may be required by it for the purposes
of the Project Highway and the performance of its obligations under this Agreement.

8.7 Access to the Authority and the Authority’s Engineer

(i) The Right of Way given to the Contractor hereunder shall always be subject to the
right of access of the Authority and the Authority’s Engineer and their employees and
agents for inspection, viewing and exercise of their rights and performance of their
obligations under this Agreement.

(ii) The Contractor shall ensure, subject to all relevant safety procedures, that the
Authority has un-restricted access to the Site during any emergency situation, as
decided by the Authority’s Engineer.

8.8 Geological and archaeological finds

It is expressly agreed that mining, geological or archaeological rights do not form part
of this Agreement with the Contractor for the Works, and the Contractor hereby
acknowledges that it shall not have any mining rights or interest in the underlying
minerals, fossils, antiquities, structures or other remnants or things either of
particular geological or archaeological interest and that such rights, interest and
property on or under the Site shall vest in and belong to the Authority or the
concerned Government Instrumentality. The Contractor shall take all reasonable
precautions to prevent its workmen or any other person from removing or damaging
such interest or property and shall inform the Authority forthwith of the discovery
thereof and comply with such instructions as the concerned Government
Instrumentality may reasonably give for the removal of such property. For the
avoidance of doubt, it is agreed that any reasonable expenses incurred by the
Contractor hereunder shall be reimbursed by the Authority. It is also agreed that the
Authority shall procure that the instructions hereunder are issued by the concerned
Government Instrumentality within a reasonable period.

42
 Article 9

Utilities and Trees

9.1 Existing utilities and roads

Notwithstanding anything to the contrary contained herein, it shall be the

responsibility of the Contractor to ensure that the respective entities owning the
existing roads, right of way, level crossings, structures, or utilities on, under or above
the Site are enabled by it to keep them in continuous satisfactory use, if necessary, by
providing suitable temporary diversions with the authority of the controlling body of
that road, right of way or utility.

9.2 Shifting of obstructing utilities

The Contractor shall, subject to Applicable Laws and with assistance of the Authority,
undertake the work of shifting of any utility (including electric lines, water pipes, gas
pipelines and telephone cables) to an appropriate location or alignment, if such utility
or obstruction adversely affects the execution of Works or Maintenance of the Project
Highway in accordance with this Agreement, as per scope given in Schedule B and in
accordance with applicable standards and specifications of concerned utility owning
entity. The cost of shifting of such utilities indicated in Schedule B is payable to the
Contractor as per Schedule H. Cost of shifting utilities not included in the Schedule B,
if any, shall be treated as Change of Scope. The Authority will provide assistance to the
Contractor for obtaining the estimates for shifting of such utilities from the entity
owning such electric lines, water pipes or telephone cable, as the case may be. The
Contractor shall execute such utility shifting works under owning agency and
Authority Engineer (AE) in accordance with the provision of agreement. The
supervision charges only shall be paid by the Authority to the Utilities Owning Entity.
In the event of any delay in shifting thereof, the Contractor shall be responsible for
failure to perform any of its obligations here under if such failure is not as a direct
consequence of delay on the part of the entity owning such electric lines, water pipes
or telephone cables, as the case may be.
The dismantled material/scrap of existing Utility to be shifted dismantled shall belong
to the Contractor who would be free to dispose-off the dismantled materials as
deemed fit by them.
The work of shifting of Utilities can be taken up by the Contractor any time after
signing of the Agreement.

9.3 New utilities

(i) The Contractor shall allow, subject to the permission from the Authority and such
conditions as the Authority may specify, access to, and use of the Site for laying
telephone lines, water pipes, electricity lines/ cables or other public utilities. Where
such access or use causes any financial loss to the Contractor, it may require the user
of the Site to pay compensation or damages as per Applicable Laws. For the avoidance
of doubt, it is agreed that use of the Site under this Clause 9.3 shall not in any manner
relieve the Contractor of its obligation to construct and maintain the Project Highway
in accordance with this Agreement and any damage caused by such use shall be
restored forthwith at the cost of the Authority.
43
(ii) The Authority may, by notice, require the Contractor to connect any adjoining road to
the Project Highway, and the connecting portion thereof falling within the Site shall
be constructed by the Contractor at the Authority’s cost in accordance with Article 10.

(iii) The Authority may by notice require the Contractor to connect, through a paved road,
any adjoining service station, hotel, motel or any other public facility or amenity to
the Project Highway, whereupon the connecting portion thereof that falls within the
Site shall be constructed by the Contractor on payment of the cost. The cost to be paid
by the Authority to the Contractor shall be determined by the Authority’s Engineer.
For the avoidance of doubt, in the event such road is to be constructed for the benefit
of any entity, the Authority may require such entity to make an advance deposit with
the Contractor or the Authority, as the case may be, of an amount equal to the
estimated cost as determined by the Authority’s Engineer and such advance shall be
adjusted against the cost of construction as determined by the Authority’s Engineer
hereunder.

(iv) In the event construction of any Works is affected by a new utility or works
undertaken in accordance with this Clause 9.3, the Contractor shall be entitled to a
reasonable Time Extension as determined by the Authority’s Engineer.

9.4 Felling of trees

The Authority shall assist the Contractor in obtaining the Applicable Permits for
felling of trees in non-forest area to be identified by the Authority for this purpose if,
and only if, such trees cause a Material Adverse Effect on the construction or
maintenance of the Project Highway. The Contractor shall fell these trees as per the
Permits obtained. The cost of such felling shall be borne by the Authority and in the
event of any delay in felling thereof for reasons beyond the control of the Contractor;
it shall be excused for failure to perform any of its obligations hereunder if such
failure is a direct consequence of delay in the felling of trees. The Parties hereto agree
that the felled trees shall be deemed to be owned by the Authority and shall be
disposed in such manner and subject to such conditions as the Authority may in its
sole discretion deem appropriate. For the avoidance of doubt, the Parties agree that if
any felling of trees hereunder is in a forest area, the Applicable Permit thereof shall be
procured by the Authority within the time specified in the Agreement.

9.5 Dismantling of structures

The Contractor shall at its own cost dismantle the structures in the acquired lands
including those on patta lands, abadi lands, assigned lands, etc. the compensation for
which, was paid by the Authority to the land owners and the lands were handed over
to the Contractor as per Schedule B-I. The Contractor shall, at its own cost, dispose of
the dismantled material in its sole discretion as deemed appropriate, while complying
with all environmental guidelines and regulations and clear the Site for undertaking
construction. In the event of any delay in dismantling of structures thereof for reasons
beyond the control of the Contractor, the Contractor shall be entitled to Damages in a
sum calculated in accordance with the formula specified in Clause 8.3 (i) for the
period of delay, and to the Time Extension in accordance with Clause 10.5 for and in
respect of the part(s) of the Works affected by such delay; provided that if the delays
involve any time overlaps, the overlaps shall not be additive.

44
9.6 Development Period

The Contractor may commence pre-construction activities like utility shifting,

boundary wall construction or any other activity assigned to the Contractor by the
Authority to enable construction of the Project Highway immediately after signing of
the Agreement, to the extent that such work is ready for execution. The Parties agree
that these works may be taken up and completed to the extent feasible by the
Contractor, before declaration of the Appointed Date, but no claim against the
Authority for delay shall survive during this period and that the undertaking of these
works by the Contractor shall not count towards the Scheduled Construction Period of
the project which starts counting only from the Appointed Date. No construction
activity of the Project Highway shall be undertaken during the development period.

45
 Article 10

Design and Construction of the Project Highway

10.1 Obligations prior to commencement of Works

(i) Within 20 (twenty) days of the Appointed Date, the Contractor shall:

(a) appoint its representative, duly authorised to deal with the Authority in
respect of all matters under or arising out of or relating to this Agreement;
(b) appoint a design director (the “Design Director”) who will head the
Contractor’s design unit and shall be responsible for surveys, investigations,
collection of data, and preparation of preliminary and detailed designs;

(c) undertake and perform all such acts, deeds and things as may be necessary or
required before commencement of Works under and in accordance with this
Agreement, the Applicable Laws and Applicable Permits; and

(d) make its own arrangements for quarrying of materials needed for the Project
Highway under and in accordance with the Applicable Laws and Applicable
Permits.

(ii) The Authority shall, appoint an engineer (the “Authority’s Engineer”) before the
Appointed Date to discharge the functions and duties specified in this Agreement, and
shall notify to the Contractor the name, address and the date of appointment of the
Authority’s Engineer forthwith.

(iii) Within 30 (thirty) days of the Appointed Date, the Contractor shall submit to the
Authority and the Authority’s Engineer a programme (the “Programme”) for the
Works, developed using networking techniques, for review and consent of the
Engineer, giving the following details:

(a) Part I : Contractor’s organization for the Project, the general methods and
arrangements for design and construction, environmental management plan,
Quality Assurance Plan including design quality plan, traffic management and
safety plan covering safety of users and workers during construction
(including use of ‘ROBOTS’ for diversion and control of traffic), Contractor’s
key personnel and equipment.

(b) Part II:Programme for completion of all stages of construction given in

Schedule-H and Project Milestones of the Works as specified in Project
Completion Schedule set forth in Schedule-J. The Programme shall include:

i. the order in which the Contractor intends to carry out the Works,
including the anticipated timing of design and stages of Works;
ii. the periods for reviews under Clause 10.2;

46
 iii. the sequence and timing of inspections and tests specified in this
Agreement; and

iv. the particulars for the pre-construction reviews and for any other
submissions, approvals and consents specified in the Agreement.

The Contractor shall submit a revised Programme whenever the previous Programme
is inconsistent with the actual progress or with the Contractor’s obligations.

(c) Part III: Monthly cash flow forecast.

(iv) The Contractor shall compute, on the basis of the Drawings prepared in accordance
with Clause 10.2 (iv), and provide to the Authority’s Engineer, the length, area and
numbers, as the case may be, in respect of the various items of work specified in
Schedule-H and comprising the Scope of the Project. The Parties expressly agree that
these details shall form the basis for estimating the interim payments for the Works in
accordance with the provisions of Clause 19.3. For the avoidance of doubt, the sum of
payments to be computed in respect of all the items of work shall not exceed the
Contract Price, as may be adjusted in accordance with the provisions of this
Agreement.

(v) The Contractor shall appoint a safety consultant (the “Safety Consultant”) to carry out
a safety audit at the design stage of the Project Highway in accordance with the
Applicable Laws and Good Industry Practice. The Safety Consultant shall be appointed
after proposing to the Authority a panel of three (3) names of qualified and
experienced firms from which the Authority may choose one (1) to be the Safety
Consultant. Provided, however, that if the panel is not acceptable to the Authority and
the reasons for the same are furnished to the Contractor, the Contractor shall propose
to the Authority a revised panel of three (3) names from the firms empanelled as
safety consultants by the [Ministry of Road Transport and Highways] for obtaining the
consent of the Authority. The Contractor shall also obtain the consent of the Authority
for the key personnel of the Safety Consultant who shall have adequate experience
and qualifications in safety audit of the highway projects. The Authority shall, within
15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its
decision, with reasons, to the Contractor, and if no such decision is conveyed within
the said period, the Contractor may proceed with engaging of the Safety Consultant.

(vi) The safety audit pursuant to Clause 10.1 (v) shall be carried out by the Safety
Consultant in respect of all such design details that have a bearing on safety of Users
as well as pedestrians and animals involved in or associated with accidents. The
recommendations of the Safety Consultant shall be incorporated in the design of the
Project Highway and the Contractor shall forward to the Authority’s Engineer a
certificate to this effect together with the recommendations of the Safety Consultant.
In the event that any works required by the Safety Consultant shall fall beyond the
scope of Schedule-B, Schedule-C or Schedule-D, the Contractor shall make a report
thereon and seek the instructions of the Authority for Change in Scope. For the

avoidance of doubt, the Safety Consultant to be engaged by the Contractor shall be

independent of the design and implementation team of the Contractor.

47
10.2 Design and Drawings

(i) Design and Drawings shall be developed in conformity with the Specifications and
Standards set forth in Schedule-D. In the event, the Contractor requires any relaxation
in design standards due to restricted Right of Way in any section, the alternative
design criteria for such section shall be provided for review and approval of the
Authority’s Engineer.

(ii) The Contractor shall appoint a proof check consultant (the “Proof Consultant”) after
proposing to the Authority a panel of three (3) names of qualified and experienced
firms from whom the Authority may choose one (1) to be the Proof Consultant.
Provided, however, that if the panel is not acceptable to the Authority and the reasons
for the same are furnished to the Contractor, the Contractor shall propose to the
Authority a revised panel of three (3) names from the firms empanelled as proof
consultants by the [Ministry of Road Transport and Highways] for obtaining the
consent of the Authority. The Contractor shall also obtain the consent of the Authority
for two (2) key personnel of the Proof Consultant who shall have adequate experience
and qualifications in highways and bridges respectively. The Authority shall, within
15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its
decision, with reasons, to the Contractor, and if no such decision is conveyed within
the said period, the Contractor may proceed with engaging of the Proof Consultant.

(iii) The Proof Consultant shall:

(a) evolve a systems approach with the Design Director so as to minimise the
time required for final designs and construction drawings; and

(b) proof check the detailed calculations, drawings and designs, which have been
approved by the Design Director.

(iv) In respect of the Contractor’s obligations with respect to the design and Drawings of
the Project Highway as set forth in Schedule-I, the following shall apply:

(a) The Contractor shall prepare and submit, with reasonable promptness and in
such sequence as is consistent with the Project Completion Schedule, three (3)
copies each of the design and Drawings, duly certified by the Proof Consultant,
to the Authority’s Engineer for its approval. Provided, however, that in respect
of Major Bridges and Structures, the Authority’s Engineer may require
additional drawings for approval in accordance with Good Industry Practice.

(b) by submitting the Drawings for review and approval to the Authority’s
Engineer, the Contractor shall be deemed to have represented that it has
determined and verified that the design and engineering, including field
construction criteria related thereto, are in conformity with the Scope of the
Project, the Specifications and Standards and the Applicable Laws;

48
 (c) within15 (fifteen) days of the receipt of the Drawings, the Authority’s
Engineer shall review the same and convey its approval/observations to the
Contractor with particular reference to their conformity or otherwise with the
Scope of the Project and the Specifications and Standards. Provided, however
that in case of a major bridge or structure, the aforesaid period of 15 (fifteen)
days may be extended up to 30 (thirty) days;

(d) if the aforesaid observations of the Authority’s Engineer indicate that the
Drawings are not in conformity with the Scope of the Project or the
Specifications and Standards, such Drawings shall be revised by the
Contractor in conformity with the provisions of this Agreement and
resubmitted to the Authority’s Engineer for review and approval. The
Authority’s Engineer shall give its observations, if any, within 10 (ten) days of
receipt of the revised Drawings. In the event the Contractor fails to revise and
resubmit such Drawings to the Authority’s Engineer for review/approval as
aforesaid, the Authority’s Engineer may withhold the payment for the affected
works in accordance with the provisions of Clause 19.5 (iv). If the Contractor
disputes any decision, direction or determination of the Authority’s Engineer
hereunder, the Dispute shall be resolved in accordance with the Dispute
Resolution Procedure;

(e) no review/approval and/or observation of the Authority’s Engineer and/or its

failure to review/approval and/or convey its observations on any Drawings
shall relieve the Contractor of its obligations and liabilities under this
Agreement in any manner nor shall the Authority’s Engineer or the Authority
be liable for the same in any manner; and if errors, omissions, ambiguities,
inconsistencies, inadequacies or other Defects are found in the Drawings, they
and the construction works shall be corrected at the Contractor's cost,
notwithstanding any approval under this Article 10;

(f) the Contractor shall be responsible for delays in submitting the Drawing as set
forth in Schedule-I caused by reason of delays in surveys and field
investigations, and shall not be entitled to seek any relief in that regard from
the Authority; and

(g) the Contractor warrants that its designers, including any third parties engaged
by it, shall have the required experience and capability in accordance with
Good Industry Practice and it shall indemnify the Authority against any
damage, expense, liability, loss or claim, which the Authority might incur,
sustain or be subject to arising from any breach of the Contractor’s design
responsibility and/or warranty set out in this Clause.

(h) the Contractor shall ensure that all the designs and drawings shall be
approved from the Authority’s Engineer within 90 days (ninety) from the
Appointed Date.

(v) Any cost or delay in construction arising from review/approval by the Authority’s
Engineer shall be borne by the Contractor.

49
(vi) Works shall be executed in accordance with the Drawings provided by the Contractor
in accordance with the provisions of this Clause 10.2 and the approval of the
Authority’s Engineer thereon as communicated pursuant to the provisions of sub-
Clause (c) & (d) of Clause 10.2 (iv). Such Drawings shall not be amended or altered
without prior written notice to the Authority’s Engineer. If a Party becomes aware of
an error or defect of a technical nature in the design or Drawings, that Party shall
promptly give notice to the other Party of such error or defect.

(vii) Within 90 (ninety) days of the Project Completion Date, the Contractor shall furnish to
the Authority and the Authority’s Engineer a complete set of as- built Drawings, in 2
(two) hard copies and in micro film form or in such other medium as may be
acceptable to the Authority, reflecting the Project Highway as actually designed,
engineered and constructed, including an as-built survey illustrating the layout of the
Project Highway and setback lines, if any, of the buildings and structures forming part
of Project Facilities.

10.3 Construction of the Project Highway

(i) The Contractor shall construct the Project Highway as specified in Schedule- B and
Schedule-C, and in conformity with the Specifications and Standards set forth in
Schedule-D. The Contractor shall be responsible for the correct positioning of all parts
of the Works, and shall rectify any error in the positions, levels, dimensions or
alignment of the Works. The 180th (One hundred and Eighty) day from the Appointed
Date shall be the scheduled completion date (the “Scheduled Completion Date”) and
the Contractor agrees and undertakes that the construction shall be completed on or
before the Scheduled Completion Date, including any extension thereof.

(ii) The Contractor shall construct the Project Highway in accordance with the Project
Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to
achieve any Project Milestone or the Scheduled Completion Date within a period of 30
(thirty) days from the date set forth in Schedule-J, unless such failure has occurred
due to Force Majeure or for reasons solely attributable to the Authority, it shall pay
Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero
(iii)
(iv) five percent) of the Contract Price for delay of each day reckoned from the date
specified in Schedule –J and until such Project Milestone is achieved or the Project
Highway is completed; provided that if the period for any or all Project Milestones or
the Scheduled Completion Date is extended in accordance with the provisions of this
Agreement, the dates set forth in Schedule-J shall be deemed to be modified
accordingly and the provisions of this Agreement shall apply as if Schedule-J has been
amended as above; provided further that in the event the Project Highway is
completed within or before the Scheduled Completion Date including any Time
Extension, applicable for that work or section, the Damages paid under this Clause
10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest
thereon.

50
 The Parties agree that for determining achievement or delays in completion of the
Project Milestones or the Project on the due date, the works affected due to delay in
providing the site for which time extension has been granted beyond the Scheduled
Completion Date will be excluded. For example on the due date to achieve the Project
Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one
hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project
length corresponding to the Project Milestone-I is not handed over or lately handed
over resulting in the extension of completion of this 5% (five percent) length beyond
Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be
achieved by 180th (one hundred and eighty) day.

For the avoidance of doubt, it is agreed that recovery of Damages under this Clause
10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement
including the right of Termination thereof. The Parties further agree that Time
Extension hereunder shall only be reckoned for and in respect of the affected Works
as specified in Clause 10.5 (ii).

(iii) The Authority shall notify the Contractor of its decision to impose Damages in
pursuance with the provisions of this Clause 10.3. Provided that no deduction on
account of Damages shall be effected by the Authority without notifying the
Contractor of its decision to impose the Damages, and taking into consideration the
representation, if any, made by the Contractor within 20 (twenty) days of such notice.
The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii)
shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10%
(ten percent) of the Contract Price, the Contractor shall be deemed to be in default of
this agreement having no cure and the Authority shall be entitled to terminate this
Agreement by issuing a Termination Notice in accordance with the provisions of
Clause 23.1 (ii).

(iv) In the event that the Contractor fails to achieve the Project Completion within a
period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J,
unless such failure has occurred due to Force Majeure or for reasons solely
attributable to the Authority, the contractor shall be deemed to be ineligible for
bidding any future projects of the Authority, both as the sole party or as one of the
parties of Joint Venture/ Consortium during the period from Scheduled Completion
Date to issuance of Completion Certificate. This restriction is applicable if the contract
value of the delayed project is not less than Rs. 300 crore.

10.4 Maintenance during Construction Period

(i) During the Construction Period, the Contractor shall maintain, at its cost, the existing
lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at
no time materially inferior for smooth vehicle movement & traffic safetyand shall
undertake the necessary repair and maintenance works for this purpose; provided
that the Contractor may, at its cost, interrupt and divert the flow of traffic if such
interruption and diversion is necessary for the efficient progress of Works and
conforms to Good Industry Practice; provided further that such interruption and

51
 diversion shall be undertaken by the Contractor only with the prior written approval
of the Authority’s Engineer which approval shall not be unreasonably withheld. For
the avoidance of doubt, it is agreed that the Contractor shall at all times be
responsible for ensuring safe operation of the Project Highway. It is further agreed
that in the event the Project includes construction of a bypass or tunnel and
realignment of the existing carriageway, the Contractor shall maintain the existing
highway in such sections until the new Works are open to traffic.

(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of
default by the Contractor in discharging the obligations specified in Clause 10.4 (i)
above, the Authority shall get these maintenance works completed in the manner
recommended by the Authority’s Engineer to avoid public inconvenience at the risk
and cost of the Contractor in order to keep the road in traffic worthy condition.

10.5 Extension of time for completion

(i) Without prejudice to any other provision of this Agreement for and in respect of
extension of time, the Contractor shall be entitled to extension of time in the Project
Completion Schedule (the “Time Extension”) to the extent that completion of any
Project Milestone is or will be delayed by any of the following, namely:

(a) delay in providing the Right of Way of Construction Zone, environmental

clearances or approval of railway authorities, specified in Clause 3.1 (iv);

(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has
been agreed under Article 13);
(c) occurrence of a Force Majeure Event;

(d) any delay, impediment or prevention caused by or attributable to the

Authority, the Authority's personnel or the Authority's other contractors on
the Site; and

(e) any other cause or delay which entitles the Contractor to Time Extension in
accordance with the provisions of this Agreement.

(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of
an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer
by notice in writing, with a copy to the Authority, stating in reasonable detail with
supporting particulars, the event or circumstances giving rise to the claim for Time
Extension in accordance with the provisions of this Agreement. Provided that the
period of 15 (fifteen) business days shall be calculated from the date on which the
Contractor became aware, or should have become aware, of the occurrence of such an
event or circumstance.

Provided further that notwithstanding anything to the contrary contained in this

Agreement, Time Extension shall be due and applicable only for the Works which are
affected by the aforesaid events or circumstances and shall not in any manner affect
the Project Completion Schedule for and in respect of the Works which are not
affected hereunder.

52
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in
accordance with the provisions of Clause 10.5 (ii) within the time specified therein,
the Contractor shall not be entitled to any Time Extension and shall forfeit its right for
any such claims in future. For the avoidance of doubt, in the event of failure of the
Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be
discharged from all liability in connection with the claim.

(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the
provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame
specified herein. In the event the Authority’s Engineer requires any clarifications to
examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen)
days from the date of receiving the claim. The Contractor shall, on receipt of the
communication of the Authority’s Engineer requesting for clarification, furnish the
same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s
Engineer shall, within a period of 30 (thirty) days from the date of receipt of such
clarifications, forward in writing to the Contractor its determination of Time
Extension.

Provided that when determining each extension of time under this Clause 10.5, the
Authority’s Engineer shall review previous determinations and may increase, but
shall not decrease, the total Time Extension.

(v) If the event or circumstance giving rise to the notice has a continuing effect:

(a) a fully detailed claim shall be considered as interim;

(b) the Contractor shall, no later than 10 (ten) days after the close of each month,
send further interim claims specifying the accumulated delay, the extension of
time claimed, and such further particulars as the Authority’s Engineer may
reasonably require; and

(c) the Contractor shall send a final claim within 30 (thirty) days after the effect
of the event or the circumstance ceases.

Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same
in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty)
days of the receipt thereof

10.6 Incomplete Works

In the event the Contractor fails to complete the Works in accordance with the Project
Completion Schedule, including any Time Extension granted under this Agreement,
the Contractor shall endeavour to complete the balance work expeditiously and shall
pay Damages to the Authority in accordance with the provisions of Clause 10.3 (ii) for
delay of each day until the Works are completed in accordance with the provisions of
this Agreement. Recovery of Damages under this Clause shall be without prejudice to
the rights of the Authority under this Agreement including the right to termination
under Clause 23.1.

53
10.7 Maintenance Manual

No later than 60 (sixty) days prior to the Project Completion Date, the Contractor
shall, in consultation with the Authority’s Engineer, evolve a maintenance manual (the
“Maintenance Manual”) for the regular and preventive maintenance of the Project
Highway in conformity with the Specifications and Standards, safety requirements
and Good Industry Practice, and shall provide 5 (five) copies thereof to the Authority’s
Engineer. The Authority’s Engineer shall review the Maintenance Manual within 15
(fifteen) days of its receipt and communicate its comments to the Contractor for
necessary modifications, if any.

10.8 As-Built Records

The Contractor shall prepare, and keep up-to-date, a complete set of as built records
of the execution of the Works, showing the exact as built locations, sizes and details
on the Works as executed with cross references to all relevant specifications and data
sheets. These records shall be kept on the Site and shall be used exclusively for the
purpose of this Sub-Clause 10.8. The Contractor shall provide 2 (two) copies of as
built records to the Authority prior to the commencement of the Tests on Completion.

10.9 Contractor's Use of Authority’s Documents

Intellectual property in the Authority’s requirements and Specifications and

Standards and all other documents and materials issued by the Authority or the
Authority’s Representative to the Contractor shall (as between the parties) remain the
property of the Authority. The Contractor may, at its cost, copy, use and communicate
any such documents for the purposes of the Contract. They shall not, without the
consent of the Authority, be used, copied or communicated to a third party by the
Contractor, except as necessary for the purposes of the Works under the Agreement.

54
 Article 11

Quality Assurance, Monitoring and Supervision

11.1 Quality of Materials and workmanship

The Contractor shall ensure that the Construction, Materials and workmanship are in
accordance with the requirements specified in this Agreement, Specifications and
Standards and Good Industry Practice.

11.2 Quality control system

(i) The Contractor shall establish a quality control mechanism to ensure compliance with
the provisions of this Agreement (the “Quality Assurance Plan” or “QAP”).

(ii) The Contractor shall, within 30 (thirty) days of the Appointed Date, submit to the
Authority’s Engineer its Quality Assurance Plan which shall include the following:

(a) organization, duties and responsibilities, procedures, inspections and

documentation;

(b) quality control mechanism including sampling and testing of Materials, test
frequencies, standards, acceptance criteria, testing facilities, reporting,
recording and interpretation of test results, approvals, check list for site
activities, and proforma for testing and calibration in accordance with the
Specifications for Road and Bridge Works issued by MORTH, relevant IRC
specifications and Good Industry Practice; and
(c) internal quality audit system.

The Authority’s Engineer shall convey its approval to the Contractor within a period
of 21 (twenty-one) days of receipt of the QAP stating the modifications, if any,
required, and the Contractor shall incorporate those in the QAP to the extent required
for conforming with the provisions of this Clause 11.2.

(iii) The Contractor shall procure all documents, apparatus and instruments, fuel,
consumables, water, electricity, labor, Materials, samples, and qualified personnel as
are necessary for examining and testing the Project Assets and workmanship in
accordance with the Quality Assurance Plan.

(iv) The cost of testing of Construction, Materials and workmanship under this Article 11
shall be borne by the Contractor.

11.3 Methodology

The Contractor shall, at least 15 (fifteen) days prior to the commencement of the
construction, submit to the Authority’s Engineer for review and consent the
methodology proposed to be adopted for executing the Works, giving details of
equipment to be deployed, traffic management and measures for ensuring safety. The
Authority’s Engineer shall complete the review and convey its consent to the

55
 Contractor within a period of 10 (ten) days from the date of receipt of the proposed
methodology from the Contractor.

11.4 Inspection and technical audit by the Authority

The Authority or any representative authorized by the Authority in this behalf may
inspect and review the progress and quality of the construction of Project Highway
and issue appropriate directions to the Authority’s Engineer and the Contractor for
taking remedial action in the event the Works are not in accordance with the
provisions of this Agreement.

11.5 External technical audit

(i) At any time during construction, the Authority may appoint an external technical
auditor to conduct an audit of the quality of the Works. The Auditor in the presence of
the representatives of the Contractor and the Authority’s Engineer shall carry out the
tests and/ or collect samples for testing in the laboratory. The timing, the testing
equipment and the sample size of this audit shall be as decided by the Authority. The
findings of the audit, to the extent accepted by the Authority, shall be notified to the
Contractor and the Authority’s Engineer for taking remedial action in accordance with
this Agreement.

(ii) After completion of the remedial measures by the Contractor, the Auditor shall
undertake a closure audit and this process will continue till the remedial measures
have brought the works into compliance with the Specifications and Standards. The
Contractor shall provide all assistance as may be required by the auditor in the
conduct of its audit hereunder. Notwithstanding anything contained in this Clause
11.5, the external technical audit shall not affect any obligations of the Contractor or
the Authority’s Engineer under this Agreement.

11.6 Inspection of construction records

The Authority shall have the right to inspect the records of the Contractor relating to
the Works.

11.7 Monthly progress reports

During the Construction Period, the Contractor shall, no later than 10 (ten) days after
the close of each month, furnish to the Authority and the Authority’s Engineer a
monthly report on progress of the Works and shall promptly give such other relevant
information as may be required by the Authority’s Engineer.

The Contractor agrees that reporting under this Clause 11.7 shall continue until the
date of the completion of the Works. Each report shall include:

(a) an executive summary;

(b) charts showing the status of Contractor's documents, construction and

manufacturing and environmental works;

56
 (c) details of work subcontracted and the performance of Sub-contractors;

(d) for the construction of each main part of the Works, the extent of progress
(both quantity and percentage of the whole), the actual or expected dates of
commencement, anticipated completion date of the activity, Contractor's
inspections and tests;
(e) records of manpower and Contractor's equipment on the Site;

(f) copies for that month of quality assurance documents, test results and
certificates;

(g) safety statistics, accident data collection including details of any hazardous
incidents and activities relating to environmental aspects and public relations;

(h) comparisons of actual and planned progress, with details of any aspects which
may jeopardize the completion in accordance with the Agreement, and the
measures being (or to be) adopted to overcome such aspects;
(i) details of any unresolved disputes or claims, in relation to the Project;

(j) details of any revision to the cash flow estimate, together with a copy of the
revised cash flow estimate;
(k) status of various Applicable Permits and compliance of conditions therein;

(l) details of various royalty payment and insurances required to be taken by the
Contractor; and

(m) such other reports as may be required by the Authority for enabling the
Authority to comply with its obligations under the other Project contracts.
(n) details of defects by the Authority;

(o) change in emission of any sewage or effluent of any nature whatsoever,

whether qualitatively or quantitatively;
(p) any Material Adverse Effect;

(q) declaration towards compliance with Applicable Laws including but not
limited to environmental and labor legislations;

(r) declaration specifying compliance with all Manuals provided to the

Contractor; and
(s) any change in the flow of traffic in the existing Project Highway.

11.8 Inspection

(i) The Authority’s Engineer and its authorized representative shall at all reasonable
times:

(a) have full access to all parts of the Site and to all places from which natural
Materials are being obtained for use in the Works; and

57
 (b) during production, manufacture and construction at the Site and at the place
of production, be entitled to examine, inspect, measure and test the Materials
and workmanship, and to check the progress of manufacture of Materials.

(ii) The Contractor shall give the Authority’s Engineer and its authorized agents access,
facilities and safety equipment for carrying out their obligations under this
Agreement.

(iii) The Authority’s Engineer shall submit a monthly inspection report (the “Inspection
Report”) to the Authority and the Contractor bringing out the results of inspections
and the remedial action taken by the Contractor in respect of Defects or deficiencies.
For the avoidance of doubt, such inspection or submission of Inspection Report by the
Authority’s Engineer shall not relieve or absolve the Contractor of its obligations and
liabilities under this Agreement in any manner whatsoever.

11.9 Samples

The Contractor shall submit the following samples of Materials and relevant
information to the Authority’s Engineer for pre-construction review:

(a) manufacturer's test reports and standard samples of manufactured Materials;

and
(b) samples of such other Materials as the Authority’s Engineer may require.

11.10 Tests

(i) For determining that the Works conform to the Specifications and Standards, the
Authority’s Engineer shall require the Contractor to carry out or cause to be carried
out tests, at such time and frequency and in such manner as specified in this
Agreement and in accordance with Good Industry Practice for quality assurance. The
test checks by the Authority’s Engineer shall comprise at least 50% (fifty percent) of
the quantity or number of tests prescribed for each category or type of test for quality
control by the Contractor.

(ii) In the event that results of any tests conducted under this Clause 11.10 establish any
Defects or deficiencies in the Works, the Contractor shall carry out remedial measures
and furnish a report to the Authority’s Engineer in this behalf. The Authority’s
Engineer shall require the Contractor to carry out or cause to be carried out tests to
determine that such remedial measures have brought the Works into compliance with
the Specifications and Standards, and the procedure shall be repeated until such
Works conform to the Specifications and Standards. For the avoidance of doubt, the
cost of such tests and remedial measures in pursuance thereof shall be solely borne
by the Contractor.

11.11 Examination of work before covering up

In respect of the work which the Authority’s Engineer is entitled to examine, inspect,
measure and/or test before it is covered up or put out of view or any part of the work

58
 is placed thereon, the Contractor shall give notice to the Authority’s Engineer
whenever any such work is ready and before it is covered up. The Authority’s
Engineer shall then either carry out the examination, inspection or testing without
unreasonable delay, or promptly give notice to the Contractor that the Authority’s
Engineer does not require to do so. Provided, however, that if any work is of a
continuous nature where it is not possible or prudent to keep it uncovered or
incomplete, the Contractor shall notify the schedule of carrying out such work to give
sufficient opportunity, not being less than 3 (three) business days’ notice, to the
Authority’s Engineer to conduct its inspection, measurement or test while the work is
continuing. Provided further that in the event the Contractor receives no response
from the Authority’s Engineer within a period of 3 (three) business days from the date
on which the Contractor’s notice hereunder is delivered to the Authority’s Engineer,
the Contractor shall be entitled to assume that the Authority’s Engineer would not
undertake the said inspection.

11.12 Rejection

If, as a result of an examination, inspection, measurement or testing, any Plant,

Materials, design or workmanship is found to be defective or otherwise not in
accordance with the provisions of this Agreement, the Authority’s Engineer shall
reject the Plant, Materials, design or workmanship by giving notice to the Contractor,
with reasons. The Contractor shall then promptly make good the Defect and ensure
that the rejected item complies with the requirements of this Agreement.

If the Authority’s Engineer requires the Plant, Materials, design or workmanship to be

retested, the tests shall be repeated under the same terms and conditions, as
applicable in each case. If the rejection and retesting cause the Authority to incur any
additional costs, such cost shall be recoverable by the Authority from the Contractor;
and may be deducted by the Authority from any monies due to be paid to the
Contractor.

11.13 Remedial work

(i) Notwithstanding any previous test or certification, the Authority’s Engineer may
instruct the Contractor to:

(a) remove from the Site and replace any Plant or Materials which are not in
accordance with the provisions of this Agreement;

(b) remove and re-execute any work which is not in accordance with the
provisions of this Agreement and the Specification and Standards; and

(c) execute any work which is urgently required for the safety of the Project
Highway, whether because of an accident, unforeseeable event or otherwise;
provided that in case of any work required on account of a Force Majeure
Event, the provisions of Clause 21.6 shall apply.

(ii) If the Contractor fails to comply with the instructions issued by the Authority’s
Engineer under Clause 11.13 (i), within the time specified in the Authority’s

59
 Engineer’s notice or as mutually agreed, the Authority’s Engineer may advise the
Authority to have the work executed by another agency. The cost so incurred by the
Authority for undertaking such work shall, without prejudice to the rights of the
Authority to recover Damages in accordance with the provisions of this Agreement, be
recoverable from the Contractor and may be deducted by the Authority from any
monies due to be paid to the Contractor.

11.14 Delays during construction

Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor
does not achieve any of the Project Milestones or the Authority’s Engineer shall have
reasonably determined that the rate of progress of Works is such that Completion of
the Project Highway is not likely to be achieved by the end of the Scheduled
Completion Date, it shall notify the same to the Contractor, and the Contractor shall,
within 15 (fifteen) days of such notice, by a communication inform the Authority’s
Engineer in reasonable detail about the steps it proposes to take to expedite progress
and the period within which it shall achieve the Project Completion Date.

11.15 Quality control records and Documents

The Contractor shall hand over a copy of all its quality control records and documents
to the Authority’s Engineer before the Completion Certificate is issued pursuant to
Clause 12.2. The Contractor shall submit Road Signage Plans to the Authority
Engineer for approval at least 6 (six) months prior to expected completion of Project
Highway.

11.16 Video recording

During the Construction Period, the Contractor shall provide to the Authority for
every calendar quarter, a video recording, which will be compiled into a 3 (three)-
hour compact disc or digital video disc, as the case may be, covering the status and
progress of Works in that quarter. The video recording shall be provided to the
Authority no later than 15 (fifteen) days after the close of each quarter after the
Appointed Date.

11.17 Suspension of unsafe Construction Works

(i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by
notice require the Contractor to suspend forthwith the whole or any part of the Works
if, in the reasonable opinion of the Authority’s Engineer, such work threatens the
safety of the Users and pedestrians.

(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the
Works or any part thereof for such time and in such manner as may be specified by
the Authority and thereupon carry out remedial measures to secure the safety of
suspended works, the Users and pedestrians. The Contractor may by notice require
the Authority’s Engineer to inspect such remedial measures forthwith and make a
report to the Authority recommending whether or not the suspension hereunder may

60
 be revoked. Upon receiving the recommendations of the Authority’s Engineer, the
Authority shall either revoke such suspension or instruct the Contractor to carry out
such other and further remedial measures as may be necessary in the reasonable
opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be
repeated until the suspension hereunder is revoked.

(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining
and protecting the Works or part thereof during the period of suspension (the
“Preservation Costs”), shall be borne by the Contractor; provided that if the
suspension has occurred as a result of any breach of this Agreement by the Authority,
the Preservation Costs shall be borne by the Authority.

(iv) If suspension of Works is for reasons not attributable to the Contractor, the
Authority’s Engineer shall determine any Time Extension to which the Contractor is
reasonably entitled.

11.18 Staff and Labor

(i) Engagement of Staff and Labor

(a) The Contractor shall make its own arrangements for the engagement of all
personnel and labor, local or otherwise, and for their payment, housing,
feeding and transport.

(b) The Contractor has verified/ shall verify the identity and address of all its
employees and officials related to the Works by collecting necessary
documentary proof.

(c) The Contractor shall seek a self-declaration from its employees that they have
not been convicted of any criminal offence by any court and if any criminal
proceedings/charge-sheets have been pending/filed against them. The
Contractor shall not employ persons with criminal track record on the project.
In cases where it comes to notice later that the employee concerned has
concealed any such fact in his self-declaration or commits a criminal offence
during the course of his employment, the Contractor shall remove such person
from the project
(d) Deleted.

(e) The employees and personnel of the Contractor shall work under the
supervision, control and direction of the Contractor and the Contractor shall
be solely responsible for all negotiations with its employees and personnel
relating to their salaries and benefits, and shall be responsible for assessments
and monitoring of performance and for all disciplinary matters. All employees
/ personnel, executives engaged by the Contractor shall be in sole
employment of the Contractor and the Contractor shall be solely responsible
for their salaries, wages, statutory payments, etc and under no circumstances
the personnel shall be deemed to be the employees of the Authority. Under no
circumstances the Authority shall be liable for any

61
 payment or claim or compensation of any nature to the employees and
personnel of the Contractor.

(ii) Returns of Labor

(a) The Contractor shall deliver to the Authority a detailed return in such form
and at such intervals as the Authority may prescribe, showing the details
including names, payment details and terms of appointment of the several
classes of labor employed by the Contractor from time to time for the Works.
The Contractor shall, in its returns certify that all dues of the workers or labor
have been fully paid.

(b) The Authority is entitled to witness labor payments made or to be made by

the Contractor. If the Contractor defaults in its obligations for making any
payments under the labor laws, the Employer may make the relevant
payments. Any sum equal to any amount paid by the Employer under this Sub-
Sub-Clause 9.2 shall be immediately due as a debt from the Contractor to the
Employer and until payment/ set off shall carry interest at 18% per annum.
For this purpose it is agreed between the parties that debt due aforesaid shall
be set off immediately out the running account bills of the Contractor under
this Agreement.

(iii) Persons in the Service of Others

The Contractor shall not recruit, or attempt to recruit from amongst persons in the
service of the Authority.

(iv) Labor Laws

(a) The Contractor shall obtain all relevant labor registrations and comply with all
relevant labor laws applying to its employees, and shall duly pay them and
afford to them all their legal rights.

(b) The Contractor shall make all deductions of tax at source and all contributions
to the Payment of Gratuity, Provident Fund (including Employees’
contribution) and Employees’ State Insurance Scheme as may be required by
Applicable Laws and deposit the aforesaid contributed amount with the
appropriate authority/(s).

(c) The Contractor shall require all personnel engaged in the Works to obey all
Applicable Laws and regulations. The Contractor shall permit Authority to
witness labor payments for the Contractors direct labor, or the Subcontractors
labor. The Contractor shall ensure that all its Subcontractors strictly comply
with all labor laws.

(d) Documentary evidence confirming compliance with Sub-Clause 12.4, as may

be required from time to time, shall be provided to the Employer’s
Representative.

(e) The Employer shall not be liable for any delay/default of the Contractor in
compliance of the labor laws.

62
(v) Facilities for Staff and Labor

The Contractor shall provide and maintain all necessary accommodation and welfare
facilities for personnel engaged for the Works. The Contractor shall not permit any
personnel engaged for the Works to maintain any temporary or permanent living
quarters within the structures forming part of the Works.

(vi) Health And Safety

All necessary precautions shall be taken by the Contractor to ensure the health and
safety of staff and labor engaged for the Works. The Contractor shall, in collaboration
with and to the requirements of the local health authorities, ensure that para-medical
staff, first aid facilities, ambulance service is available on the Site at all times, and that
suitable arrangements are made for all necessary welfare and hygiene requirements
and for the prevention of epidemics. The Contractor shall appoint a safety officer to be
responsible for the safety of personnel on the Site. This safety officer shall be qualified
for his work and shall have the authority to issue instructions concerning safety and
take protective measures to prevent accidents. The Contractor shall maintain records
and make reports concerning health, safety and welfare of personnel, and damage to
property, in such manner as the Authority may reasonably require.

(vii) Contractor's Personnel

The Contractor shall employ only personnel who are appropriately qualified, skilled
and experienced in their respective trades or occupations. The Authority may require
the Contractor to remove any personnel engaged for the Works, who in the opinion of
the Authority:

(a) has engaged in any misconduct;

(b) is incompetent or negligent in the performance of his duties;
(c) fails to conform with any provisions of the Contract;

(d) engages in any conduct which is prejudicial to safety, health, or the protection
of the environment; or
(e) makes errors in the discharge of his functions.

If appropriate and required by the Employer, the Contractor shall then appoint (or
cause to be appointed) a suitable replacement person.

(viii) Disorderly Conduct

The Contractor shall at all times take all reasonable precautions to prevent any
unlawful, riotous or disorderly conduct by or amongst its personnel, and to preserve
peace and protection of people and property in the neighbourhood of the Works.

63
 Article 12

Completion Certificate

12.1 Tests on Completion

(i) At least 30 (thirty) days prior to the likely completion of the Project Highway, or a
Section thereof, the Contractor shall notify the Authority’s Engineer of its intent to
subject the Project Highway or a Section thereof, to Tests. The date and time of each of
the Tests shall be determined by the Authority’s Engineer in consultation with the
Contractor, and notified to the Authority who may designate its representative to
witness the Tests. The Contractor shall either conduct the Tests as directed by the
Authority’s Engineer or provide such assistance as the Authority’s Engineer may
reasonably require for conducting the Tests. In the event of the Contractor and the
Authority’s Engineer failing to mutually agree on the dates for conducting the Tests,
the Contractor shall fix the dates by giving not less than 10 (ten) days’ notice to the
Authority’s Engineer.

(ii) All Tests shall be conducted in accordance with Schedule-K. The Authority’s Engineer
shall either conduct or observe, monitor and review the Tests conducted by the
Contractor, as the case may be, and review the results of the Tests to determine
compliance of the Project Highway or a Section thereof, with Specifications and
Standards and if it is reasonably anticipated or determined by the Authority’s
Engineer during the course of any Test that the performance of the Project Highway
or Section or any part thereof, does not meet the Specifications and Standards, it shall
have the right to suspend or delay such Test and require the Contractor to remedy
and rectify the Defect or deficiencies. Upon completion of each Test, the Authority’s
Engineer shall provide to the Contractor and the Authority copies of all Test data
including detailed Test results. For the avoidance of doubt, it is expressly agreed that
the Authority’s Engineer may require the Contractor to carry out or cause to be
carried out additional Tests, in accordance with Good Industry Practice, for
determining the compliance of the Project Highway or Section thereof with the
Specifications and Standards.

12.2 Completion Certificate

(i) Upon completion of all Works forming part of the Project Highway, and the
Authority’s Engineer determining the Tests to be successful and after the receipt of
notarized true copies of the certificate(s) of insurance, copies of insurance policies
and premium payment receipts in respect of the insurance defined in Article 20 and
Schedule P of this Agreement, it shall, at the request of the Contractor forthwith issue
to the Contractor and the Authority a certificate substantially in the form set forth in
Schedule-L (the “Completion Certificate”).

(ii) Upon receiving the Completion Certificate, the Contractor shall remove its equipment,
materials, debris and temporary works from the Site within a period of 30 (thirty)
days thereof, failing which the Authority may remove or cause to be removed, such
equipment, materials, debris and temporary works and recover from the Contractor

64
 an amount equal to 120% (one hundred and twenty per cent) of the actual cost of
removal incurred by the Authority.

(iii) Without prejudice to the obligations of the Contractor specified in Articles 14 and 17,
the property and ownership of all the completed Works forming part of the Project
Highway shall vest in the Authority.

12.3 Rescheduling of Tests

If the Authority’s Engineer certifies to the Authority and the Contractor that it is
unable to issue the Completion Certificate, as the case may be, because of events or
circumstances on account of which the Tests could not be held or had to be
suspended, the Contractor shall be entitled to re-schedule the Tests and hold the same
as soon as reasonably practicable.

Ministry’s Letter No. RW/NH/34048/7/2013-S&R (P&B) Dated:-22.03.2019 Shall be

part of the Article-12.(Enclosed at the last of this document)

65
 Article 13

Change of Scope

13.1 Change of Scope

(i) The Authority may, notwithstanding anything to the contrary contained in this
Agreement, require the Contractor to make modifications/ alterations to the Works
(“Change of Scope”) within a period of six months counted from the Appointed Date.
Upon the Authority making its intention known to the Contractor for the specific
Change of Scope, be it positive or negative, the Contractor shall submit his proposal
for the said Change of Scope involving additional cost or reduction in cost. Any such
Change of Scope shall be made and valued in accordance with the provisions of this
Article 13.

(ii) Provided that any such Change of Scope, excluding major structures (e.g. Major
Bridge/ ROB/ RUB/ Flyover/ elevated road of more than 50 m length) may be
required and agreed to be executed between the parties beyond the period of six
months of the Appointed Date but before expiry of 50% of the original Scheduled
Construction Period of the Project Highway, subject to the condition that it shall not
entail any claims (e.g. Extension of Time/ Prolongation related claims), against the
Authority.

(iii) The Change of Scope shall mean the following:

(a) change in specifications of any item of Works;

(b) omission of any work from the Scope of the Project except under Clause 8.3
(iii); provided that, subject to Clause 13.5, the Authority shall not omit any
Work under this Clause in order to get it executed by any other authority; and
/ or

(c) any additional Work, Plant, Materials or services which are not included in the
Scope of the Project, including any associated Tests on completion of
construction.

13.2 Procedure for Change of Scope

(i) In the event of the Authority determining that a Change of Scope is necessary, it may
direct the Authority’s Engineer to issue to the Contractor a notice specifying in
reasonable detail the Works and services contemplated there under (the “Change of
Scope Notice”). The Contractor shall submit a detailed proposal as per Clause 13.2 (iii)
within 15 days from the receipt of Change of Scope Notice.

(ii) If the Contractor determines, not later than 90 days from the Appointed Date, that a
Change of Scope to the Works is required, it shall prepare a proposal with relevant
details as per Clause 13.2 (iii) at its own cost and shall submit to the Authority to
consider such Change of Scope (the “Change of Scope Request”).
66
(iii) Upon receipt of a Change of Scope Notice, the Contractor shall, with due diligence,
provide to the Authority and the Authority’s Engineer such information as is
necessary, together with detailed proposal in support of:

(a) the impact, if any, which the Change of Scope is likely to have on the Project
Completion Schedule if the works or services are required to be carried out
during the Construction Period; and

(b) the options for implementing the proposed Change of Scope and the effect, if
any, each such option would have on the costs and time thereof, including the
following details:
i. break-up of the quantities, unit rates and cost for different items of work;
and
ii. proposed design for the Change of Scope;

iii. proposed modifications, if any, to the Project Completion Schedule of the

Project Highway.

For the avoidance of doubt, the Parties expressly agree that, subject to the
provisions of Clause 13.4 (ii), the Contract Price shall be increased or
decreased, as the case may be, on account of any such Change of Scope.

(iv) The parties agree that costs and time for implementation of the proposed Change of
Scope shall be determined as per the following:

(a) For works where Schedule of Rates (SOR) of concerned circle of State’s Public
Works Department are applicable at the Base Date are available, the same
shall be applicable for determination of costs. In case of non-availability of
Schedule of Rates at the Base Date, the available Schedule of Rates shall be
applied by updating the same based on WPI. In case the Contract Price is
lower/ higher than the Estimated Project Cost as per RFP, then the SOR rates
shall be reduced/ increased in the same proportion accordingly.
(b) For item of Works not included in Schedule of Rates as mentioned in sub-para
(a) of Clause 13.2 (iv) above, the cost of same shall be derived on the basis of
MORTH Standard Data Book and the Authority’s Engineer shall determine the
prevailing market rates and discount the same considering WPI to achieve the
prevailing rate at the Base Date, and for any item in respect of which MORTH
Standard Data Book does not provide the requisite details, the Authority’s
Engineer shall determine the rate in accordance with Good Industry Practice.

For the avoidance of doubt, in case the cost as determined by the Contractor
and the Authority reveals a difference of more than 10% (ten per cent), the
cost as determined by the Authority shall be considered as final and binding
on the Contractor.

67
(c) The design charges shall be considered only for new works or items (i.e. the
Works or items not similar to the works or items in the original scope) @ 1%
(one per cent) of cost of such new works or items.

68
 (d) The costs of existing works or items, which are being changed/ omitted shall
also be valued as per above procedure and only net cost shall be considered.

(e) The reasonable time for completion of works to be taken under Change of
Scope shall be determined by the Authority’s Engineer on the basis of Good
Industry Practice and if such time exceeds the Scheduled Completion Date, the
issue of Completion Certificate shall not be affected or delayed on account of
construction of Change of Scope items/ works remaining incomplete on the
date of Tests.

(v) Upon consideration of the detailed proposal submitted by the Contractor under the
Clause 13.2 (iii), the Authority, within 15 (fifteen) days of receipt of such proposal,
may in its sole discretion either accept such Change of Scope with modifications, if
any, and initiate proceedings thereof in accordance with this Article 13 or reject the
proposal and inform the Contractor of its decision and shall issue an order (the
“Change of Scope Order”) requiring the Contractor to proceed with the performance
thereof.

For the avoidance of doubt, the Parties agree that the Contractor shall not undertake
any Change of Scope without the express consent of the Authority, save and except
any works necessary for meeting any Emergency, that too with verbal approval of
Authority which shall be confirmed in writing in next 3 (three) days. In the event that
the Parties are unable to agree, the Authority may:

(a) issue a Change of Scope Order requiring the Contractor to proceed with the
performance thereof at the rates and conditions approved by the Authority till
the matter is resolved in accordance with Article 26;
or
(b) proceed in accordance with Clause 13.5.

(vi) The provisions of this Agreement, insofar as they relate to Works and Tests, shall
apply mutatis mutandis to the Works undertaken by the Contractor under this Article
13.

13.3 Payment for Change of Scope

Payment for Change of Scope shall be made in accordance with the payment schedule
specified in the Change of Scope Order.

13.4 Restrictions on Change of Scope

(i) No Change of Scope shall be executed unless the Authority has issued the Change of
Scope Order save and except any Works necessary for meeting any Emergency.

(ii) The total value of all Change of Scope Orders shall not exceed 10% (ten per cent) of
the Contract Price.

69
(iii) Notwithstanding anything to the contrary in this Article 13, if any change is
necessitated because of any default of the Contractor in the performance of its
obligations under this Agreement, the same shall not be deemed to be Change of
Scope, and shall not result in any adjustment of the Contract Price or the Project
Completion Schedule.

13.5 Power of the Authority to undertake Works

(i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in
accordance with Clause 13.2, the Authority may, after giving notice to the Contractor
and considering its reply thereto, award such Works or services to any person or
agency on the basis of open competitive bidding. It is also agreed that the Contractor
shall provide assistance and cooperation to the person or agency who undertakes the
works or services hereunder. The Contractor shall not be responsible for rectification
of any Defects, but the Contractor shall carry out maintenance of such works after
completion of Defect Liability Period of work by other person or agency during the
remaining period of this agreement without any extra payment.

(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the
Specifications and Standards and shall be carried out in a manner that minimizes the
disruption in operation of the Project Highway. The provisions of this Agreement,
insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works
carried out under this Clause 13.5.

70
 Article 14

Maintenance

14.1 Maintenance obligations of the Contractor

(i) The Contractor shall maintain the Project Highway for a period of 5 (five) / 10 (ten)
years, corresponding to the Defects Liability Period, commencing from the date of the
Completion Certificate (the “Maintenance Period”). For the performance of its
Maintenance obligations, the Contractor shall be paid:

(a) For flexible pavement with 5 years Maintenance Period including structures:
no maintenance charges shall be paid for the first year; 0.50%of the Contract
Price each for the second, third and fourth year; and 1% of the Contract Price
for the fifth year

(b) For rigid pavement with 10 years Maintenance Period including structures:
0.25% of the Contract Price each for the first, second and third year, 0.5% of
the Contract Price each for fourth, fifth, sixth and seventh year, and 0.75% of
the Contract Price each for eighth, ninth and tenth year.

(c) For flexible perpetual pavement with 10 years maintenance period including
structures: no maintenance charges shall be paid for the first year; 0.5% of the
Contract Price each for the second, third and fourth year; 0.75% of the
Contract Price each for the subsequent years till laying of the renewal layer or
end of maintenance period, whichever is earlier. The requirement for the
renewal layer shall be worked out based on the survey and investigation of
the existing pavement and the cost of such renewal works shall be made
separately to the Contractor based on the principles defined under clause
13.2(iii). After laying of the renewal layer, the Contractor shall be paid @ 0.5%
of the original Contract Price each for the remaining years till the end of
maintenance period.

(d) For stand-alone Bridge/ Tunnel works: the contractor shall be paid @ 0.25%
of the Contract Price each for the first five years and @ 0.50% of the Contract
Price each for the remaining period of five years.

Above amount for the performance of Contractors’ Maintenance obligations shall be,
inclusive of all taxes. The amount payable for maintenance shall be adjusted to reflect
any increase or decrease arising out of variation in WPI to be determined in
accordance with the provisions of Clause 19.12. It is further agreed that the Contract
Price hereunder shall be reckoned with reference to the amount specified in Clause
19.1 (i), which shall be adjusted to the extent of Change of Scope and the works
withdrawn under the provisions of Clause 8.3 (iii), but shall not include any price
adjustments in pursuance of Clause 19.10.

71
(ii) During the Maintenance Period, the Authority shall provide to the Contractor access
to the Site for Maintenance in accordance with this Agreement. The obligations of the
Contractor hereunder shall include:

(a) permitting safe, smooth and uninterrupted flow of traffic on the Project
Highway;

(b) undertaking routine maintenance including prompt repairs of potholes,

cracks, joints, drains, embankments, structures, pavement markings, lighting,
road signs and other traffic control devices. For the avoidance of doubt, the
electricity charges for operation of electrical infrastructure installed along the
project length, except the infrastructure being used by the Contractor for its
own use, shall be borne by the Authority;
(c) undertaking repairs to structures;
(d) informing the Authority of any unauthorized use of the Project Highway;
(e) informing the Authority of any encroachments on the Project Highway; and

(f) operation and maintenance of all communication, patrolling, and

administrative systems necessary for the efficient maintenance of the Project
Highway in accordance with the provisions of this Agreement.

(iii) In respect of any Defect or deficiency not specified in Schedule-E, the Contractor shall,
at its own cost, undertake repair or rectification in accordance with Good Industry
Practice, save and except to the extent that such Defect or deficiency shall have arisen
on account of any willful default or neglect of the Authority or a Force Majeure Event.

(iv) The Contractor shall remove promptly from the Project Highway any waste materials
(including hazardous materials and waste water), rubbish and other debris
(including, without limitation, accident debris) and keep the Project Highway in a
clean, tidy and orderly condition, and in conformity with the Applicable Laws,
Applicable Permits and Good Industry Practice.

14.2 Maintenance Requirements

The Contractor shall ensure and procure that at all times during the Maintenance
Period, the Project Highway conforms to the maintenance requirements set forth in
Schedule-E (the “Maintenance Requirements”).

14.3 Maintenance Programme

(i) The Contractor shall prepare a monthly maintenance programme (the “Maintenance
Programme”) in consultation with the Authority’s Engineer and submit the same to
the Authority’s Engineer not later than 10 (ten) days prior to the commencement of
the month in which the Maintenance is to be carried out. For this purpose a joint
monthly inspection by the Contractor and the Authority’s Engineer shall be
undertaken. The Maintenance Programme shall contain the following:

72
 (a) The condition of the road in the format prescribed by the Authority’s
Engineer;
(b) the proposed maintenance Works; and
(c) deployment of resources for maintenance Works.

14.4 Safety, vehicle breakdowns and accidents

(i) The Contractor shall ensure safe conditions for the Users, and in the event of unsafe
conditions, lane closures, diversions, vehicle breakdowns and accidents, it shall follow
the relevant operating procedures for removal of obstruction and debris without
delay. Such procedures shall conform to the provisions of this Agreement, Applicable
Laws, Applicable Permits and Good Industry Practice.

(ii) The Contractor shall maintain and operate a round-the-clock vehicle rescue post with
1 (one) mobile crane having the capacity to lift a truck with a Gross Vehicle Weight of
30,000 (thirty thousand) kilograms; and such post shall be located at [****]. The
Contractor shall promptly remove any damaged vehicles and debris from the Project
Highway to enable safe movement of traffic and shall report all accidents to the police
forthwith.

14.5 Lane closure

(i) The Contractor shall not close any lane of the Project Highway for undertaking
maintenance works except with the prior written approval of the Authority’s
Engineer. Such approval shall be sought by the Contractor through a written request
to be made at least 10 (ten) days before the proposed closure of lane and shall be
accompanied by particulars thereof. Within 5 (five) business days of receiving such
request, the Authority’s Engineer shall grant permission with such modifications as it
may deem necessary and a copy of such permission shall be sent to the Authority.

(ii) Upon receiving the permission pursuant to Clause 14.5 (i), the Contractor shall be
entitled to close the designated lane for the period specified therein, and for all lane
closures extending a continuous period of 48 (forty-eight) hours, the Contractor shall,
in the event of any delay in re-opening such lane, for every stretch of 250 (two
hundred and fifty) meters, or part thereof, pay Damages to the Authority calculated at
the rate of 0.1% (zero point one per cent) of the monthly maintenance payment for
each day of delay until the lane has been re-opened for traffic. In the event of any
delay in re-opening such lanes or in the event of emergency decommissioning and
closure to traffic of the whole or any part of the Project Highway due to failure of the
Contractor, the Contractor shall pay damages to the Authority at double the above
rate, without prejudice the rights of the Authority under this Agreement including
Termination thereof.

14.6 Reduction of payment for non-performance of Maintenance obligations

(i) In the event that the Contractor fails to repair or rectify any Defect or deficiency set
forth in Schedule-E within the period specified therein, it shall be deemed as failure of

73
 performance of Maintenance obligations by the Contractor and the Authority shall be
entitled to effect reduction in monthly lump sum payment for maintenance in
accordance with Clause 19.7 and Schedule-M, without prejudice to the rights of the
Authority under this Agreement, including Termination thereof.

(ii) If the nature and extent of any Defect justifies more time for its repair or rectification
than the time specified in Schedule-E, the Contractor shall be entitled to additional
time in conformity with Good Industry Practice. Such additional time shall be
determined by the Authority’s Engineer and conveyed to the Contractor and the
Authority with reasons thereof.

14.7 Authority’s right to take remedial measures

In the event the Contractor does not maintain and/or repair the Project Highway or
any part thereof in conformity with the Maintenance Requirements, the Maintenance
Manual or the Maintenance Programme, as the case may be, and fails to commence
remedial works within 15 (fifteen) days of receipt of the Maintenance Inspection
Report under Clause 15.2 or a notice in this behalf from the Authority or the
Authority’s Engineer, as the case may be, the Authority shall, without prejudice to its
rights under this Agreement including Termination thereof, be entitled to undertake
such remedial measures at the cost of the Contractor, and to recover its cost from the
Contractor. In addition to recovery of the aforesaid cost, a sum equal to 20% (twenty
per cent) of such cost shall be paid by the Contractor to the Authority as Damages.

14.8 Restoration of loss or damage to Project Highway

Save and except as otherwise expressly provided in this Agreement, in the event that
the Project Highway or any part thereof suffers any loss or damage during the
Maintenance from any cause attributable to the Contractor, the Contractor shall, at its
cost and expense, rectify and remedy such loss or damage forthwith so that the
Project Highway conforms to the provisions of this Agreement.

14.9 Overriding powers of the Authority

(i) If in the reasonable opinion of the Authority, the Contractor is in material breach of its
obligations under this Agreement and, in particular, the Maintenance Requirements,
and such breach is causing or likely to cause material hardship or danger to the Users
and pedestrians, the Authority may, without prejudice to any of its rights under this
Agreement including Termination thereof, by notice require the Contractor to take
reasonable measures immediately for rectifying or removing such hardship or danger,
as the case may be.

(ii) In the event that the Contractor, upon notice under Clause 14.9 (i), fails to rectify or
remove any hardship or danger within a reasonable period, the Authority may
exercise overriding powers under this Clause 14.9 (ii) and take over the performance
of any or all the obligations of the Contractor to the extent deemed necessary by it for
rectifying or removing such hardship or danger; provided that the exercise of such
overriding powers by the Authority shall be of no greater scope and of no longer

74
 duration than is reasonably required hereunder; provided further that any costs and
expenses incurred by the Authority in discharge of its obligations hereunder shall be
recovered by the Authority from the Contractor, and the Authority shall be entitled to
deduct any such costs and expenses incurred from the payments due to the
Contractor under Clause 19.7 for the performance of its Maintenance obligations.

(iii) In the event of a national emergency, civil commotion or any other circumstances
specified in Clause 21.3, the Authority may take over the performance of any or all the
obligations of the Contractor to the extent deemed necessary by it, and exercise such
control over the Project Highway or give such directions to the Contractor as may be
deemed necessary; provided that the exercise of such overriding powers by the
Authority shall be of no greater scope and of no longer duration than is reasonably
required in the circumstances which caused the exercise of such overriding power by
the Authority. For the avoidance of doubt, it is agreed that the consequences of such
action shall be dealt in accordance with the provisions of Article 21. It is also agreed
that the Contractor shall comply with such instructions as the Authority may issue in
pursuance of the provisions of this Clause 14.9 (iii), and shall provide assistance and
cooperation to the Authority, on a best effort basis, for performance of its obligations
hereunder.

14.10 Taking over Certificate

The Maintenance Requirements set forth in Schedule-E having been duly carried out,
Maintenance Period as set forth in Clause 14.1 (i) having been expired and Authority’s
Engineer determining the Tests on Completion of Maintenance to be successful in
accordance with Schedule-Q; the Authority will issue Taking Over Certificate to the
Contractor substantially in the format set forth in Schedule-R.

75
 Article 15

Supervision and Monitoring during Maintenance

15.1 Inspection by the Contractor

(i) The Authority’s Engineer shall undertake regular inspections to evaluate

continuously the compliance with the Maintenance Requirements.

(ii) The Contractor shall carry out a detailed pre-monsoon inspection of all bridges,
culverts and drainage system in accordance with the guidelines contained in IRC:
SP35. Report of this inspection together with details of proposed maintenance works
as required shall be conveyed to the Authority’s Engineer forthwith. The Contractor
shall complete the proposed maintenance works before the onset of the monsoon and
send a compliance report to the Authority’s Engineer. Post monsoon inspection shall
be undertaken by the Contractor and the inspection report together with details of
any damages observed and proposed action to remedy the same shall be conveyed to
the Authority’s Engineer forthwith.

15.2 Inspection and payments

(i) The Authority’s Engineer may inspect the Project Highway at any time, but at least
once every month, to ensure compliance with the Maintenance Requirements. It shall
make a report of such inspection (“Maintenance Inspection Report”) stating in
reasonable detail the Defects or deficiencies, if any, with particular reference to the
Maintenance Requirements, the Maintenance Manual, and the Maintenance
Programme, and send a copy thereof to the Authority and the Contractor within 10
(ten) days of such inspection.

(ii) After the Contractor submits to the Authority’s Engineer the Monthly Maintenance
Statement for the Project Highway pursuant to Clause 19.6, the Authority’s Engineer
shall carry out an inspection within 10 (ten) days to certify the amount payable to the
Contractor. The Authority’s Engineer shall inform the Contractor of its intention to
carry out the inspection at least 3 (three) business days in advance of such inspection.
The Contractor shall assist the Authority’s Engineer in verifying compliance with the
Maintenance Requirements.

(iii) For each case of non-compliance of Maintenance Requirements as specified in the

inspection report of the Authority’s Engineer, the Authority’s Engineer shall calculate
the amount of reduction in payment in accordance with the formula specified in
Schedule-M.

(iv) Any deduction made on account of non-compliance will not be paid subsequently
even after establishing the compliance thereof. Such deductions will continue to be
made every month until the compliance is procured.

76
15.3 Tests

For determining that the Project Highway conforms to the Maintenance

Requirements, the Authority’s Engineer shall require the Contractor to carry out, or
cause to be carried out, Tests specified by it in accordance with Good Industry
Practice. The Contractor shall, with due diligence, carry out or cause to be carried out
all such Tests in accordance with the instructions of the Authority’s Engineer and
furnish the results of such Tests forthwith to the Authority’ Engineer.

At any time during Maintenance Period, the Authority may appoint an external
technical auditor to conduct an audit of the quality of the Works. The Auditor in the
presence of the representatives of the Contractor and the Authority’s Engineer shall
carry out the Tests and/ or collect samples for testing in the laboratory. The timing,
the testing equipment and the sample size of this audit shall be as decided by the
Authority. The findings of the audit, to the extent accepted by the Authority, shall be
notified to the Contractor and the Authority’s Engineer for taking remedial measures.
After completion of the remedial measures by the Contractor, the auditor shall
undertake a closure audit and this process will continue till the remedial measures
have brought the maintenance works into compliance with the Specifications and
Standards. The Contractor shall provide all assistance as may be required by the
auditor in the conduct of its audit hereunder. Notwithstanding anything contained in
this Clause 15.3, the external technical audit shall not affect any obligations of the
Contractor or the Authority’s Engineer under this Agreement.

15.4 Reports of unusual occurrence

The Contractor shall, during the Maintenance Period, prior to the close of each day,
send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report
stating accidents and unusual occurrences on the Project Highway relating to the
safety and security of the Users and Project Highway. A monthly summary of such
reports shall also be sent within 3 (three) business days of the closing of month. For
the purposes of this Clause 15.4, accidents and unusual occurrences on the Project
Highway shall include:

(a) accident, death or severe injury to any person;

(b) damaged or dislodged fixed equipment;
(c) flooding of Project Highway; and
(d) any other unusual occurrence.

77
 Article 16

Traffic Regulation

16.1 Traffic regulation by the Contractor

(i) The Contractor shall take all the required measures and make arrangements for the
safety of Users during the Construction and Maintenance of the Project Highway or a
Section thereof in accordance with the provisions of MORTH Specifications. It shall
provide, erect and maintain all such barricades, signs, markings, flags, and lights as
may be required by Good Industry Practice for the safety of the traffic passing through
the Section under construction or maintenance.

(ii) All works shall be carried out in a manner creating least interference to traffic passing
through the Project Highway or a Section thereof. In sections where construction or
maintenance Works on the carriageway are taken up, the Contractor shall ensure that
proper passage is provided for the traffic. Where it is not possible or safe to allow
traffic on part width of the carriageway, a temporary diversion of proper
specifications shall be constructed by the Contractor at its own cost. ‘ROBOTS’ may be
used for diversion and control of traffic during Construction. The Contractor shall take
prior approval of the Authority’s Engineer for any proposed arrangement for traffic
regulation during Construction and Maintenance, which approval shall not be
unreasonably withheld.

78
 Article 17

Defects Liability

17.1 Defects Liability Period

(i) The Contractor shall be responsible for all the Defects and deficiencies, except usual
wear and tear in the Project Highway or any Section thereof, till the expiry of a period
of commencing from the date of Completion Certificate (the “Defects Liability Period”)
as specified below:

(a) 5 (five) years from the date of completion in case of a road being constructed
with flexible pavement;

(b) 10 (ten) years from the date of completion in case of road being constructed
with rigid pavement;

(c) 10 (ten) years from the date of completion in case of road being constructed
with flexible pavement using perpetual design;

(d) 10 (ten) years from the date of completion in case of all stand-alone
structures, e.g. Major Bridges/ and Tunnels;

(e) 10 (ten) years from the date of completion for the stretches where new
technology/ material has been/ is proposed to be used.

(f) 3 (three) years from the date of completion for stretches requiring renewal of
Bituminous Concrete (BC) layer through either using hot-in-place recycling of
the entire BC layer or providing a fresh layer of BC with 40mm thickness.

(g) 3 (three) years from the date of completion for stretches requiring
improvement to riding quality, in cases other than those mentioned in para (f)
above, through laying a layer of BM/DBM and BC.

The Defects Liability Period shall commence from the date of the Completion
Certificate. For the avoidance of any doubt, any repairs or restoration because of usual
wear or tear in the Project Highway or any Section thereof shall form a part of the
Maintenance obligations of the Contractor as specified in Article 14.

17.2 Remedying Defects

Save and except as provided in Clause 14.1 (iii), the Contractor shall repair or rectify
all Defects and deficiencies observed by the Authority or Authority’s Engineer during
the Defects Liability Period within a period of 15 (fifteen) days from the date of notice
issued by the Authority or Authority’s Engineer in this behalf, or within such
reasonable period as may be determined by the Authority or Authority’s Engineer at
the request of the Contractor, in accordance with Good Industry Practice.

79
17.3 Cost of remedying Defects

Any repair or rectification undertaken in accordance with the provisions of Clause

17.2, including any additional testing, shall be carried out by the Contractor at its own
risk and cost, to the extent that such rectification or repair is attributable to:

(a) the design of the Project;

(b) Plant, Materials or workmanship not being in accordance with this Agreement
and the Specifications and Standards;

(c) improper maintenance during construction of the Project Highway by the

Contractor; and/ or

(d) failure by the Contractor to comply with any other obligation under this
Agreement.

17.4 Contractor’s failure to rectify Defects

If the Contractor fails to repair or rectify such Defect or deficiency within the period
specified in Clause 17.2, the Authority shall be entitled to get the same repaired,
rectified or remedied at the Contractor’s cost to make the Project Highway conform to
the Specifications and Standards and the provisions of this Agreement. All costs
consequent thereon shall, after due consultation with the Authority and the
Contractor, be determined by the Authority’s Engineer. The cost so determined and
an amount equal to 20% (twenty percent) of the cost as Damages shall be recoverable
by the Authority from the Contractor and may be deducted by the Authority from any
monies due to the Contractor.

17.5 Extension of Defects Liability Period

The Defects Liability Period shall be deemed to be extended till the identified Defects
under Clause 17.2 have been remedied or rectified.

80
 Article 18

Authority’s Engineer

18.1 Appointment of the Authority’s Engineer

(i) The Authority shall appoint a firm of Consulting Engineers or a Project Monitoring
Committee (PMC) substantially in accordance with the selection criteria set forth in
Schedule-N, to be the engineer under this Agreement (the “Authority’s Engineer”). In
unavoidable circumstances, Authority may appoint an officer to act as Authority’s
Engineer until appointment of a Consulting Engineering firm/ Supervision
Consultant/ PMC.

(ii) The officer in-charge of the Authority (e.g. PD/ RO/ CGM/ Member in the case of
NHAI; RO/CE/ADG in the case of MoRTH projects executed through the State PWDs;
and PD/ED/Director in the case of NHIDCL) is responsible for the overall supervision
and monitoring of the execution of project as the representative of the owner of the
project. The Authority's Engineer is appointed to assist the Authority for carrying out
the functions as detailed under clause 18.2. As such, an officer of the Authority is
vested with all such powers and responsibilities as are enjoined upon the Authority's
Engineer and is fully competent to issue any instructions for proper monitoring and
supervision of the project, either by himself or through the Authority's Engineer.
Instructions issued by the concerned officer of the Authority shall have the same
effect as that of the Authority's Engineer in terms of this Agreement. Wherever such
concerned officer issues any instructions or notice to the Contractor, he shall endorse
a copy thereof to the Authority's Engineer.

(iii) The Authority’s Engineer should be appointed within 10 days from the date of this
Agreement or before declaration of Appointed Date, whichever is earlier. The
Authority shall notify the appointment or replacement of the Authority’s Engineer to
the Contractor.

(iv) The staff of the Authority’s Engineer shall include suitably qualified engineers and
other professionals who are competent to assist the Authority’s Engineer to carry out
its duties.

18.2 Duties and authority of the Authority’s Engineer

(i) The Authority’s Engineer shall perform the duties and exercise the authority in
accordance with the provisions of this Agreement and substantially in accordance
with the terms of reference (“Terms of Reference” or “TOR”) set forth in Annexure-I of
Schedule N, but subject to obtaining prior written approval of the Authority before
determining:

(a) any Time Extension;

(b) any additional cost to be paid by the Authority to the Contractor;
(c) the Termination Payment;

81
 (d) issuance of Completion Certificate; or

(e) any other matter which is not specified in (a), (b), (c) or (d) above and which
creates financial liability on either Party.

(ii) No decision or communication of the Authority’s Engineer shall be effective or valid

unless it is accompanied by an attested true copy of the approval of the Authority for
and in respect of any matter specified in Clause 18.2 (i).

(iii) The Authority’s Engineer shall submit regular periodic reports, at least once every
month, to the Authority in respect of its duties and functions under this Agreement.
Such reports shall be submitted by the Authority’s Engineer within 10 (ten) days of
the beginning of every month. For the avoidance of doubt, the Authority’s Engineer
shall include in its report, compliance of the recommendations of the Safety
Consultant.

18.3 Delegation by the Authority’s Engineer

(i) The Authority’s Engineer may, by order in writing, delegate any of his duties and
responsibilities to suitably qualified and experienced personnel who are accountable
to Authority’s Engineer, or may revoke any such delegation, under intimation to the
Authority and the Contractor. Provided, however, that the Authority’s Engineer shall
be responsible and liable for all actions and omissions of such personnel.

(ii) Any failure of the Authority’s Engineer to disapprove any work, Plant or Materials
shall not constitute approval, and shall, therefore, not prejudice the right of the
Authority to reject the work, Plant or Materials, which is not in accordance with the
provisions of this Agreement and the Specifications and Standards.

(iii) Notwithstanding anything stated in Clause 18.3 (i) above, the Authority’s Engineer
shall not delegate the authority to refer any matter for the Authority’s prior approval
wherever required in accordance with the provisions of Clause 18.2.

18.4 Instructions of the Authority’s Engineer

(i) The Authority’s Engineer may issue instructions for remedying any Defect(s) to the
Contractor. The Contractor shall take such instructions from the Authority’s Engineer,
or from an assistant to whom appropriate authority has been delegated under Clause
18.3.

(ii) The instructions issued by the Authority’s Engineer shall be in writing. However, if
the Authority’s Engineer issues any oral instructions to the Contractor, it shall
confirm the oral instructions in writing within 2 (two) working days of issuing them.

(iii) In case the Contractor does not receive the confirmation of the oral instructions
within the time specified in Clause 18.4 (ii), the Contractor shall seek the written
confirmation of the oral instructions from the Authority’s Engineer. The Contractor
shall obtain acknowledgement from the Authority’s Engineer of the communication
seeking written confirmation. In case of failure of the Authority’s Engineer or its
delegatedassistant to reply to the Contractor within 2 (two) days of the receipt of the

82
 communication from the Contractor, the Contractor may not carry out the
instructions.

(iv) In case of any dispute on any of the instructions issued by the delegated assistant, the
Contractor may refer the dispute to the Authority’s Engineer, who shall then confirm,
reverse or vary the instructions within 3 (three) business days of the dispute being
referred.

18.5 Determination by the Authority’s Engineer

(i) The Authority’s Engineer shall consult with each Party in an endeavour to reach
agreement wherever this Agreement provides for the determination of any matter by
the Authority’s Engineer. If such agreement is not achieved, the Authority’s Engineer
shall make a fair determination in accordance with this Agreement having due regard
to all relevant circumstances. The Authority’s Engineer shall give notice to both the
Parties of each agreement or determination, with supporting particulars.

(ii) Each Party shall give effect to each agreement or determination made by the
Authority’s Engineer in accordance with the provisions of this Agreement. Provided,
however, that if any Party disputes any instruction, decision, direction or
determination of the Authority’s Engineer, the Dispute shall be resolved in accordance
with the Dispute Resolution Procedure.

18.6 Remuneration of the Authority’s Engineer

The remuneration, costs and expenses of the Authority’s Engineer shall be paid by the
Authority.

18.7 Termination of the Authority’s Engineer

(i) The Authority may, in its discretion, replace the Authority’s Engineer at any time.
However, the Authority shall ensure that alternative arrangements for appointment of
another Authority's Engineer or designation of its own officer as the Authority
Engineer for the intervening period are made simultaneously.

(ii) If the Contractor has reasons to believe that the Authority’s Engineer is not
discharging its duties and functions in accordance with the provisions of this
Agreement, it may make a written representation to the Authority and seek
termination of the appointment of the Authority’s Engineer. Upon receipt of such
representation, the Authority shall hold a tripartite meeting with the Contractor and
the Authority’s Engineer and makes best efforts for an amicable resolution of the
representation. In the event that the appointment of the Authority’s Engineer is
terminated hereunder, the Authority shall appoint forthwith another
Authority’sEngineerinaccordancewithClause 18.1and18.7(i).

83
 Part IV

Financial Covenants

84
 Article 19

Payments

19.1 Contract Price

(i) The Authority shall make payments to the Contractor for the Works on the basis of
the lump sum price accepted by the Authority in consideration of the obligations
specified in this Agreement for an amount of INR … … … … (INR … … … … … … … …)
(the “Contract Price”), which shall be subject to adjustments in accordance with the
provisions of this Agreement. For the avoidance of doubt, the Parties expressly agree
that the Contract Price shall not include the cost of Maintenance, which shall be paid
separately in accordance with the provisions of Clause 19.7. The Parties further agree
that save and except as provided in this Agreement, the Contract Price shall be valid
and effective until issue of Completion Certificate.

(ii) The Contract Price includes all duties, taxes, royalty, cess, charges, and fees that may
be levied in accordance with the laws and regulations in force as on the Base Date on
the Contractor's equipment, Plant, Materials and supplies acquired for the purpose of
this Agreement and on the services performed under this Agreement. Nothing in this
Agreement shall relieve the Contractor from its responsibility to pay any tax including
any tax that may be levied in India on profits made by it in respect of this
Agreement.The contract price also includes the cost of shifting of obstructing utilities
as given in clause 9.2 and Schedule B.
(iii) The Contract Price shall not be adjusted for any change in costs stated in Clause 19.1
(ii) above, except as stated in Clauses 19.10 and 19.17.

(iv) The Contract Price shall not be adjusted to take account of any unforeseen difficulties
or costs, unless otherwise provided for in this Agreement.

(v) Unless otherwise stated in this Agreement, the Contract Price covers all the
Contractor’s obligations for the Works under this Agreement and all things necessary
for the Construction and the remedying of any Defects in the Project Highway.

(vi) All payments under this Agreement shall be made in Indian Rupees.

19.2 Advance Payment

(i) The Authority shall make an interest-bearing advance payment (the “Advance
Payment”) @ “Bank Rate + 3%”, equal to 10 % (ten percent) of the Contract Price,
exclusively for mobilization expenses. The Advance Payment for mobilization
expenses shall be made in two installments each equal to 5% (five percent) of the
Contract Price. The second 5% (five percent) mobilization advance would be released
after submission of utilization certificate by the Contractor for the first 5% (five per
cent) advance already released earlier.

(ii) In addition to above, the Authority shall make an additional interest-bearing Advance
Payment against newly purchased key Construction equipment required for the
works as per agreed Construction programme and brought to the site, if so requested

85
 by the Contractor subject to the same terms and conditions specified for Advance
Payment for mobilization expenses in this Agreement. The maximum of such advance
shall be 5% (five per cent) of the Contract Price against Bank Guarantee. This advance
shall be further subject to the condition that:

(a) such new equipment are considered by the Authority’s Engineer to be

necessary for the works and

(b) these new equipment should be procured in the name of Contractor and is
verified by Authority’s Engineer to have been brought to site.

The Advance Payment for mobilization expenses and for acquisition of key new
Construction equipment would be deemed as interest bearing advance at the
applicable interest rate (@"Bank rate + 3%”), to be compounded annually on a
reducing balance basis. The interest would be recovered along with the recovery of
mobilization Advance Payment as per provision laid down for the mobilization
advance recovery.

(iii) The Contractor may apply to the Authority for the first installment of the Advance
Payment at any time after the Appointed Date, along with an irrevocable and
unconditional guarantee from a Bank for an amount equivalent to 110% (one
hundred and ten per cent) of such installment, substantially in the form provided at
Annex-III of Schedule-G, to remain effective till the complete and full repayment
thereof.

(iv) At any time, after 60 (sixty) days from the Appointed Date, the Contractor may apply
to the Authority for the second installment of the Advance Payment along with an
irrevocable and unconditional guarantee from a Bank for an amount equivalent to
110% (one hundred and ten per cent) of such installment, substantially in the form
provided at Annex-III of Schedule-G, to remain effective till the complete and full
repayment thereof.

The Contractor has the option of splitting the Bank Guarantee against Advance
Payment for mobilization expenses into parts, each not less than 2.75% (two point
seven five per cent) of the Contract Price. Each part of the guarantee shall remain
effective till full repayment of such part advance corresponding to this bank
guarantee. Such part of Bank Guarantee shall be returned to the Contractor on
recovery under the Agreement of the full amount of such part guarantee within 30
(thirty) days of the said recovery.

(v) The Advance Payment shall be paid by the Authority to the Contractor within 15
(fifteen) days of the receipt of its respective requests in accordance with the
provisions of this Clause 19.2.

(vi) The Advance Payment shall be repaid through percentage deductions from the stage
payments determined by the Authority’s Engineer in accordance with Clause 19.5, as
follows:

(a) deductions shall commence in the first Stage Payment Statement;

86
 (b) deductions shall be made at the rate of 15% (fifteen percent) of each Stage
Payment Statement until such time as the advance payment has been repaid;
provided that the advance payment shall be completely repaid prior to the
time when 80% (eighty percent) of the Schedule Construction Period is over;

(c) if total certified stage payments (excluding the Advance Payment and
deductions and repayments of retention) does not exceed 20% (twenty
percent) of the Contract Price within [50% of the Scheduled Construction
Period] from the Appointed Date then the Advance Payment including
interest shall be recovered by encashment of the Bank Guarantee for the
Advance Payment.

(vii) If the Advance Payment has not been fully repaid prior to Termination under Clause
21.7 or Article 23, as the case may be, the whole of the balance then outstanding shall
immediately become due and payable by the Contractor to the Authority. Without
prejudice to the provisions of Clause 19.2 (vi), in the event of Termination for
Contractor Default, the Advance Payment shall be deemed to carry interest @ “Bank
Rate+5%” per annum from the date of Advance Payment to the date of recovery by
encashment of the Bank Guarantee for the Advance Payment. For the avoidance of
doubt, the aforesaid interest shall be payable on the unrecovered balance.

19.3 Procedure for estimating the payment for the Works

(i) The Authority shall make interim payments to the Contractor as certified by the
Authority’s Engineer on completion of a stage, in a length, number or area as specified
and valued in accordance with the proportion of the Contract Price assigned to each
item and its stage in Schedule-H.

(ii) The Contractor shall base its claim for interim payment for the stages completed till
the end of the month for which the payment is claimed, valued in accordance with
Clause 19.3 (i), supported with necessary particulars and documents in accordance
with this Agreement.

(iii) Any reduction in the Contract Price arising out of Change of Scope or the works
withdrawn under Clause 8.3 shall not affect the amounts payable for the items or
stage payments thereof which are not affected by such Change of Scope or
withdrawal. For avoidance of doubt and by way of illustration, the Parties agree that if
the amount assigned to Major Bridges is reduced from Rs. 100 crore to Rs. 80 crore
owing to Change of Scope or withdrawal of work, the reduction in payment shall be
restricted to relevant payments for Major Bridges only and the payment due in
respect of all other stage payments under the item Major Bridges shall not be affected
in any manner. The Parties further agree that the adjustments arising out of the
aforesaid modifications shall be carried out in a manner that the impact of such
modifications is restricted to the said Change of Scope or withdrawal, as the case may
be, and does not alter the payments due for and in respect of items or stage payments
which do not form part of such Change of Scope or withdrawal.

87
19.4 Stage Payment Statement for Works

The Contractor shall submit a statement (the “Stage Payment Statement”), in 3 (three)
copies, by the 7th (seventh) day of the month to the Authority’s Engineer in the form
set forth in Schedule-O, showing the amount calculated in accordance with Clause
19.3 to which the Contractor considers himself entitled for completed stage(s) of the
Works. The Stage Payment Statement shall be accompanied with the progress reports
and any other supporting documents. The Contractor shall not submit any claim for
payment of incomplete stages of work.

19.5 Stage Payment for Works

(i) Within 10 (ten) days of receipt of the Stage Payment Statement from the Contractor
pursuant to Clause 19.4, the Authority’s Engineer shall broadly determine the amount
due to the Contractor and recommend the release of 90 (ninety) percent of the
amount so determined as part payment against the Stage Payment Statement,
pending issue of the Interim Payment Certificate by the Authority’s Engineer. Within
10 (ten) days of the receipt of recommendation of the Authority’s Engineer, the
Authority shall make electronic payment directly to the Contractor’s bank account.

(ii) Within 15 (fifteen) days of the receipt of the Stage Payment Statement referred to in
Clause 19.4, the Authority’s Engineer shall determine and shall deliver to the
Authority and the Contractor an IPC certifying the amount due and payable to the
Contractor, after adjusting the payments already released to the Contractor against
the said statement. For the avoidance of doubt, the Parties agree that the IPC shall
specify all the amounts that have been deducted from the Stage Payment Statement
and the reasons therefor.

(iii) In cases where there is a difference of opinion as to the value of any stage, the
Authority’s Engineer’s view shall prevail and interim payments shall be made to the
Contractor on this basis; provided that the foregoing shall be without prejudice to the
Contractor’s right to raise a Dispute.

(iv) The Authority’s Engineer may, for reasons to be recorded, withhold from payment:

(a) the estimated value of work or obligation that the Contractor has failed to
perform in accordance with this Agreement and the Authority’s Engineer had
notified the Contractor; and

(b) the estimated cost of rectification of work done being not in accordance with
this Agreement.

(v) Payment by the Authority shall not be deemed to indicate the Authority's acceptance,
approval, consent or satisfaction with the work done.

19.6 Monthly Maintenance Statement of the Project Highway

(i) The Contractor shall submit to the Authority’s Engineer a monthly maintenance
statement (“Monthly Maintenance Statement”) in 3 (three) copies by the 7th

88
 (seventh) day of each month in the format set forth in Schedule-O for the
Maintenance of the Project Highway during the previous month.

(ii) The monthly lump sum amount payable for Maintenance shall be 1/12th (one-
twelfth) of the annual cost of Maintenance as specified in Clause 14.1 (i).

19.7 Payment for Maintenance of the Project Highway

(i) Within 15 (fifteen) days of receipt of the Monthly Maintenance Statement from the
Contractor pursuant to Clause 19.6, the Authority’s Engineer shall verify the
Contractor’s monthly maintenance statement and certify the amount to be paid to the
Contractor taking into account:

(a) Compliance with the Maintenance Requirements; and

(b) reduction for non-compliance with the Maintenance Requirement in

accordance with Clause 19.7 (ii).

The Authority’s Engineer shall deliver to the Authority an IPC approving or

amending the monthly maintenance statement to reflect the amount due to
the Contractor in accordance with this Agreement.

(ii) Maintenance shall be measured in units of one kilometer each; provided, however,
that payment thereof shall be made in fixed monthly amounts in accordance with this
Agreement. If the Maintenance Requirements set forth in Schedule-E are not met,
reduction in payments shall be made in accordance with the provisions of Schedule-
M. The reductions for non-compliance with the Maintenance Requirements shall be
applied on the basis of monthly inspections by the Authority’s Engineer.

(iii) The deduction made on account of non-compliance with the Maintenance

Requirements shall not be subsequently considered for payment after the compliance
is achieved by repair or rectification.

(iv) The Authority shall pay to the Contractor every quarter any amount due under any
IPC under this Clause 19.7. The payment shall be made no later than 30 (thirty) days
from the date of submission of the last IPC for the relevant quarter.

19.8 Payment of Damages

(i) The Contractor may claim Damages due and payable to it in accordance with the
provisions of this Agreement.

(ii) The Authority’s Engineer shall issue the IPC within 15 (fifteen) days of the receipt of
the claim under Clause 19.8 (i), after making adjustments in accordance with the
provisions of this Agreement. The Authority shall pay to the Contractor the amount
due under any IPC within a period of 30 (thirty) days from the date of the submission
of the claim under this Clause 19.8. In the event of the failure of the Authority to make
payment to the Contractor within the specified time, the Authority shall be liable to

89
 pay to the Contractor interest thereon and the provisions of Clause 19.9 shall apply
mutatis mutandis thereto.

19.9 Time of payment and interest

(i) The Authority shall pay to the Contractor any amount due under any payment
certificate issued by the Authority’s Engineer in accordance with the provisions of this
Article 19, or in accordance with any other clause of this Agreement as follows:

(a) payment shall be made no later than 30 (thirty) days from the date of
submission of the Stage Payment Statement by the Contractor to the
Authority’s Engineer for certification in accordance with the provisions of
Clause 19.4 for an IPC; provided that, in the event the IPC is not issued by the
Authority’s Engineer within the aforesaid period of 30 (thirty) days, the
Authority shall pay the amount shown in the Contractor’s Stage Payment
Statement and any discrepancy therein shall be added to, or deducted from,
the next payment certificate issued to the Contractor; and

(b) payment shall be made no later than 30 (thirty) days from the date of
submission of the Final Payment Certificate for Works along with the
discharge submitted to the Authority’s Engineer in accordance with the
provisions of Clause 19.15 for certification.

(ii) In the event of the failure of the Authority to make payment to the Contractor within
the time period stated in this Clause 19.9, the Authority shall be liable to pay to the
Contractor interest @ Bank Rate + 3% per annum, on all sums remaining unpaid from
the date on which the same should have been paid, calculated in accordance with the
provisions of sub-Clauses (a) and (b) of Clause 19.9 (i) and till the date of actual
payment.

19.10 Price adjustment for the Works

(i) The amounts payable to the Contractor for Works shall be adjusted in accordance
with the provisions of this Clause 19.10

(ii) Subject to the provisions of Clause 19.10 (iii), the amounts payable to the Contractor
for Works, shall be adjusted in the IPC issued by the Authority’s Engineer for the
increase or decrease in the index cost of inputs for the Works, by the addition or
subtraction of the amounts determined by the formulae prescribed in Clause 19.10
(iv).

(iii) To the extent that full compensation for any increase or decrease in costs to the
Contractor is not covered by the provisions of this or other Clauses in this Agreement,
the costs and prices payable under this Agreement shall be deemed to include the
amounts required to cover the contingency of such other increase or decrease of costs
and prices.

(iv) The Contract Price shall be adjusted for increase or decrease in rates and price of
labour, cement, steel, Plant, machinery and spares, bitumen, fuel and lubricants, and

90
other material inputs in accordance with the principles, procedures and formulae
specified below:

(a) Price adjustment shall be applied on completion of the specified stage of the
respective item of work in accordance with Schedule-H;
(b) Adjustment for each item of work/stage shall be made separately;

(c) The following expressions and meanings are assigned to the value of the work
done:

RW= Value of work done for the completion of a stage under the following
items of Schedule-H:
i. Road works; and
ii. Other works

BR = Value of work done for the completion of a stage under the items Major
Bridges and Structures (Schedule-H)

(d) Price adjustment for changes in cost shall be paid in accordance with the
following formulae:

(i)

(ii)

Where,

VRW = Increase or decrease in the cost of road works/other works during the period
under consideration due to changes in the rates for relevant components as
stated in sub-paragraph (e).

VBR = Increase or decrease in the cost of Major Bridges and Structures during the
period under consideration due to changes in the rates for relevant
components as stated in sub-paragraph (e).

PB, PC, PL, PM, and PS are the percentages of bitumen, cement, labour, other
materials, and steel/components (including strands and cables) respectively for the
relevant item as stated in sub-paragraph (e).

PA is the percentage of Plant, machinery and spares component for the relevant item
as stated in sub-paragraph (e).

91
PF is the percentage of fuel and lubricants for the relevant items as stated in sub-
paragraph (e).

AO = The wholesale price index as published by the Ministry of Commerce &

Industry, Government of India (hereinafter called “WPI”) for “Manufacture of
machinery for mining, quarrying and construction” for the month of the Base
Date.

AI = The WPI for construction machinery for the month three months prior to the
month to which the IPC relates.

BO = The official retail price of bitumen at the nearest refinery at [Haldiya] on the
Base Date.

BI = The official retail price of bitumen at nearest refinery at [Haldiya], on the first
day of the month three months prior to the month to which the IPC relates.

CO = The WPI for Ordinary Portland Cement for the month of the Base Date.

CI = The WPI for Ordinary Portland Cement for the month three months prior to
the month to which the IPC relates.

FO = The official retail price of high speed diesel (HSD) oil at the existing consumer
pumps of Indian Oil Corporation (“IOC”) in the State of [Jharkhand] on the
Base Date.

FI = The official retail price of HSD at the existing consumer pumps of IOC in the
State of [Jharkhand] on the first day of the month three months prior to the
month to which the IPC relates.

LO = The consumer price index for industrial workers for the [circle **** in the
State of Jharkhand], published by Labor Bureau, Ministry of Labor,
Government of India, (hereinafter called “CPI”) for the month of the Base Date.

LI = The CPI for the month three months prior to the month to which the IPC
relates.

MO = The WPI for all commodities for the month of the Base Date.

MI = The WPI for all commodities for the month three months prior to the month to
which the IPC relates.

SO = The WPI for Mild Steel –Long Products for the month of the Base Date.

SI = The WPI for Mild Steel –Long Products for the month three months prior to
the month to which the IPC relates.

(e) The following percentages shall govern the price adjustment of the Contract
Price:

92
 Component Item
Road Works Major
Earthwork, Bituminous Cement Culverts, Bridges and
Granular work, work Concrete minor bridges Structures
and Other Pavement and other
Works Structures
Labour (PL) [8%] [5%] Nil [10%] Nil
Cement (PC) [5%] Nil Nil [20%] Nil
Steel (PS) [35%] Nil Nil [33%] Nil
Bitumen (PB) Nil [40%] Nil Nil Nil
Fuel andlubricants(PF) [12%] [15%] Nil [10%] Nil
OtherMaterials(PM) [30%] [18%] Nil [12%] Nil
Plant,machineryand [10%] [22%] Nil [15%] Nil
spares (PA)

Total 100% 100% Nil 100% Nil

19.11 Restrictions on price adjustment

Price adjustment shall be due and payable only in respect of the stages of Works for
which the Stage Payment Statement has been submitted by the Contractor no later
than 30 (thirty) days from the date of the applicable Project Milestone or the
Scheduled Completion Date, as the case may be, including any Time Extension granted
therefore in accordance with the provisions of this Agreement. For the avoidance of
doubt, in the event of submission of any Stage Payment Statement after the period
specified herein, price adjustment shall be applicable until the date of the respective
Project Milestone or the Scheduled Completion Date, as the case may be.

19.12 Price adjustment for Maintenance of Project Highway

Lump sum payment for Maintenance shall be adjusted every quarter for changes in
rates and prices of various inputs in accordance with the formula given below:

Where

V = Increase or decrease in the quarterly lump sum payment

P = Quarterly lump sum payment due to the Contractor after adjusting any
reduction in payment for non-compliance of the Maintenance Requirements
W0 = The wholesale price index (all commodities) for the month of the Base
Date.
WI= The wholesale price index (all commodities) for the first day of the quarter
under consideration for determining the price adjustment.

19.13 Final Payment Statement

(i) Within 60 (sixty) days after receiving the Completion Certificate under Clause 12.2,
theContractor shall submit to the Authority’s Engineer for consideration 6 (six) copies
of a Final Payment Statement (the “Final Payment Statement”) for Works, with
93
 supporting documents showing in detail, in the form prescribed by the Authority’s
Engineer:

(a) the summary of Contractor’s Stage Payment claims for Works as submitted in
accordance with Clause 19.4;
(b) the amounts received from the Authority against each claim; and
(c) any further sums which the Contractor considers due to it from the Authority.

If the Authority’s Engineer disagrees with or cannot verify any part of the
Final Payment Statement, the Contractor shall submit such further
information as the Authority’s Engineer may reasonably require. The
Authority’s Engineer shall deliver to the Authority:

i. an IPC for those parts of the Final Payment Statement which are not in
dispute, along with a list of disputed items which shall then be settled in
accordance with the provisions of Article 26; or

ii. a Final Payment Certificate in accordance with Clause 19.15 if there are no
disputed items.

(ii) If the Authority’s Engineer does not prescribe the form referred to in Clause 19.13 (i)
within 15 (fifteen) of the date of issue of the Completion Certificate, the Contractor
shall submit the statement in such form as it deems fit.

19.14 Discharge

Upon submission of the Final Payment Statement for Works under Clause 19.13, the
Contractor shall give to the Authority, with a copy to the Authority’s Engineer, a
written discharge confirming that the total of the Final Payment Statement represents
full and final settlement of all monies due to the Contractor in respect of this
Agreement for all the Works arising out of this Agreement, except for any monies due
to either Party on account of any Defect. Provided that such discharge shall become
effective only after the payment due has been made in accordance with the Final
Payment Certificate issued pursuant to Clause 19.15.

19.15 Final Payment Certificate

(i) Within 30 (thirty) days after receipt of the Final Payment Statement for Works under
Clause 19.13, and the written discharge under Clause 19.14, and there being
nodisputed items of claim, the Authority’s Engineer shall deliver to the Authority,
with a copy to the Contractor, a final payment certificate (the “Final Payment
Certificate”)stating the amount which, in the opinion of the Authority’s Engineer, is
finally due under this Agreement or otherwise. For the avoidance of doubt, before
issuing the Final Payment Certificate, the Authority’s Engineer shall ascertain from
the Authority all amounts previously paid by the Authority and for all sums to which
the Authority is entitled, the balance, if any, due from the Authority to the Contractor
or from the Contractor to the Authority, as the case may be.

(ii) The Authority shall, in accordance with the provisions of Clause 19.9, pay to the
Contractor the amount which is stated as being finally due in the Final Payment
Certificate.

19.16 Final payment statement for Maintenance

94
(i) Within 30 (thirty) days after completion of the Maintenance Period, the Contractor
shall submit to the Authority’s Engineer 6 (six) copies of the final payment statement
for Maintenance of the Project Highway, with supporting documents showing the
details set forth below in the form prescribed by the Authority’s Engineer:

(a) the total amount claimed in accordance with clause 19.7 (i) and

(b) any sums which the Contractor considers to be due to it, with supporting
documents.

(ii) The Authority’s Engineer shall certify final payment within 30 (thirty) days of the
receipt of the final payment statement of Maintenance under Clause 19.16 (i),
segregating the items of amount payable from the items of amount disallowed. The
Authority shall make payment on the basis of the final payment authorized by the
Authority’s Engineer within a period of 30 (thirty) days of the receipt of the Final
Payment Statement from the Authority’s Engineer.

(iii) If the Authority’s Engineer does not prescribe the form within 15 (fifteen) days of the
date of issue of the Completion Certificate, the Contractor shall submit the statement
in such form as it deems fit.

19.17 Change in law

(i) If as a result of Change in Law, the Contractor suffers any additional costs in the
execution of the Works or in relation to the performance of its other obligations under
this Agreement, the Contractor shall, within 15 (fifteen) days from the date it becomes
reasonably aware of such addition in cost, notify the Authority with a copy to the
Authority’s Engineer of such additional cost due to Change in Law.

(ii) If as a result of Change in Law, the Contractor benefits from any reduction in costs for
the execution of this Agreement or in accordance with the provisions of this
Agreement, either Party shall, within 15 (fifteen) days from the date it becomes
reasonably aware of such reduction in cost, notify the other Party with a copy to the
Authority’s Engineer of such reduction in cost due to Change in Law.

(iii) The Authority’s Engineer shall, within 15 (fifteen) days from the date of receipt of the
notice from the Contractor or the Authority, determine any addition or reduction to
the Contract Price, as the case may be, due to the Change in Law.

19.18 Correction of Interim Payment Certificates

The Authority’s Engineer may by an Interim Payment Certificate make any correction
or modification in any previous Interim Payment Certificate issued by the Authority’s
Engineer.

19.19 Authority’s claims

If the Authority considers itself to be entitled to any payment from the Contractor
under any Clause of this Agreement, it shall give notice and particulars to the
Contractor 20 (twenty) days before making the recovery from any amount due to the
Contractor, and shall take into consideration the representation, if any, made by the
Contractor in this behalf, before making such recovery.

19.20 Bonus for early completion

95
In the event that the Project Completion Date occurs prior to the Scheduled
Completion Date, the Contractor shall be entitled to receive a payment of bonus
equivalent to 0.03% (zero point zero three per cent) of the Contract Price for each day
by which the Project Completion Date precedes the Scheduled Completion Date, but
subject to a maximum of 5% (five per cent) of the Contract Price. Provided, however,
that the payment of bonus, if any, shall be made only after the issue of the Completion
Certificate. For the avoidance of the doubt, the Parties agree that for the purpose of
determining the bonus payable hereunder, the works shall always be deemed to be as
specified in this Contract Agreement but excluding the works deemed to be deleted
from the scope of work under clause 8.3 of this Contract Agreement and the Contract
Price shall always be deemed to be the amount specified in Clause 19.1 (i) after
excluding the Contract Price of the Works deemed to be deleted from the Scope of
Work under clause 8.3 of this Contract Agreement, and shall exclude any revision
thereof for any reason. The Parties also agree that bonus shall be payable only if each
work for which Time Extension has been granted is completed within respective
Extended Time.

96
 Article 20

Insurance

20.1 Insurance for Works and Maintenance

(i) The Contractor shall effect and maintain at its own cost the insurances specified in
Schedule-P and as per the requirements under the Applicable Laws.

(ii) Subject to the provisions of Clause 21.6, the Authority and the Contractor shall, in
accordance with its obligations as provided for in this Agreement, be liable to bear the
cost of any loss or damage that does not fall within the scope of this Article 20 or
cannot be recovered from the insurers.

(iii) Subject to the exceptions specified in Clause 20.1 (iv) below, the Contractor shall, save
and except as provided for in this Agreement, fully indemnify, hold harmless and
defend the Authority from and against any and all losses, damages, costs, charges
and/or claims with respect to:

(a) the death of or injury to any person; or

(b) the loss of or damage to any property (other than the Works);

that may arise out of or in consequence of any breach by the Contractor of this
Agreement during the execution of the Works or the remedying of any Defects
therein.

(iv) Notwithstanding anything stated above in Clause 20.1 (iii), the Authority shall fully
indemnify the Contractor from and against any and all losses, damages, costs, charges,
proceedings and/or claims arising out of or with respect to:

(a) the use or occupation of land or any part thereof by the Authority;

(b) the right of the Authority to execute the Works, or any part thereof, on, over,
under, in or through any land;

(c) the damage to property which is the unavoidable result of the execution and
completion of the Works, or the remedying of any Defects therein, in
accordance with this Agreement; and

(d) the death of or injury to persons or loss of or damage to property resulting

from any act or neglect of the Authority, its agents, servants or other
contractors, not being employed by the Contractor.

Provided that, in the event of any injury or damage as a result of the

contributory negligence of the Contractor, the Authority shall be liable to
indemnify the Contractor from and against any and all losses, damages, costs,
charges, proceedings and/or claims to the extent as may be proportionately
determined to be the liability of the Authority, its servants or agents or other
contractors not associated with the Contractor in such injury or damage.

(v) Without prejudice to the obligations of the Parties as specified under Clauses 20.1 (iii)
and 20.1 (iv), the Contractor shall maintain or effect such third party insurances as
may be required under the Applicable Laws.
97
(vi) The Contractor shall provide to the Authority, within 30 days of the Appointed Date,
evidence of professional liability insurance maintained by its Design Director and/or
consultants to cover the risk of professional negligence in the design of Works. The
professional liability coverage shall be for a sum of not less than [3% (three per cent)]
of the Contract Price and shall be maintained until the end of the Defects Liability
Period.

20.2 Notice to the Authority

No later than 15 (fifteen) days after the date of this Agreement, the Contractor shall
by notice furnish to the Authority, in reasonable detail, information in respect of the
insurances that it proposes to effect and maintain in accordance with this Article 20.
Within 15 (fifteen) days of receipt of such notice, the Authority may require the
Contractor to effect and maintain such other insurances as may be necessary
pursuant hereto, and in the event of any difference or disagreement relating to any
such insurance, the Dispute Resolution Procedure shall apply.

20.3 Evidence of Insurance Cover

(i) All insurances obtained by the Contractor in accordance with this Article 20 shall be
maintained with insurers on terms consistent with Good Industry Practice. Within 10
(ten) days from the Appointed Date, the Contractor shall furnish to the Authority
notarized true copies of the certificate(s) of insurance, copies of insurance policies
and premia payment receipts in respect of such insurance, and no such insurance
shall be cancelled, modified, or allowed to expire or lapse until the expiration of at
least 45 (forty-five) days after notice of such proposed cancellation, modification or
non-renewal has been delivered by the Contractor to the Authority. The Contractor
shall act in accordance with the directions of the Authority. Provided that the
Contractor shall produce to the Authority the insurance policies in force and the
receipts for payment of the current premia.

(ii) The Contractor shall ensure the adequacy of the insurances at all times in accordance
with the provisions of this Agreement.

20.4 Remedy for failure to insure

If the Contractor shall fail to effect and keep in force all insurances for which it is
responsible pursuant hereto, the Authority shall have the option to either keep in
force any such insurances, and pay such premia and recover the costs thereof from
98
 the Contractor, or in the event of computation of a Termination Payment, treat an
amount equal to the Insurance Cover as deemed to have been received by the
Contractor.

20.5 Waiver of subrogation

All insurance policies in respect of the insurance obtained by the Contractor pursuant
to this Article 20 shall include a waiver of any and all rights of subrogation or
recovery of the insurers there under against, inter alia, the Authority, and its assigns,
successors, undertakings and their subsidiaries, Affiliates, employees, insurers and
underwriters, and of any right of the insurers to any set-off or counterclaim or any
other deduction, whether by attachment or otherwise, in respect of any liability of any
such person insured under any such policy or in any way connected with any loss,
liability or obligation covered by such policies of insurance.

20.6 Contractor’s waiver

The Contractor hereby further releases, assigns and waives any and all rights of
subrogation or recovery against, inter alia, the Authority and its assigns, undertakings
and their subsidiaries, Affiliates, employees, successors, insurers and underwriters,
which the Contractor may otherwise have or acquire in or from or in any way
connected with any loss, liability or obligation covered by policies of insurance
maintained or required to be maintained by the Contractor pursuant to this
Agreement (other than third party liability insurance policies) or because of
deductible clauses in or inadequacy of limits of any such policies of insurance.

20.7 Cross liabilities

Any such insurance maintained or affected in pursuance of this Article 20 shall

include a cross liability clause such that the insurance shall apply to the Contractor
and to the Authority as separately insured.

20.8 Accident or injury to workmen

Notwithstanding anything stated in this Agreement, it is hereby expressly agreed

between the Parties that the Authority shall not be liable for or in respect of any
damages or compensation payable to any workman or other person in the
employment of the Contractor or Sub-contractor, save and except as for death or
injury resulting from any act, omission or willful default of the Authority, its agents or
servants. The Contractor shall indemnify and keep indemnified the Authority from
99
 and against all such claims, proceedings, damages, costs, charges, and expenses
whatsoever in respect of the above save and except for those acts, omissions or willful
defaults for which the Authority shall be liable.

20.9 Insurance against accident to workmen

The Contractor shall effect and maintain during the Agreement such insurances as
may be required to insure the Contractor’s personnel and any other persons
employed by it on the Project Highway from and against any liability incurred in
pursuance of this Article 20. Provided that for the purposes of this Clause 20.9, the
Contractor’s personnel/any person employed by the Contractor shall include the Sub-
contractor and its personnel. It is further provided that, in respect of any
personsemployed by any Sub-contractor, the Contractor's obligations to insure as
aforesaid under this Clause 20.9 shall be discharged if the Sub-contractor shall have
insured against any liability in respect of such persons in such manner that the
Authority is indemnified under the policy. The Contractor shall require such Sub-
contractor to produce before the Authority, when required, such policy of insurance
and the receipt for payment of the current premium within 10 (ten) days of such
demand being made by the Authority.

20.10 Application of insurance proceeds

The proceeds from all insurance claims, except for life and injury, shall be applied for
any necessary repair, reconstruction, reinstatement, replacement, improvement,
delivery or installation of the Project Highway and the provisions of this Agreement in
respect of construction of works shall apply mutatis mutandis to the works
undertaken out of the proceeds of insurance.

20.11 Compliance with policy conditions

Each Party hereby expressly agrees to fully indemnify the other Party from and
against all losses and claims arising from its failure to comply with conditions
imposed by the insurance policies effected in accordance with this Agreement.

20.12 General Requirements of Insurance Policies

The Contractor must:

(a) immediately deposit copies of the policies or certificates of any insurance
which it is required to effect under the Contract, together with receipts for the
premiums;
100
(b) effect all insurances for which the Contractor is responsible with an insurer
approved by the Authority;
(c) make no material changes to the terms of any insurance without the
Authority’s approval;
(d) in all respects comply with any conditions stipulated in the insurance policies
which the Contractor is required to effect under the Agreement or which the
Authority has effected in relation to the Facility and notified to the Contractor;
and shall provide all assistance to the Authority in the application for, and
finalization of, such comprehensive insurance package;
(e) regardless of the extent of settlement of claims by the underwriters or the
time taken for settlement of claims, the Contractor shall make good any loss,
or damage at its own cost promptly;
(f) provide all assistance to the Authority in the application for, and finalization
of, such comprehensive insurance package;
(g) pay the Contractor's share of the insurance premiums for insurance premiums
allocated under such comprehensive insurance package policy tothe
insurances directly to the insurance provider promptly on demand. In case the
Contractor fails to make such payment in time, the Authority may elect to pay
the Contractor's share and adjust it against amounts payable to the Contractor
under this Agreement;
(h) in the case of occurrence of any event leading to an insurance claim, promptly
follow the procedures specified by the insurance provider, and provide full
cooperation and access to the insurance provider or its representative, to
settle the claim expeditiously;
(i) require all the Sub-Contractors providing equipment and materials or services
to the Contractor or the Authority to obtain, maintain and keep in force during
the time in which they are involved in the performance of the Works
hereunder insurance coverage consistent with the Contractor's insurance
obligations hereunder and the Contractor shall also be responsible for
fulfillment of this requirement; and
(j) the required insurance coverage and the Contractor's obligations-referred to
shall in no way affect or limit the Contractor's liability with respect to its
performance of the Works. Nothing in this Section shall limit or relieve the
Contractor of its liabilities and obligations under this Agreement.

101
 Part V

Force Majeure and Termination

102
 Article 21

Force Majeure

21.1 Force Majeure

As used in this Agreement, the expression “Force Majeure” or “Force Majeure Event”
shall mean occurrence in India of any or all of Non-Political Event, Indirect Political
Event and Political Event, as defined in Clauses 21.2, 21.3 and 21.4 respectively, if it
affects the performance by the Party claiming the benefit of Force Majeure (the
“Affected Party”) of its obligations under this Agreement and which act or event (i) is
beyond the reasonable control of the Affected Party, and (ii) the Affected Party could
not have prevented or overcome by exercise of due diligence and following Good
Industry Practice, and (iii) has Material Adverse Effect on the Affected Party.

21.2 Non-Political Event

A Non-Political Event shall mean one or more of the following acts or events:

(a) act of God, epidemic, extremely adverse weather conditions, lightning,

earthquake, landslide, cyclone, flood, volcanic eruption, chemical or
radioactive contamination or ionizing radiation, fire or explosion (to the
extent of contamination or radiation or fire or explosion originating from a
source external to the Site);

(b) strikes or boycotts (other than those involving the Contractor, Sub-
contractors or their respective employees/ representatives, or attributable to
any act or omission of any of them) interrupting supplies and services to the
Project Highway for a continuous period of 24 (twenty-four) hours and an
aggregate period exceeding 10 (ten) days in an Accounting Year, and not being
an Indirect Political Event set forth in Clause 21.3;

(c) any failure or delay of a Sub-contractor but only to the extent caused by
another Non-Political Event;

(d) any judgment or order of any court of competent jurisdiction or statutory

authority made against the Contractor in any proceedings for reasons other
than (i) failure of the Contractor to comply with any Applicable Law or
Applicable Permit, or (ii) on account of breach of any Applicable Law or
Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or
(iv) exercise of any of its rights under this Agreement by the Authority;

(e) the discovery of geological conditions, toxic contamination or archaeological

remains on the Site that could not reasonably have been expected to be
discovered through a site inspection; or
(f) any event or circumstances of a nature analogous to any of the foregoing.

21.3 Indirect Political Event

An Indirect Political Event shall mean one or more of the following acts or events:

103
 (a) an act of war (whether declared or undeclared), invasion, armed conflict or
act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or
military action, civil commotion or politically motivated sabotage;

(b) industry-wide or State-wide strikes or industrial action for a continuous

period of 24 (twenty-four) hours and exceeding an aggregate period of 10
(ten) days in an Accounting Year;

(c) any civil commotion, boycott or political agitation which prevents

construction of the Project Highway by the Contractor for an aggregate period
exceeding 10 (ten) days in an Accounting Year;

(d) any failure or delay of a Sub-contractor to the extent caused by any Indirect
Political Event;
(e) any Indirect Political Event that causes a Non-Political Event; or
(f) any event or circumstances of a nature analogous to any of the foregoing.

21.4 Political Event

A Political Event shall mean one or more of the following acts or events by or on
account of any Government Instrumentality:

(a) Change in Law, only if consequences thereof cannot be dealt with under and in
accordance with the provisions of Clause 19.17;

(b) compulsory acquisition in national interest or expropriation of any Project

Assets or rights of the Contractor or of the Sub-Contractors;

(c) unlawful or unauthorized or without jurisdiction revocation of, or refusal to

renew or grant without valid cause, any clearance, license, permit,
authorization, no objection certificate, consent, approval or exemption
required by the Contractor or any of the Sub-contractors to perform their
respective obligations under this Agreement; provided that such delay,
modification, denial, refusal or revocation did not result from the Contractor’s
or any Sub-contractor’s inability or failure to comply with any condition
relating to grant, maintenance or renewal of such clearance, license,
authorization, no objection certificate, exemption, consent, approval or
permit;

(d) any failure or delay of a Sub-contractor but only to the extent caused by
another Political Event; or
(e) any event or circumstances of a nature analogous to any of the foregoing.

21.5 Duty to report Force Majeure Event

(i) Upon occurrence of a Force Majeure Event, the Affected Party shall by notice report
such occurrence to the other Party forthwith. Any notice pursuant hereto shall include
full particulars of:

104
 (a) the nature and extent of each Force Majeure Event which is the subject of any
claim for relief under this Article 21 with evidence in support thereof;

(b) the estimated duration and the effect or probable effect which such Force
Majeure Event is having or will have on the Affected Party’s performance of its
obligations under this Agreement;

(c) the measures which the Affected Party is taking or proposes to take for
alleviating the impact of such Force Majeure Event; and
(d) any other information relevant to the Affected Party’s claim.

(ii) The Affected Party shall not be entitled to any relief for or in respect of a Force
Majeure Event unless it shall have notified the other Party of the occurrence of the
Force Majeure Event as soon as reasonably practicable, and in any event no later than
10 (ten) days after the Affected Party knew, or ought reasonably to have known, of its
occurrence, and shall have given particulars of the probable material effect that the
Force Majeure Event is likely to have on the performance of its obligations under this
Agreement.

(iii) For so long as the Affected Party continues to claim to be materially affected by such
Force Majeure Event, it shall provide the other Party with regular (and not less than
weekly) reports containing information as required by Clause 21.5 (i), and such other
information as the other Party may reasonably request the Affected Party to provide.

21.6 Effect of Force Majeure Event on the Agreement

(i) Upon the occurrence of any Force Majeure after the Appointed Date, the costs
incurred and attributable to such event and directly relating to this Agreement (the
“Force Majeure costs”) shall be allocated and paid as follows:

(a) upon occurrence of a Non-Political Event, the Parties shall bear their
respective Force Majeure costs and neither Party shall be required to pay to
the other Party any costs thereof;

(b) upon occurrence of an Indirect Political Event, all Force Majeure costs
attributable to such Indirect Political Event, and not exceeding the Insurance
Cover for such Indirect Political Event, shall be borne by the Contractor, and to
the extent Force Majeure costs exceed such Insurance Cover, one half of such
excess amount shall be reimbursed by the Authority to the Contractor for the
Force Majeure events; and

(c) upon occurrence of a Political Event, all Force Majeure costs attributable to
such Political Event shall be reimbursed by the Authority to the Contractor.

(d) For the avoidance of doubt, Force Majeure costs may include costs directly
attributable to the Force Majeure Event, but shall not include debt repayment
obligations, if any, of the Contractor.

(ii) Save and except as expressly provided in this Article 21, neither Party shall be liable
in any manner whatsoever to the other Party in respect of any loss, damage, cost,

105
 expense, claims, demands and proceedings relating to or arising out of occurrence or
existence of any Force Majeure Event or exercise of any right pursuant hereto.

(iii) Upon the occurrence of any Force Majeure Event during the Construction Period, the
Project Completion Schedule for and in respect of the affected Works shall be
extended on a day for day basis for such period as performance of the Contractor’s
obligations is affected on account of the Force Majeure Event or its subsisting effects.

21.7 Termination Notice for Force Majeure Event

(i) If a Force Majeure Event subsists for a period of 60 (sixty) days or more within a
continuous period of 120 (one hundred and twenty) days, either Party may in its
discretion terminate this Agreement by issuing a Termination Notice to the other
Party without being liable in any manner whatsoever, save as provided in this Article
21, and upon issue of such Termination Notice, this Agreement shall, notwithstanding
anything to the contrary contained herein, stand terminated forthwith; provided that
before issuing such Termination Notice, the Party intending to issue the Termination
Notice shall inform the other Party of such intention and grant 15 (fifteen) days’ time
to make a representation, and may after the expiry of such 15 (fifteen) days period,
whether or not it is in receipt of such representation, in its sole discretion issue the
Termination Notice.

21.8 Termination Payment for Force Majeure Event

(i) In the event of this Agreement being terminated on account of a Non-Political Event,
the Termination Payment shall be an amount equal to the sum payable under Clause
23.5.

Provided that in the event Termination occurs during the Maintenance Period, the
Authority’s Engineer shall only determine the value of Works associated with
Maintenance.

(ii) If Termination is on account of an Indirect Political Event, the Termination Payment

shall include:

(a) any sums due and payable under Clause 23.5; and

(b) the reasonable cost, as determined by the Authority’s Engineer, of the Plant
and Materials procured by the Contractor and transferred to the Authority for
use in Construction or Maintenance, only if such Plant and Materials are in
conformity with the Specifications and Standards;

Provided that in the event Termination occurs during the Maintenance Period, the
Authority’s Engineer shall only determine the value of Works associated with
Maintenance.

(iii) If Termination is on account of a Political Event, the Authority shall make a

Termination Payment to the Contractor in an amount that would be payable under
Clause 23.6 (ii) as if it were an Authority Default.

106
21.9 Dispute resolution

In the event that the Parties are unable to agree in good faith about the occurrence or
existence of a Force Majeure Event, such Dispute shall be finally settled in accordance
with the Dispute Resolution Procedure; provided that the burden of proof as to the
occurrence or existence of such Force Majeure Event shall be upon the Party claiming
relief and/ or excuse on account of such Force Majeure Event.

21.10 Excuse from performance of obligations

If the Affected Party is rendered wholly or partially unable to perform its obligations
under this Agreement because of a Force Majeure Event, it shall be excused from
performance of such of its obligations to the extent it is unable to perform on account
of such Force Majeure Event; provided that:

(a) the suspension of performance shall be of no greater scope and of no longer

duration than is reasonably required by the Force Majeure Event;

(b) the Affected Party shall make all reasonable efforts to mitigate or limit damage
to the other Party arising out of or as a result of the existence or occurrence of
such Force Majeure Event and to cure the same with due diligence; and

(c) when the Affected Party is able to resume performance of its obligations
under this Agreement, it shall give to the other Party notice to that effect and
shall promptly resume performance of its obligations hereunder.

107
 Article 22

Suspension of Contractor’s Rights

22.1 Suspension upon Contractor Default

Upon occurrence of a Contractor Default, the Authority shall be entitled, without

prejudice to its other rights and remedies under this Agreement including its rights of
Termination hereunder, to (i) suspend carrying out of the Works or Maintenance or
any part thereof, and (ii) carry out such Works or Maintenance itself or authorise any
other person to exercise or perform the same on its behalf during such suspension
(the “Suspension”). Suspension hereunder shall be effective forthwith upon issue of
notice by the Authority to the Contractor and may extend up to a period not exceeding
90 (ninety) days from the date of issue of such notice.

22.2 Authority to act on behalf of Contractor

During the period of Suspension hereunder, all rights and liabilities vested in the
Contractor in accordance with the provisions of this Agreement shall continue to vest
therein and all things done or actions taken, including expenditure incurred by the
Authority for discharging the obligations of the Contractor under and in accordance
with this Agreement shall be deemed to have been done or taken for and on behalf of
the Contractor and the Contractor undertakes to indemnify the Authority for all costs
incurred during such period. The Contractor hereby licenses and sub-licenses
respectively, the Authority or any other person authorized by it under Clause 22.1 to
use during Suspension, all Intellectual Property belonging to or licensed to the
Contractor with respect to the Project Highway and its design, engineering,
construction and maintenance, and which is used or created by the Contractor in
performing its obligations under the Agreement.

22.3 Revocation of Suspension

(i) In the event that the Authority shall have rectified or removed the cause of
Suspension within a period not exceeding 60 (sixty) days from the date of Suspension,
it shall revoke the Suspension forthwith and restore all rights of the Contractor under
this Agreement. For the avoidance of doubt, the Parties expressly agree that the
Authority may, in its discretion, revoke the Suspension at any time, whether or not the
cause of Suspension has been rectified or removed hereunder.

(ii) Upon the Contractor having cured the Contractor Default within a period not
exceeding 60 (sixty) days from the date of Suspension, the Authority shall revoke the
Suspension forthwith and restore all rights of the Contractor under this Agreement.

22.4 Termination

(i) At any time during the period of Suspension under this Article 22, the Contractor may
by notice require the Authority to revoke the Suspension and issue a Termination

108
 Notice. The Authority shall, within 15 (fifteen) days of receipt of such notice,
terminate this Agreement under and in accordance with Article 23.

(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event
that Suspension is not revoked within 90 (ninety) days from the date of Suspension
hereunder, the Agreement shall, upon expiry of the aforesaid period, be deemed to
have been terminated by mutual agreement of the Parties and all the provisions of
this Agreement shall apply, mutatis mutandis, to such Termination as if a Termination
Notice had been issued by the Authority upon occurrence of a Contractor Default.

109
 Article 23

Termination

23.1 Termination for Contractor Default

(i) Save as otherwise provided in this Agreement, in the event that any of the defaults
specified below shall have occurred, and the Contractor fails to cure the default within
the Cure Period set forth below, or where no Cure Period is specified, then within a
Cure Period of 60 (sixty) days, the Contractor shall be deemed to be in default of this
Agreement (the “Contractor Default”), unless the default has occurred solely as a
result of any breach of this Agreement by the Authority or due to Force Majeure. The
defaults referred to herein shall include:

(a) the Contractor fails to provide, extend or replenish, as the case may be, the
Performance Security in accordance with this Agreement;

(b) after the replenishment or furnishing of fresh Performance Security in

accordance with Clause 7.3, the Contractor fails to cure, within a Cure Period
of 30 (thirty) days, the Contractor Default for which the whole or part of the
Performance Security was appropriated;

(c) the Contractor does not achieve the latest outstanding Project Milestone due
in accordance with the provisions of Schedule-J, subject to any Time
Extension, and continues to be in default for 45 (forty five) days;

(d) the Contractor abandons or manifests intention to abandon the construction

or Maintenance of the Project Highway without the prior written consent of
the Authority;

(e) the Contractor fails to proceed with the Works in accordance with the
provisions of Clause 10.1 or stops Works and/or the Maintenance for 30
(thirty) days without reflecting the same in the current programme and such
stoppage has not been authorized by the Authority’s Engineer;

(f) the Project Completion Date does not occur within the period specified in
Schedule-J for the Scheduled Completion Date, or any extension thereof;

(g) the Contractor fails to rectify any Defect, the non-rectification of which shall
have a Material Adverse Effect on the Project, within the time specified in this
Agreement or as directed by the Authority’s Engineer;

(h) the Contractor subcontracts the Works or any part thereof in violation of this
Agreement or assigns any part of the Works or the Maintenance without the
prior approval of the Authority;
(i) the Contractor creates any Encumbrance in breach of this Agreement;

(j) an execution levied on any of the assets of the Contractor has caused a
Material Adverse Effect;

110
(k) the Contractor is adjudged bankrupt or insolvent, or if a trustee or receiver is
appointed for the Contractor or for the whole or material part of its assets
that has a material bearing on the Project;

(l) the Contractor has been, or is in the process of being liquidated, dissolved,
wound-up, amalgamated or reconstituted in a manner that would cause, in the
reasonable opinion of the Authority, a Material Adverse Effect;

(m) a resolution for winding up or insolvency of the Contractor is passed, or any

petition for winding up or insolvency of the Contractor is admitted by a court
of competent jurisdiction and a provisional liquidator or receiver or interim
resolution professional, as the case may be, is appointed and such order has
not been set aside within 90 (ninety) days of the date thereof or the
Contractor is ordered to be wound up by court except for the purpose of
amalgamation or reconstruction; provided that, as part of such amalgamation
or reconstruction, the entire property, assets and undertaking of the
Contractor are transferred to the amalgamated or reconstructed entity and
that the amalgamated or reconstructed entity has unconditionally assumed
the obligations of the Contractor under this Agreement; and provided that:

i. the amalgamated or reconstructed entity has the capability and

experience necessary for the performance of its obligations under this
Agreement; and

ii. the amalgamated or reconstructed entity has the financial standing to

perform its obligations under this Agreement and has a credit worthiness
at least as good as that of the Contractor as at the Appointed Date;

(n) any representation or warranty of the Contractor herein contained which is,
as of the date hereof, found to be false or the Contractor is at any time
hereafter found to be in breach or non-compliance thereof;

(o) the Contractor submits to the Authority any statement, notice or other
document, in written or electronic form, which has a material effect on the
Authority’s rights, obligations or interests and which is false in material
particulars;

(p) the Contractor has failed to fulfill any obligation, for which failure
Termination has been specified in this Agreement; or

(q) the Contractor commits a default in complying with any other provision of this
Agreement if such a default causes a Material Adverse Effect on the Project or
on the Authority.

(r) gives or offers to give (directly or indirectly) to any person any bribe, gift,
gratuity, commission or other thing of value, as an inducement or reward:
i. for doing or forbearing to do any action in relation to the Contract, or

ii. for showing or forbearing to show favour or disfavour to any person in

relation to the Contract,

or if any of the Contractor’s personnel, agents or subcontractors gives or

offers to give (directly or indirectly) to any person any such inducement or
reward as is described in this sub-paragraph (s). However, lawfulinducements
and rewards to Contractor’s Personnel shall not entitle termination.

111
(ii) Without prejudice to any other rights or remedies which the Authority may have
under this Agreement, upon occurrence of a Contractor Default, the Authority shall be
entitled to terminate this Agreement by issuing a Termination Notice to the
Contractor; provided that before issuing the Termination Notice, the Authority shall
by a notice inform the Contractor of its intention to issue such Termination Notice and
grant 15 (fifteen) days to the Contractor to make a representation, and may after the
expiry of such 15 (fifteen) days, whether or not it is in receipt of such representation,
issue the Termination Notice.

(iii) The following shall apply in respect of cure of any of the defaults and/ or breaches of
the Agreement:

(a) The Cure Period shall commence from the date of the notice by the Authority
to the Contractor asking the latter to cure the breach or default specified in
such notice;

(b) The Cure Period provided in the Agreement shall not relieve the Contractor
from liability for Damages caused by its breach or default;

(c) The Cure Period shall not in any way be extended by any period of suspension
under the Agreement;

(d) If the cure of any breach by the Contractor requires any reasonable action by
the Contractor that must be approved by the Authority hereunder the
applicable Cure Period (and any liability of the Contractor for damages
incurred) shall be extended by the period taken by the Authority to accord its
required approval.

(iv) After termination of this Agreement for Contractor Default, the Authority may
complete the Works and/or arrange for any other entities to do so. The Authority and
these entities may then use any Materials, Plant and equipment, Contractor’s
documents and other design documents made by or on behalf of the Contractor.

23.2 Termination for Authority Default

(i) In the event that any of the defaults specified below shall have occurred, and the
Authority fails to cure such default within a Cure Period of 90 (ninety) days or such
longer period as has been expressly provided in this Agreement, the Authority shall
be deemed to be in default of this Agreement (the “Authority Default”) unless the
default has occurred as a result of any breach of this Agreement by the Contractor or
due to Force Majeure. The defaults referred to herein shall include:

(a) the Authority commits a material default in complying with any of the
provisions of this Agreement and such default has a Material Adverse Effect on
the Contractor;

112
 (b) the Authority has failed to make payment of any amount due and payable to
the Contractor within the period specified in this Agreement;

(c) the Authority has failed to provide, within a period of 180 (one hundred and
eighty) days from the Appointed Date, the environmental clearances required
for construction of the Project Highway;

(d) the Authority becomes bankrupt or insolvent, goes into liquidation, has a
receiving or administration order made against him, compounds with its
creditors, or carries on business under a receiver, trustee or manager for the
benefit of its creditors, or if any act is done or event occurs which (under
Applicable Laws) has a similar effect;

(e) the Authority repudiates this Agreement or otherwise takes any action that
amounts to or manifests an irrevocable intention not to be bound by this
Agreement;

(f) the Authority’s Engineer fails to issue the relevant Interim Payment Certificate
within 60 (sixty) days after receiving a statement and supporting documents;
or

(g) the whole work is suspended by Authority beyond 120 (one hundred twenty)
days for any reason which is not attributed to the Contractor.

(ii) Without prejudice to any other right or remedy which the Contractor may have under
this Agreement, upon occurrence of an Authority Default, the Contractor shall be
entitled to terminate this Agreement by issuing a Termination Notice to the Authority;
provided that before issuing the Termination Notice, the Contractor shall by a notice
inform the Authority of its intention to issue the Termination Notice and grant 15
(fifteen) days to the Authority to make a representation, and may after the expiry of
such 15 (fifteen) days, whether or not it is in receipt of such representation, issue the
Termination Notice.

If on the consideration of the Authority’s representation or otherwise, the contractor

does not issue the Termination Notice on such 15th (fifteenth) day and prefers to
continue with the project, it is deemed that the cause of action of the Termination
Notice has been condoned by the Contractor and he would be deemed to have waived
any claim and forfeited any right to any other remedy on that count or in relation to
such action or omission.

23.3 Termination for Authority’s convenience

Notwithstanding anything stated hereinabove, the Authority may terminate this

Agreement for convenience. The termination shall take effect 30 (thirty) days from
the date of notice provided to the Contractor.

23.4 Requirements after Termination

Upon Termination of this Agreement in accordance with the terms of this Article 23,
the Contractor shall comply with and conform to the following:

113
 (a) deliver all relevant records, reports, Intellectual Property and other licences
pertaining to the Works, Maintenance, other design documents;

(b) transfer and/or deliver all Applicable Permits to the extent permissible under
Applicable Laws; and
(c) vacate the Site within 15 (fifteen) days.

23.5 Valuation of Unpaid Works

(i) Within a period of 45 (forty-five) days after Termination under Clause 23.1, 23.2 or
23.3, as the case may be, has taken effect, the Authority’s Engineer shall proceed in
accordance with Clause 18.5 to determine as follows the valuation of unpaid Works
(the “Valuation of Unpaid Works”):

(a) value of the completed stage of the Works, less payments already made;

(b) reasonable value of the partially completed stages of works as on the date of
Termination, only if such works conform with the Specifications and
Standards; and

(c) value of Maintenance, if any, for completed months, less payments already
made, and shall adjust from the sum thereof (i) any other amounts payable or
recoverable, as the case may be, in accordance with the provisions of this
Agreement; and (ii) all taxes due to be deducted at source.

(ii) The Valuation of Unpaid Works shall be communicated to the Authority, with a copy
to the Contractor, within a period of 30 (thirty) days from the date of Termination.

23.6 Termination Payment

(i) Upon Termination on account of Contractor’s Default under Clause 23.1, the Authority
shall:

(a) encash and appropriate the Performance Security, Additional Performance

Security if any and Retention Money, or in the event the Contractor has failed
to replenish or extend the Performance Security and Additional Performance
Security if any, claim the amount stipulated in Clause 7.1, as agreed pre-
determined compensation to the Authority for any losses, delays and cost of
completing the Works and Maintenance, if any;

(b) encash and appropriate the Bank Guarantee, if any, for and in respect of the
outstanding Advance Payment and interest thereon; and

(c) pay to the Contractor, by way of Termination Payment, an amount equivalent

to the Valuation of Unpaid Works after adjusting any other sums payable or
recoverable, as the case may be, in accordance with the provisions of this
Agreement.

(ii) Upon Termination on account of an Authority Default under Clause 23.2 or for
Authority’s convenience under Clause 23.3, the Authority shall:

114
 (a) return the Performance Security, Additional Performance Security and
Retention Money forthwith;

(b) encash and appropriate the bank guarantee, if any, for and in respect of the
outstanding Advance Payment; and
(c) pay to the Contractor, by way of Termination Payment, an amount equal to:
i. Valuation of Unpaid Works;

ii. the reasonable cost of temporary works, as determined by the Authority’s

Engineer; and

iii. 10% (ten per cent) of the cost of the Works and Maintenance that are not
commenced or not completed,

and shall adjust from the sum thereof (i) any other amounts payable or
recoverable, as the case may be, in accordance with the provisions of this
Agreement, and (ii) all taxes due to be deducted at source.

(iii) Termination Payment shall become due and payable to the Contractor within 30
(thirty) days of a demand being made by the Contractor to the Authority with the
necessary particulars, and in the event of any delay, the Authority shall pay interest at
Bank Rate + 3% per annum, on the amount of Termination Payment remaining
unpaid; provided that such delay shall not exceed 90 (ninety) days. For the avoidance
of doubt, it is expressly agreed that Termination Payment shall constitute full
discharge by the Authority of its payment obligations in respect thereof hereunder.

(iv) The Contractor expressly agrees that Termination Payment under this Article 23 shall
constitute a full and final settlement of all claims of the Contractor on account of
Termination of this Agreement and that it shall not have any further right or claim
under any law, treaty, convention, contract or otherwise.

23.7 Other rights and obligations of the Parties

Upon Termination for any reason whatsoever:

(a) property and ownership in all Materials, Plant and Works and the Project
Highway shall, as between the Contractor and the Authority, vest in the
Authority in whole; provided that the foregoing shall be without prejudice to
Clause 23.6;

(b) risk of loss or damage to any Materials, Plant or Works and the care and
custody thereof shall pass from the Contractor to the Authority; and

(c) the Authority shall be entitled to restrain the Contractor and any person
claiming through or under the Agreement from entering upon the Site or any
part of the Project, which have not been vested in the Authority in accordance
with the provisions of this Agreement.

115
23.8 Survival of rights

Notwithstanding anything to the contrary contained in this Agreement any

Termination pursuant to the provisions of this Agreement shall be without prejudice
to the accrued rights of either Party including its right to claim and recover money
damages, insurance proceeds, security deposits, and other rights and remedies, which
it may have in law or Agreement. All rights and obligations of either Party under this
Agreement, including Termination Payments, shall survive the Termination to the
extent such survival is necessary for giving effect to such rights and obligations.

23.9 Foreclosure with mutual consent

(i) Without prejudice to any provision of this Agreement, the Authority and Contractor
may foreclose this Agreement by mutual consent in circumstances which does not
constitute either party’s default without any liability or consequential future liability
for either party.

(ii) Should a Party intend to foreclose this Agreement by mutual consent, the intending
Party shall issue a notice to the other Party and upon issuance of such notice, the
other Party may within 15 days from receipt of such notice either agree to such
foreclosure or raise objection(s) to the same by intimating either of the two possible
positions to the intending Party in writing.

(iii) In either case of the other Party agreeing to the proposed foreclosure or otherwise,
the Parties may negotiate the proposed foreclosure and sign a Supplementary
Agreement for foreclosure to the main Contract Agreement within 30 (thirty) days of
the date agreeing by both Parties. Foreclosure shall not come into effect unless and
otherwise Supplementary Agreement is signed.

(iv) Any attempt or endeavor for foreclosure by mutual agreement shall be without
prejudice to the rights and obligations of the Parties herein and the factum of such an
attempt or exercise shall not stop either of the Parties from discharging their
contractual obligations under this Agreement.

(v) For the avoidance of doubt, it is clarified that such foreclosure will be without
prejudice to the Contractor and shall not affect the Contractor in any way if it wishes
to bid in future projects of the Authority.

116
 Part VI

Other Provisions

117
 Article 24

Assignment and Charges

24.1 Restrictions on assignment and charges

This Agreement shall not be assigned by the Contractor to any person, save and
except with the prior consent in writing of the Authority, which consent the Authority
shall be entitled to decline without assigning any reason.

24.2 Hypothecation of Materials or Plant

Notwithstanding the provisions of Clause 24.1, the Contractor may pledge or

hypothecate to its lenders, any Materials or Plant prior to their incorporation in the
Works. Further, the Contractor may, by written notice to the Authority, assign its right
to receive payments under this Agreement either absolutely or by way of charge, to
any person providing financing to the Contractor in connection with the performance
of the Contractor’s obligations under this Agreement. The Contractor acknowledges
that any such assignment by the Contractor shall not relieve the Contractor from any
obligations, duty or responsibility under this Agreement.

118
 Article 25

Liability and Indemnity

25.1 General indemnity

(i) The Contractor will indemnify, defend, save and hold harmless the Authority and its
officers, servants, agents, Government Instrumentalities and Government owned
and/or controlled entities/enterprises, (the “Authority Indemnified Persons”) against
any and all suits, proceedings, actions, demands and third party claims for any loss,
damage, cost and expense of whatever kind and nature, whether arising out of any
breach by the Contractor of any of its obligations under this Agreement or from any
negligence under the Agreement, including any errors or deficiencies in the design
documents, or tort or on any other ground whatsoever, except to the extent that any
such suits, proceedings, actions, demands and claims have arisen due to any negligent
act or omission, or breach or default of this Agreement on the part of the Authority
Indemnified Persons.

25.2 Indemnity by the Contractor

(i) Without limiting the generality of Clause 25.1, the Contractor shall fully indemnify,
hold harmless and defend the Authority and the Authority Indemnified Persons from
and against any and all loss and/or damages arising out of or with respect to:

(a) failure of the Contractor to comply with Applicable Laws and Applicable
Permits;

(b) payment of taxes required to be made by the Contractor in respect of the

income or other taxes of the Sub-contractors, suppliers and representatives;
or

(c) non-payment of amounts due because of Materials or services furnished to

the Contractor or any of its Sub-contractors which are payable by the
Contractor or any of its Sub-contractors.

(ii) Without limiting the generality of the provisions of this Article 25, the Contractor shall
fully indemnify, hold harmless and defend the Authority Indemnified Persons from
and against any and all suits, proceedings, actions, claims, demands, liabilities and
damages which the Authority Indemnified Persons may hereafter suffer, or pay by
reason of any demands, claims, suits or proceedings arising out of claims of
infringement of any domestic or foreign patent rights, copyrights or other intellectual
property, proprietary or confidentiality rights with respect to any materials,
information, design or process used by the Contractor or by the Sub-contractors in
performing the Contractor’s obligations or in any way incorporated in or related to
the Project. If in any such suit, action, claim or proceedings, a temporary restraint
order or preliminary injunction is granted, the Contractor shall make every
reasonable effort, by giving a satisfactory bond or otherwise, to secure the
revocationor suspension of the injunction or restraint order. If, in any such suit,
action, claim or proceedings, the Project Highway, or any part thereof or comprised
therein, is held to constitute an infringement and its use is permanently enjoined, the
Contractor shall promptly make every reasonable effort to secure for the Authority a

119
 license, at no cost to the Authority, authorizing continued use of the infringing work. If
the Contractor is unable to secure such license within a reasonable time, the
Contractor shall, at its own expense, and without impairing the Specifications and
Standards, either replace the affected work, or part, or process thereof with non-
infringing work or part or process or modify the same so that it becomes non-
infringing.

25.3 Notice and contest of claims

In the event that either Party receives a claim or demand from a third party in respect
of which it is entitled to the benefit of an indemnity under this Article 25 (the
“Indemnified Party”) it shall notify the other Party (the “Indemnifying Party”) within
15 (fifteen) days of receipt of the claim or demand and shall not settle or pay the claim
without the prior approval of the Indemnifying Party, which approval shall not be
unreasonably withheld or delayed. If the Indemnifying Party wishes to contest or
dispute the claim or demand, it may conduct the proceedings in the name of the
Indemnified Party, subject to the Indemnified Party being secured against any costs
involved, to its reasonable satisfaction.

25.4 Defence of claims

(i) The Indemnified Party shall have the right, but not the obligation, to contest, defend
and litigate any claim, action, suit or proceeding by any third party alleged or asserted
against such Party in respect of, resulting from, related to or arising out of any matter
for which it is entitled to be indemnified hereunder, and reasonable costs and
expenses thereof shall be indemnified by the Indemnifying Party. If the Indemnifying
Party acknowledges in writing its obligation to indemnify the Indemnified Party in
respect of loss to the full extent provided by this Article 25, the Indemnifying Party
shall be entitled, at its option, to assume and control the defense of such claim, action,
suit or proceeding, liabilities, payments and obligations at its expense and through the
counsel of its choice; provided it gives prompt notice of its intention to do so to the
Indemnified Party and reimburses the Indemnified Party for the reasonable cost and
expenses incurred by the Indemnified Party prior to the assumption by the
Indemnifying Party of such defence. The Indemnifying Party shall not be entitled to
settle or compromise any claim, demand, action, suit or proceeding without the prior
written consent of the Indemnified Party, unless the Indemnifying Party provides
such security to the Indemnified Party as shall be reasonably required by the
Indemnified Party to secure the loss to be indemnified hereunder to the extent so
compromised or settled.

(ii) If the Indemnifying Party has exercised its rights under Clause 25.3, the Indemnified
Party shall not be entitled to settle or compromise any claim, action, suit or
proceeding without the prior written consent of the Indemnifying Party (which
consent shall not be unreasonably withheld or delayed).

120
(iii) If the Indemnifying Party exercises its rights under Clause 25.3, the Indemnified Party
shall nevertheless have the right to employ its own counsel, and such counsel may
participate in such action, but the fees and expenses of such counsel shall be at the
expense of the Indemnified Party, when and as incurred, unless:

(a) the employment of counsel by such party has been authorized in writing by
the Indemnifying Party; or

(b) the Indemnified Party shall have reasonably concluded that there may be a
conflict of interest between the Indemnifying Party and the Indemnified Party
in the conduct of the defense of such action; or

(c) the Indemnifying Party shall not, in fact, have employed independent counsel
reasonably satisfactory to the Indemnified Party, to assume the defense of
such action and shall have been so notified by the Indemnified Party; or

(d) the Indemnified Party shall have reasonably concluded and specifically
notified the Indemnifying Party either:
i. that there may be specific defenses available to it which are different from
or additional to those available to the Indemnifying Party; or
ii. that such claim, action, suit or proceeding involves or could have a
material adverse effect upon it beyond the scope of this Agreement:

Provided that if Sub-clauses (b), (c) or (d) of this Clause 25.4 (iii) shall be applicable,
the counsel for the Indemnified Party shall have the right to direct the defense of such
claim, demand, action, suit or proceeding on behalf of the Indemnified Party, and the
reasonable fees and disbursements of such counsel shall constitute legal or other
expenses hereunder.

25.5 Survival on Termination

The provisions of this Article 25 shall survive Termination.

121
 Article 26

Dispute Resolution

26.1 Dispute Resolution

(i) Any dispute, difference or controversy of whatever nature howsoever arising under
or out of or in relation to this Agreement (including its interpretation) between the
Parties, and so notified in writing by either Party to the other Party (the “Dispute”)
shall, in the first instance, be attempted to be resolved amicably in accordance with
the conciliation procedure set forth in Clause 26.2.

(ii) The Parties agree to use their best efforts for resolving all Disputes arising under or in
respect of this Agreement promptly, equitably and in good faith, and further agree to
provide each other with reasonable access during normal business hours to all non-
privileged records, information and data pertaining to any Dispute.

26.2 Conciliation

In the event of any Dispute between the Parties, either Party may call upon the
Authority’s Engineer, or such other person as the Parties may mutually agree upon
(the “Conciliator”) to mediate and assist the Parties in arriving at an amicable
settlement thereof. Failing mediation by the Conciliator or without the intervention of
the Conciliator, either Party may require such Dispute to be referred to the Chairman
of the Authority and the Chairman of the Board of Directors of the Contractor for
amicable settlement, and upon such reference, the said persons shall meet no later
than 7 (seven) business days from the date of reference to discuss and attempt to
amicably resolve the Dispute. If such meeting does not take place within the 30
(thirty) business day period or the Dispute is not amicably settled within 30 (thirty)
days of the meeting or the Dispute is not resolved as evidenced by the signing of
written terms of settlement within 30 (thirty) days of the notice in writing referred to
in Clause 26.1.1 or such longer period as may be mutually agreed by the Parties,
either Party may refer the Dispute to arbitration in accordance with the provisions of
Clause 26.3 but before resorting to such arbitration, the parties agree to explore
conciliation by the Conciliation Committees of Independent Experts set up by the
Authority in accordance with the procedure decided by the panel of such experts and
notified by the Authority on its website including its subsequent amendments. In the
event of the conciliation proceedings being successful, the parties to the dispute
would sign the written settlement agreement and the conciliators would authenticate
the same. Such settlement agreement would then be binding on the parties in terms of
Section 73 of the Arbitration Act. In case of failure of the conciliation process even at
the level of the Conciliation Committee, either party may refer the Dispute to
arbitration in accordance with the provisions of Clause 26.3.

26.3 Arbitration

(i) Any dispute which remains unresolved between the parties through the mechanisms
available/ prescribed in the Agreement, irrespective of any claim value, which has not

122
 been agreed upon/ reached settlement by the parties, will be referred to the Arbitral
Tribunal as per the Arbitration and Conciliation Act.

(ii) Deleted

(iii) The Arbitral Tribunal shall make a reasoned award (the “Award”). Any Award made
in any arbitration held pursuant to this Article 26 shall be final and binding on the
Parties as from the date it is made, and the Contractor and the Authority agree and
undertake to carry out such Award without delay.

(iv) The Contractor and the Authority agree that an Award may be enforced against the
Contractor and/or the Authority, as the case may be, and their respective assets
wherever situated.

(v) This Agreement and the rights and obligations of the Parties shall remain in full force
and effect, pending the Award in any arbitration proceedings hereunder. Further, the
parties unconditionally acknowledge and agree that notwithstanding any dispute
between them, each Party shall proceed with the performance of its respective
obligations, pending resolution of Dispute in accordance with this Article.

(vi) In the event the Party against whom the Award has been granted challenges the
Award for any reason in a court of law, it shall make an interim payment to the other
Party for an amount equal to 75% (seventy five per cent) of the Award, pending final
settlement of the Dispute. The aforesaid amount shall be paid forthwith upon
furnishing an irrevocable Bank Guarantee for a sum equal to 120 % (one hundred and
twenty per cent) of the aforesaid amount. Upon final settlement of the Dispute, the
aforesaid interim payment shall be adjusted and any balance amount due to be paid
or returned, as the case may be, shall be paid or returned with interest calculated at
the rate of 10% (ten per cent) per annum from the date of interim payment to the
date of final settlement of such balance.

26.4 Adjudication by Regulatory Authority, Tribunal or Commission

In the event of constitution of a statutory regulatory authority, tribunal or

commission, as the case may be, with powers to adjudicate upon disputes between
the Contractor and the Authority, all Disputes arising after such constitution shall,
instead of reference to arbitration under Clause 26.3, be adjudicated upon by such
regulatory authority, tribunal or commission in accordance with the Applicable Law
and all references to Dispute Resolution Procedure shall be construed accordingly.
For the avoidance of doubt, the Parties hereto agree that the adjudication hereunder
shall not be final and binding until an appeal against such adjudication has been
decided by an appellate tribunal or court of competent jurisdiction, as the case may
be, or no such appeal has been preferred within the time specified in the Applicable
Law.

123
 Article 27

Miscellaneous

27.1 Governing law and jurisdiction

This Agreement shall be construed and interpreted in accordance with and governed
by the laws of India, and the courts at [Delhi] shall have exclusive jurisdiction over
matters arising out of or relating to this Agreement.

27.2 Waiver of immunity

Each Party unconditionally and irrevocably:

(a) agrees that the execution, delivery and performance by it of this Agreement
constitute commercial acts done and performed for commercial purpose;

(b) agrees that, should any proceedings be brought against it or its assets,
property or revenues in any jurisdiction in relation to this Agreement or any
transaction contemplated by this Agreement, no immunity (whether by
reason of sovereignty or otherwise) from such proceedings shall be claimed
by or on behalf of the Party with respect to its assets;

(c) waives any right of immunity which it or its assets, property or revenues now
has, may acquire in the future or which may be attributed to it in any
jurisdiction; and

(d) consents generally in respect of the enforcement of any judgment or award

against it in any such proceedings to the giving of any relief or the issue of any
process in any jurisdiction in connection with such proceedings (including the
making, enforcement or execution against it or in respect of any assets,
property or revenues whatsoever irrespective of their use or intended use of
any order or judgment that may be made or given in connection therewith).

27.3 Delayed payments

The Parties hereto agree that payments due from one Party to the other Party under
the provisions of this Agreement shall be made within the period set forth therein,
and if no such period is specified, within 30 (thirty) days of receiving a demand along
with the necessary particulars. In the event of delay beyond such period, the
defaulting Party shall pay interest for the period of delay calculated at a rate equal to
Base Rate plus 2 (two) percent, calculated at quarterly rests, and recovery thereof
shall be without prejudice to the rights of the Parties under this Agreement including
Termination thereof.

27.4 Waiver

(i) Waiver, including partial or conditional waiver, by either Party of any default by the
other Party in the observance and performance of any provision of or obligations
under this Agreement:-
(a) shall not operate or be construed as a waiver of any other or subsequent
default hereof or of other provisions of or obligations under this Agreement;

124
 (b) shall not be effective unless it is in writing and executed by a duly authorized
representative of the Party; and
(c) shall not affect the validity or enforceability of this Agreement in any manner.

(ii) Neither the failure by either Party to insist on any occasion upon the performance of
the terms, conditions and provisions of this Agreement or any obligation there under
nor time or other indulgence granted by a Party to the other Party shall be treated or
deemed as waiver of such breach or acceptance of any variation or the relinquishment
of any such right hereunder.

27.5 Liability for review of Documents and Drawings

Except to the extent expressly provided in this Agreement:

(a) no review, comment or approval by the Authority or the Authority’s Engineer

of any Document or Drawing submitted by the Contractor nor any observation
or inspection of the construction, or maintenance of the Project Highway nor
the failure to review, approve, comment, observe or inspect hereunder shall
relieve or absolve the Contractor from its obligations, duties and liabilities
under this Agreement, the Applicable Laws and Applicable Permits; and

(b) the Authority shall not be liable to the Contractor by reason of any review,
comment, approval, observation or inspection referred to in Sub-clause (a)
above.

27.6 Exclusion of implied warranties etc.

This Agreement expressly excludes any warranty, condition or other undertaking

implied at law or by custom or otherwise arising out of any other agreement between
the Parties or any representation by either Party not contained in a binding legal
agreement executed by both Parties.

27.7 Survival

(i) Termination shall:

(a) not relieve the Contractor or the Authority, as the case may be, of any
obligations hereunder which expressly or by implication survive Termination
hereof; and

(b) except as otherwise provided in any provision of this Agreement expressly

limiting the liability of either Party, not relieve either Party of any obligations
or liabilities for loss or damage to the other Party arising out of, or caused by,
acts or omissions of such Party prior to the effectiveness of such Termination
or arising out of such Termination.

125
(ii) All obligations surviving Termination shall only survive for a period of 3 (three) years
following the date of such Termination.

27.8 Entire Agreement

This Agreement and the Schedules together constitute a complete and exclusive
statement of the terms of the agreement between the Parties on the subject hereof,
and no amendment or modification hereto shall be valid and effective unless such
modification or amendment is agreed to in writing by the Parties and duly executed
by persons especially empowered in this behalf by the respective Parties. All prior
written or oral understandings, offers or other communications of every kind
pertaining to this Agreement are abrogated and withdrawn. For the avoidance of
doubt, the Parties hereto agree that any obligations of the Contractor arising from the
Request for Qualification or Request for Proposals, as the case may be, shall be
deemed to form part of this Agreement and treated as such.

27.9 Severability

If for any reason whatever, any provision of this Agreement is or becomes invalid,
illegal or unenforceable or is declared by any court of competent jurisdiction or any
other instrumentality to be invalid, illegal or unenforceable, the validity, legality or
enforceability of the remaining provisions shall not be affected in any manner, and the
Parties will negotiate in good faith with a view to agreeing to one or more provisions
which may be substituted for such invalid, unenforceable or illegal provisions, as
nearly as is practicable to such invalid, illegal or unenforceable provision. Failure to
agree upon any such provisions shall not be subject to the Dispute Resolution
Procedure set forth under this Agreement or otherwise.

27.10 No partnership

This Agreement shall not be interpreted or construed to create an association, joint

venture or partnership between the Parties, or to impose any partnership obligation
or liability upon either Party, and neither Party shall have any right, power or
authority to enter into any agreement or undertaking for, or act on behalf of, or to act
as or be an agent or representative of, or to otherwise bind, the other Party.

27.11 Third parties

This Agreement is intended solely for the benefit of the Parties and their respective
successors and permitted assigns, and nothing in this Agreement shall be construed to
create any duty to, standard of care with reference to, or any liability to, any person
not a Party to this Agreement.

27.12 Successors and assigns

This Agreement shall be binding upon, and inure to the benefit of the Parties and their
respective successors and permitted assigns.

126
27.13 Notices

Any notice or other communication to be given by any Party to the other Party under
or in connection with the matters contemplated by this Agreement shall be in writing
and shall:

(a) in the case of the Contractor, be given by facsimile or e-mail and by letter
delivered by hand to the address given and marked for attention of the person
set out below or to such other person as the Contractor may from time to time
designate by notice to the Authority; provided that notices or other
communications to be given to an address outside [Delhi] may, if they are
subsequently confirmed by sending a copy thereof by registered
acknowledgement due, air mail or by courier, be sent by facsimile or e-mail to
the person as the Contractor may from time to time designate by notice to the
Authority;
[***]

(b) in the case of the Authority, be given by facsimile or e-mail and by letter
delivered by hand and be addressed to the [Chairman] of the Authority with a
copy delivered to the Authority Representative or such other person as the
Authority may from time to time designate by notice to the Contractor;
provided that if the Contractor does not have an office in [Delhi] it may send
such notice by facsimile or e-mail and by registered acknowledgement due, air
mail or by courier; and

(c) any notice or communication by a Party to the other Party, given in

accordance herewith, shall be deemed to have been delivered when in the
normal course of post it ought to have been delivered and in all other cases, it
shall be deemed to have been delivered on the actual date and time of
delivery; provided that in the case of facsimile or e- mail, it shall be deemed to
have been delivered on the working day following the date of its delivery.

27.14 Language

All notices required to be given by one Party to the other Party and all other
communications, Documentation and proceedings which are in any way relevant to
this Agreement shall be in writing and in English language.

27.15 Counterparts

This Agreement may be executed in two counterparts, each of which, when executed
and delivered, shall constitute an original of this Agreement.

27.16 Confidentiality

The Parties shall treat the details of this Agreement as private and confidential, except
to the extent necessary to carry out obligations under it or to comply with Applicable
Laws. The Contractor shall not publish, permit to be published, or disclose any

127
 particulars of the Works in any trade or technical paper or elsewhere without the
previous agreement of the Authority.

27.17 Copyright and Intellectual Property rights

(i) As between the Parties, the Contractor shall retain the copyright and other
Intellectual Property rights in the Contractor's documents and other design
documents made by (or on behalf of) the Contractor. The Contractor shall be deemed
(by signing this Agreement) to give to the Authority a non-terminable transferable
non-exclusive royalty-free license to copy, use and communicate the Contractor's
documents, including making and using modifications of them. This license shall:

(a) apply throughout the actual or intended working life (whichever is longer) of
the relevant parts of the Works;

(b) entitle any person in proper possession of the relevant part of the Works to
copy, use and communicate the Contractor's documents for the purposes of
completing, operating, maintaining, altering, adjusting, repairing and
demolishing the Works; and

(c) in the case of Contractor's documents which are in the form of computer
programs and other software, permit their use on any computer on the Site
and other places as envisaged by this Agreement, including replacements of
any computers supplied by the Contractor.

(ii) The Contractor's documents and other design documents made by (or on behalf of)
the Contractor shall not, without the Contractor's consent, be used, copied or
communicated to a third party by (or on behalf of) the Authority for purposes other
than those permitted under this Clause 27.17.

(iii) As between the Parties, the Authority shall retain the copyright and other intellectual
property rights in this Agreement and other documents made by (or on behalf of) the
Authority. The Contractor may, at its cost, copy, use, and obtain communication of
these documents for the purposes of this Agreement. They shall not, without the
Authority's consent, be copied, used or communicated to a third party by the
Contractor, except as necessary for the purposes of the contract.

27.18 Limitation of Liability

(i) Neither Party shall be liable to the other Party for loss of use of any Works, loss of
profit, loss of any contract or for any indirect or consequential loss or damage which
may be suffered by the other Party in connection with this Agreement, save and
except as provided under Articles 23 and 25.

(ii) The total liability of one Party to the other Party under and in accordance with the
provisions of this Agreement, save and except as provided in Articles 23 and 25, shall
not exceed the Contract Price. For the avoidance of doubt, this Clause shall not limit
the liability in any case of fraud, deliberate default or reckless misconduct by the
defaulting Party.

128
27.19 Care and Supply of Documents

(i) Each of the Contractor’s documents shall be in the custody and care of the Contractor,
unless and until taken over by the Authority. Unless otherwise stated in the
Agreement, the Contractor shall supply to the Authority 2 (two) copies of the each of
the Contractor’s documents.

(ii) The Contractor shall keep, on the Site, a copy of the Agreement, publication named in
the Authority’s requirements, the Contractor’s documents, and variations and other
communications given under the Agreement. The Authority’s personnel shall have the
right of access to all these documents at all reasonable times.

(iii) If a Party becomes aware of an error or defect of a technical nature in a document

which was prepared for use in executing the Works, the Party shall promptly give
notice to the other party of such error or defect.

27.20 Authority’s Use of Contractor’s Documents.

(i) As between the Parties, the Contractor shall retain the copyright and other
Intellectual Property rights in the Contractor’s Documents and other design
documents made by (or on behalf of) the Contractor.

(ii) The Contractor hereby gives to the Authority a non-terminable transferable

nonexclusive royalty-free license to copy, use and communicate the Contractor’s
Documents, including making and using modifications of them. This license shall:

(a) apply throughout the actual or intended working life (whichever is longer) of
the relevant parts of the Works,

(b) entitle any person in proper possession of the relevant part of the Works to
copy, use and communicate the Contractor’s Documents for the purposes of
completing, operating, maintaining, altering, adjusting, repairing and
demolishing the Works, and

(c) in the case of Contractor’s Documents which are in the form of computer
programs and other software, permit their use on any computer on the Site
and other places as envisaged by the Contractor, including replacements of
any computers supplied by the Contractor.

(iii) The Contractor’s Documents and other design documents made by or on behalf of the
Contractor shall not, without the Contractor’s consent, be used, copied or
communicated to a third party by (or on behalf of) the Authority for purposes other
than those permitted under this Sub-Clause.

27.21 Contractor’s Use of Authority’s Documents

As between the Parties, the Authority shall retain the copyright and other intellectual
property rights in the Authority’s requirements and other Documents made by (or on
behalf of) the Authority. The Contractor may, at its cost copy, use, and obtain
communication of these documents for the purpose of the Agreement. They shall not
without the Authority’s consent, be copied, used or communicating to a third party by
the Contractor, except as necessary for the purposes of the Agreement.

129
27.22 Access to the Site by Others

The Contractor shall, at all times, afford access to the Site to the authorized
representatives of the Authority, the Authority’s Engineer and anyone else authorized
by the Authority to access the site and to the persons duly authorized by any
Governmental Agency having jurisdiction over the Project, including those concerned
with safety, security or environmental protection to inspect the Project Highway and
to investigate any matter within their authority and upon reasonable notice, the
Contractor shall provide to such persons reasonable assistance necessary to carry out
their respective duties and functions with minimum disruption to the construction,
operation and maintenance of the Project Highway consistent with the purpose for
which such persons have gained such access to the Site.

27.23 Term

This Agreement shall come into force and effect from the date first hereinabove
written and shall remain in force and effect till the Termination Date i.e. the Parties
perform all their respective obligations or is terminated by any of the Parties for the
reasons and in the manner provided for in the Agreement.

27.24 Amendments

The Agreement may not be supplemented, amended, modified or changed except by

an instrument in writing signed by the Contractor and the Authority and expressed to
be a supplement, modification or change to the Agreement.

27.25 Representation and Bribes

The Contractor represents and warrants to the Authority that:

(a) No representation or warranty by the Contractor contained herein or in any

other document furnished by it to the Authority, or to any Governmental
Instrumentality in relation to Applicable Permits contains or will contain any
untrue statement of material fact or omits or will omit to state a material fact
necessary to make such representation or warranty not misleading; and

(b) It warrants that no sums, in cash or kind, have been paid or will be paid by or
on behalf of the Contractor, to any person by way of fees, commission or
otherwise for securing or entering into the Contractor for influencing or
attempting to influence any officer or employee of the Authority or GOI in
connection therewith.

27.26 No Agency

The Agreement does not constitute either Party as the agent, partner or legal
representative of the other for any purposes whatsoever, and neither Party shall have
any express or implied right or authority to assume or to create any obligation or
responsibility on behalf of or in the name of the other Party.

130
Schedules

131
 Schedule-A

(See Clauses 2.1 and 8.1)

Site of the Project

1 The Site

(i) The Site of Reconstruction/Widening work from Km 49.00 to 52.800 of NH-220 the state of
Jharkhand on EPC mode.Project Highway shall include the land, buildings, structures and
road works as described in Annex-I of this Schedule-A.

(ii) The dates of handing over the Right of Way to the Contractor are specified in Annex-II
of this Schedule-A.

(iii) An inventory of the Site including the land, buildings, structures, road works, trees
and any other immovable property on, or attached to, the Site shall be prepared
jointly by the Authority Representative and the Contractor, and such inventory shall
form part of the memorandum referred to in Clause 8.2 (i) of this Agreement.

(iv) The alignment plans of the Project Highway are specified in Annex-III. In the case of
sections where no modification in the existing alignment of the Project Highway is
contemplated, the alignment plan has not been provided. Alignment plans have only
been given for sections where the existing alignment is proposed to be upgraded. The
proposed profile of the Project Highways shall be followed by the contractor with
minimum FRL as indicated in the alignment plan. The Contractor, however,
improve/upgrade the Road Profile as indicated in Annex-III based on site/design
requirement.

(v) The status of the environment clearances obtained or awaited is given in Annex-IV.

132
 Annex – I

(Schedule-A)

Site

[Note: Through suitable drawings and description in words, the land, buildings, structures
and road works comprising the Site shall be specified briefly but precisely in this
Annex-I. All the chainages/ location referred to in Annex-I to Schedule-A shall be
existing chainages.]

1. Site
Site of the Reconstruction/Widening work from Km 49.00 to 52.800 of NH-220 the state of
Jharkhand on EPC mode (Job No. – NH-220(AP)2023-24/346). The land, carriageway
and structures comprising the Site are described below.

2. Land
The Site of the Project Highway comprises the land (sum total of land already in
possession and land to be possessed) as described below:
Chainage (km)
S. No. Right of Way (m) Remarks
From To
49.00 49.03 11 m avg.
1 TCS-03
49.03 49.385 11 m avg.
2 TCS-01
49.385 49.400 11 m avg.
3 TCS-04
49.400 49.430 11 m avg.
4 TCS-05
49.430 49.445 11 m avg.
5 TCS-04
49.445 51.56 11 m avg.
6 TCS-01
51.56 51.81 8.5 m
7 TCS-02
51.81 52.77 11 m avg.
8 TCS-01
52.77 52.80 11 m avg.
9 TCS-03
3. Carriageway
The existing carriageway of the Project Highway isDouble lane except Km 51.56 to 51.81(single
lane).The type of the existing pavement is flexible.

4. Major Bridges
The Site includes following major bridges.
S.No. Chainage Type of Structure No. of Width(m)
(km) Spans with span
Foundation Sub- structure Superstructure length (m)
NIL

133
5. Road over-bridges (ROB)/ Road under-bridges (RUB)
The Site includes the following ROB (road over railway line)/RUB (road under
railway line):

S. No. Chainage Type of Structure No. of Spans Width ROB/

(km) with span (m) RUB
Foundation Superstructure length (m)
NIL

134
6. Grade separators- NA

The Site includes the following grade separators:

S. Chainage Type of Structure No. of Spans with Width
No. (km) span length (m) (m)
Foundation Superstructure

NIL

7. Minor bridges-
The Site includes the following minor bridges:
Type of Structure No. of Spans with
S. Chainage span length (m)
Sub- Width (m)
No. (km) Foundation Super- structure
structure
1
49.400 open RCC RCC 30 10

8. Railway line crossings-

The Site includes the following railway level crossings:

S. No. Location (km) Remarks

NIL

9. Underpasses (vehicular, non vehicular):-

The Site includes the following underpasses:

S. No. Chainage (km) Type of Structure No. of Spans with Width

span length (m) (m)

NIL

10. Culverts
The Site has the following culverts:

Chainage Span/Opening with

S No. Type of Culvert Width (m)
(km) span length

49.220 Slab Culvert 1x1.0

1

49.250 Slab Culvert 1x1.0

2

49.410 HPC 1x1.0

3

135
 49.700 Slab Culvert 1x1.0
4

49.810 Slab Culvert 1x1.2

5

50.150 Slab Culvert 1x1.0

6

50.260 Slab Culvert 2x1.9

7

51.200 Slab Culvert 1x1.0

8

51.500 Slab Culvert 1x1.0

9

51.850 Slab Culvert 1x1.0

10

52.025 Slab Culvert 1x1.0

11

52.205 Slab Culvert 1x1.0

12

52.370 HPC 1x1.0

13

52.500 Slab Culvert 1x1.0

14

52.600 Slab Culvert 1x1.0

15

11. Bus bays- NA

The details of bus bays on the Site are as follows:
S. No. Chainage (km) Length (m) Left Hand Side Right Hand
Side

NIL

136
12. Truck Lay byes-NA
The details of truck lay byes are as follows:
S. No. Chainage (km) Length (m) Left Hand Side Right Hand
Side

NIL

13. Road side drains

The details of the roadside drains are as follows:

S. No. Location Type

From km to km Masonry/cc (Pucca) Earthen (Kutcha)

NIL

14. Major junctions

The details of major junctions are as follows:

S. No. Location(km) At Separated Category of Cross Road

grade
NH SH MDR Others
NIL

(NH: National Highway, SH: State Highway, MDR: Major District Road)

15. Minor junctions

The details of the minor junctions are as follows:
Type
SL. No.
Location (km)
Y-junction T –junction Cross road
1 50.00 ✓

2 50.50 ✓
3 51.81 ✓
4 52.77 ✓
16. Bypasses-NA
The details of the existing road sections proposed to be bypassed are as follows:

S. No. Name of bypass Chainage (km) Length (in

(town) Km)
From km to km

NIL

17. Other structures - Nil

137
138
 Sheet - I

(i) Electrical utilities

The site includes the following electrical utilities:

(a) Extra High-Tension Lines (EHT Lines) *

S. No. Chainage Length(in Km) Crossings

From To 400KV 220KV 110KV 66KV 400KV 220KV 110KV 66KV

(b) High Tension/Low Tension Lines (HT/LT Lines) *

S. No. Chainage Length(in Km) Crossings Transformers

From To 33KV 11 KV LT 33KV 1 1 KV LT No Capacity

(ii) Public Health utilities (Water/Sewage Pipe Lines) *

The site includes the following Public Health utilities:

S. Chainage Length in Km) Crossings

No. From To Water Supply line Sewage line Water Supply line Sewage line
With With With With With With With With
Pumping Gravity Pumping Gravity Pumping Gravity Pumping Gravity
flow flow flow flow

(iii) Any Other Line

(*This is illustrative and may change as per features of existing utilities.)

139
 Annex – II

(As per Clause 8.3 (i))

(Schedule-A)

Dates for providing Right of Way of Construction Zone

The dates on which the Authority shall provide Right of Way of Construction Zone to the
Contractor on different stretches of the Site are stated below:

From km to km Length Width(m) Date of

(km) providing ROW*
(i) Full Right of Way (full width) Km49.00 to Km 3.8 km 11m avg. Land already in
(a) Stretch 52.800of NH-220 possession
(b) Stretch accordingly ROW
(c) Stretch shall be provided
on appointed date
(ii Part Right of Way (part width)
(a) Stretch
(b) Stretch
(c) Stretch
*(ii) Balance Right of Way (width)
(a) Stretch
(b) Stretch
(c) Stretch

*The dates specified herein shall in no case be beyond 150 (one hundred and fifty) days after
the Appointed Date.

140
 Annex - III

(Schedule-A)

Alignment Plans

The existing alignment of the Project Highway shall be modified in the following sections as
per the alignment plan indicated below:

1. No existing alignment.

The existing alignment of the Project Highway shall be modified in the following sections as
per alignment Plans:NA
Design Chainage
S.I. no. Length (Km) Scheme Remarks
(km)
- - - - -

141
 Annex – IV

(Schedule-A)

Environment Clearances

The following environment clearances have been obtained: [NA]

The following environment clearances are awaited: [NA]

142
 Schedule - B

(See Clause 2.1)

Development of the Project Highway

1. Development of the Project Highway

Development of the Project Highway shall include design and construction of the
Project Highway as described in this Schedule-B and in Schedule-C.

2. [Rehabilitation and augmentation]

[Rehabilitation and augmentation] shall include [4 lane and 2 lane bypass] of the
Project Highway as described in Annex-I of this Schedule-B and in Schedule-C.

3. Specifications and Standards

The Project Highway shall be designed and constructed in conformity with the
Specifications and Standards specified in Annex-I of Schedule-D.

143
 Annex – I

(Schedule-B)

Description of [4 lane with divided carriageway and 2 lane with paved shoulder]

[Note: Description of the Project Highway shall be given by the Authority in detail together with
explanatory drawings (where necessary) to explain the Authority’s requirements precisely
in order to avoid subsequent changes in the Scope of the Project. The particulars that must
be specified in this Schedule-B are listed below as per the requirements of the Manual of
Specifications and Standards forTwo Laning of Highways with paved shoulder (Latest
revision of IRC: SP: 73), and for 4 lane divided carriageway (Latest revision of IRC: SP: 84)&
MORTH amendments referred to as the Manual. If any standards, specifications or details
are not given in the Manual, the minimum design/construction requirements shall be
specified in this Schedule. In addition to these particulars, all other essential project specific
details, as required, should be provided in order to define the Scope of the Project clearly
and precisely.

(i) For Reconstruction/ Widening work from Km 49.00 to Km52.80 0f NH-220.

(ii) Width of Carriageway

(a) Carriageway and roadway width:Proposed construction is Twolane3.8 km
(Reconstruction/Widening) out of 3.8 Km 3.45 km Reconstruction to 2lane(7m Width) and
in 0.250 km length widening from single lane to intermediate lane within available
RoWshall be undertakenside in accordance with the typical cross sections attached.

Provided that in the built-up areas [refer to paragraphs 2.1 (ii) of the Manual and provide
necessary details]: the width of the carriageway shall be as specified in the following table:
Sl. Built-up stretch Location Width(m) Typical cross
No. (Township) (km to km) section
(Ref. to Manual)
1 Nil

141
The chainage wise typical cross-sections of main carriageway are as under:

Design Chainage(km)
S.No. From To Length(m) TCS
1 49.00 49.03 30 TCS-03
2 49.03 49.385 355 TCS-01
3 49.385 49.400 15 TCS-04
4 49.400 49.430 30 TCS-05
5 49.430 49.445 15 TCS-04
6 49.445 51.56 2115 TCS-01
7 51.56 51.81 250 TCS-02
8 51.81 52.77 960 TCS-01
9 52.77 52.80 30 TCS-03
Total Length(m) 3800

Chainage wise typical cross-sections of service road are as under:NA

(b) Except as otherwise provided in this Agreement, the width of the paved carriageway
and cross-sectional features shall conform to paragraph 1above.

2. Geometric Design and General Features

(i) General

Geometric design and general features of the Project Highway shall be in accordance with
Section 2 of the Manual.

(ii) Design speed

The design speed shall be the minimum design speed of [100 km per hr for plain/ rolling
terrain].

(iii) Improvement of the existing road geometrics(NR)

[Refer to paragraph 2.1 (v) of the Manual and provide details]

In the following sections, where improvement of the existing road geometrics to the prescribed
standards is not possible, the existing road geometrics shall be improved to the extent possible
within the given right of way and proper road signs and safety measures shall be provided:
$ The contents of this Annex-I may be modified in accordance with the structure of the Project.

(iv) Right of Way

[Refer to paragraph 2.3 of the Manual]. Details of the Right of Way are given in Annex II of
Schedule-A.

(v) Type of shoulders

[Refer to paragraph 2.6 of the Manual and specify]

142
 (a) In built-up sections, footpaths/fully paved shoulders shall be provided in the
following stretches: N.A
Fully paved
Stretch
shoulders/ Reference to
SL.no. (from km to km)
footpaths cross section
From To

(b) In open country, [For 4 lane divided carriageway Paved shoulder of 2x2.5m width
shall be provided and 2x1.5m earthen shoulder width shall be covered with 150mm
of compacted layer of granular material.-NA

(c) Design and specifications of granular material shall conform to the requirements

Design Chainage (km)

Sr No. Side
From To Length(m) TCS
NA

specified in the relevant Manual.

(vi) Lateral and vertical clearances at underpasses

(a) Lateral and vertical clearances at underpasses and provision of guardrails/crash

barriers shall be as per the provision of relevant Manual.

(b) Lateral clearance: The width of the opening at the underpasses shall be as follows:
(i)

Sl. Location Proposed Clear span Total Vertical

No. Structure Length(m) clearance
type (m)
NA

(iii) Flyover
SR. No. Design Total Length(m) Type of Proposal
Chainag(km) Span/Opening(m) Structure Type
Proposed
NA

(vii) Lateral and vertical clearances at overpasses

(a) Lateral and vertical clearances at overpasses shall be as per the provision of
relevant Manual.
(b) Lateral clearance: The width of the opening at the overpasses shall be as follows:
Sl. Location (Chainage) Span/ opening Remarks
No. (from km to km) (m)

Nil

(viii) Service roads

143
 Service roads shall be constructed at the locations and for the lengths indicated below:
[Refer to the provision of relevant Manual and provide details]
Service road with RE wall location:NA

(ix) Grade separated structures

(a) Grade separated structures shall be provided as per provision of the relevant
Manual. The requisite particulars are given below:
Sl. Location Proposed Clear span Total Vertical
No. Structure Length(m) clearance
type (m)
NA

02 Nos. of Flyover
SR. No. Design Total Length(m) Type of Proposal
Chainag(km) Span/Opening(m) Structure Type
Proposed
NA

[Refer to the provision of relevant Manual and provide details]

In the case of grade separated structures, the type of structure and the level of the Project Highway
and the crossroads shall be as follows: [Refer to the provision of relevant Manual and specify the type
of vehicular under pass/ overpass structure and whether the cross road is to be carried at the existing
level, raised or lowered]

Sl. No. Location Type of Cross road at Remarks, if any

Structure Existing Raised Lowered
Length(m) Level Level Level
1. NA

(x) Cattle and pedestrian underpass /overpass

Cattle and pedestrian underpass/ overpass shall be constructed as follows: [Refer to

theprovision of relevant Manual and specify the requirements of cattle and
pedestrianunderpass/ overpass]

Sl. No. Location Proposed Span details Lateral

Structure type clearance

(xi) Typical cross-sections of the Project Highway

Attached .

144
145
146
 3. Intersections and Grade Separators

All intersections and grade separators shall be as per the provision of relevant Manual.
Existing intersections which are deficient shall be improved to the prescribed standards.
[Refer to the provision of relevant Manual and specify the requirements. Explain where
necessary with drawings/sketches/general arrangement]
Properly designed intersections shall be provided at the locations and of the types and
features given in the tables below:
(i) At-grade intersections(Minor junction)
Design Chainage, Type of
Sl. No. Existing Chainage, Km Location
Km Junction
T Rashunchopa village
1 50.00 50.00
Chowk
2 50.50. 50.50. T
3 51.81 51.81 T PalidihVillage more
4 52.77 52.77 T Banakata Chowk

(ii) Grade separated intersection with/without ramps

Sl. Location Salient features Minimum length Type of Road to be carried

No. of viaduct to be Junction over/under the
provided structures
NA

4. Road Embankment and Cut Section

(i) The Final Finished Road level(FRL) shall be followed by the contractor with minimum FRL
as indicated in the Plan and Profile Section.

(ii) Raising of the existing road as per existing level.

5. Pavement Design
(i) Pavement design shall be carried out in accordance with the provision of relevant Manual.
(ii) Type of pavement
(a)Flexible pavement as per IRC:37-2018 , IRC-SP:73-2018 and IRC-SP:84-2019for entire
stretch
[Refer to the provision of relevant Manual and state specific requirement, if any, of
providing cement concrete pavement.]
(iii) Design requirements

Minimum Proposed crust

TCS No. Description of TCS Length (m) thickness
(In mm)/Drain
147
 Minimum Proposed crust
TCS No. Description of TCS Length (m) thickness
(In mm)/Drain

BC = 40 MM
Reconstruction of existing DBM = 70 MM
TCS-1 road to Two lane (10 m 3430.00 WMM = 250 MM
Width including Shoulder) GSB =200 MM

BC = 40 MM
DBM = 70 MM
Widening from single lane to
WMM = 250 MM
TCS-2 intermediate lane(8.5 m 250.00
Widthincluding Shoulder) GSB =200 MM
SUBGRADE = 500 MM

BC = 40 MM
Reconstruction of existing DBM = 70 MM
TCS-3 road to Two lane (11 m 60.00 WMM = 250 MM
Widthincluding Shoulder) GSB =200 MM

BC = 40 MM
Reconstruction of existing DBM = 70 MM
TCS-4 road to Two lane (11 m 30.00 WMM = 250 MM
Widthincluding Shoulder) GSB =200 MM

TCS-5 Typical cross section at

Mastic Asphalt=25 mm
Irrigation canal Bridge 30.00
Deck BC=40mm

[Refer to the provision of relevant Manual and specify design requirements and strategy]
(a) Design Period and strategy

Flexible pavement for new pavement or for widening and strengthening of the
existing pavement shall be designed for a minimum design period of 20years. Stage
construction shall not be permitted.
(b) Design Traffic

Notwithstanding anything to the contrary contained in this Agreement or the

Manual, the Contractor shall design the pavement for a designtraffic of 20million
standard axles(minimum).
(iv) Reconstruction of stretches
[Refer to the provision of relevant Manual and specify the stretches, if any, to be
reconstructed.]
The following stretches of the existing road shall be reconstructed. These shall be designed
as new pavement.
Sl. No. Stretch From km to km Remarks

1 NA

(v) Widening and Improvement of Stretches:

Improvement of existing road below VUP are as follows:
148
6. Proposed Roadside Drainage:NA
(i)Ulined drain: Provision of unlined drains in Both side as under:
S. NO. Type of Location
Longitudinal Length(KM) Side Total
Drain Length(km)

NA

(ii)Covered LINEDdrains:Covered lined draininbothsideat built-upsectionsas

perTCS2 asunder:NA
S. NO. Type of Location
Longitudinal Length(KM) Side Total
Drain Length(km)

NA

Drainage system including surface and subsurface drains for the Project Highway shall be
provided as per the provision of relevant Manual. Additional drain if required as per site
condition has to be provided.
7. Design of Structures
(i) General
(a) All bridges, culverts and structures shall be designed and constructed in accordance
with the provision of relevant Manual and shall conform to the cross- sectional
features and other details specified therein.
(b) Width of the carriageway of new bridges and structures shall be as follows:

[Refer to the provision of relevant Manual and specify the width of carriageway of
new bridges and structures of more than 60 (sixty) meter length, if the carriageway
width is different from 7.5 (seven point five) meters in the table below.]

S.No Design Chainage Span Type of Bridges

(km)
NIL

(c) The following structures shall be provided with footpaths:

[Refer to the provision of relevant Manual and provide details of new Structures
with footpath.]
*Attach typical cross-section, if necessary.
(d) All bridges shall be high-level bridges.
[Refer to the provision of relevant Manual and state if there is any exception]

(e) The following structures shall be designed to carry utility services specified in table
below:
[Refer to the provision of relevant Manual and provide details]
Sl. No. Bridge at km Utility service to be Remarks
carried

149
 (f) Cross-section of the new culverts and bridges at deck level for the Project Highway
shall conform to the typical cross-sections given in the provision of relevant Manual.
(ii) Culverts:
The Culverts details are as follows:NA

New
Total Culverts construction.(BOX newly construction
CELL)

Note : May be increased as per site requirements.

(a) Overall width of all culverts shall be equal to roadway width of approaches or
28.00m for 4 lane section as per IRC specification.
(b) Reconstruction/New of construction of culverts:
The existing culverts at the following locations shall be re-constructed as new
culverts with approach road as per site requirement and relevant manuals. The
Existing Culverts shall be dismantled or removed.
[Refer to the provision of relevant Manual and provide details]

Sl.No. Design Clear Total Type of Culvert No. of Type of Proposal

Chainage(km) Span/Opening Length Lane
NA

Note : May be increased as per site requirements.

*[Specify modifications, if any, required in the road level, etc.]

Bus Bays/ Bus Stops:

Total 04 nos. of Bus Bays cum Bus Shelter are proposed in this section of the project

Sl. No. Design Chainage Side

NA

Truck Lay Bays:

Total 02 nos. of Truck Bays are proposed in this section of the project

Sl. Design Side Location

No. Chainage(km)(
km) NA

Road side Amenities:

Rain water harvesting:

Sl. Design Chainage Side
No.
1 NA

150
 Note : May be increased as per site requirements &MoRT&H circular no. –
RW/NH-33044/14/2003- S&R(R) Pt. II dated 03.09.2019

Length of Retainingwall:NA
Length MinimumTotal
Design Chainage(km) Side
(m) Length(m)
NA

Note : May be increased as per site requirements.

Length of RE wall:
Sr No Design Chainage (km) Length(m) TCS No.
From To
1
NA

Note : May be increased as per site requirements

Protection work:
Thrie-Metalbeam crash barrier has been proposed to provide protection to the traffic at
chainages having height of embankment and near the approach side of the bridge. Chainage
mentioned below:

Thrie beam crash barrier

Design Chainage(km)
Sr From To Length(m) Side TCS Type
No

1 NA

Design Chainage(km)
Sr From To Length(m) TCS Type
No

NA
Note : May be increased as per site requirements.

New Jeresy crash barrier

Design Chainage(km)
Sr From To Length(m) Side TCS Type
No
1
NA
Note : May be increased as per site requirements.

151
Utility Duct:

Utility duct is provided in entire stretch except Structure and RE wall location.
Chute drain:
Chute drain is to be provided as slope protection work in the approach of bridge embankment as per
site requirements.

(c) Widening of existing culverts:

All existing culverts which are not to be reconstructed shall be widened to the
roadway width of the project Highway as per the typical cross section given in the
provision of relevant manual. Repairs and strengthening of existing structures
where required shall be carried out.

SL.
Culvert Location Type, span, height and width of Remarks,
No.
(km) Proposed culvert(m) if any

NA

(d) Additional new culverts shall be constructed as per particulars given in the table
below:
Additional new culverts if required any as per site condition, has to be provided.

SL.
Culvert Location Type, span, heightened width of Remarks, if
No.
(km) proposed culvert(m) any
NA

(e) (a) Major Repairs/replacements of railing/parapets, flooring and protection works

of the existing culverts shall be undertaken as follows:
[Refer to the provision of relevant Manual and provide details]

Sl. No. Location at km Type of repair required

NA

(f) Floor protection works shall be as specified in the relevant IRC Codes and
Specifications.

152
(iii) Bridges-
(a) Existing bridges to be re- constructed/widened

[(i)The existing bridges at the following locations shall be re-constructed

as new Structures]
[Refer to the provision of relevant Manual and provide details]

Sl.No. Bridge Salient Adequacy or otherwiseof Remarks

location(km) detailsofexisti the existingwaterway,
ng bridge verticalclearance, etc*
NIL
*Attach GAD

(ii) The following narrow bridges shall be widened:

Sl. Existing Extent of Cross-section at deck

No. Location (km) width (m) widening (m) level for widening @

NA
@ Attach cross-section

(b) Additional new bridges

[Specify additional new bridges if required, and attach GAD]

New bridges at the following locations on the Project Highway shall be constructed.
GADs for the new bridges are attached in the drawings folder.

Sl. No. Location(km) Total length(m) Remarks,if any

(c) The railings of existing bridges shall be replaced by crash barriers at the following
locations:
[Refer to the provision of relevant Manual and provide details:]

Sl. No. Location at km Remarks

As per site requirement.

(d) Repairs/replacements of railing/parapets of the existing bridges shall be
undertaken as follows:
[Refer to the provision of relevant Manual and provide details]

Sl. No. Location at km Remarks

1 As per site requirement.

(e) Drainage system for bridge decks

An effective drainage system for bridge decks shall be provided as specified in the
provision of relevant Manual
(f) Structures in marine environment
153
 [Refer to the provision of relevant Manual and specify the necessary measures /
treatments for protecting structures in marine environment, where applicable]

(iv) Rail-road bridges-

(a) Design, construction and detailing of ROB/RUB shall be as specified in the provision
of relevant Manual. [Refer to the provision of relevant Manual and specify
modification, if any]
(b) Road over-bridges-
Road over-bridges (road over rail) shall be provided at the following level crossings,
as per GAD drawings attached:
Sl. Location of Level crossing (Chainage Span (m)
No. km)
NA
Sr. no. Design Type of Span Total Skew angle
Chainage structure arrangement(m) Length
ROB Proper Span
NA

(c) Road under-bridges-NA

Sl. No. Location of Level crossing (Chainage Number and length of
km) Span (m)
1 NA NA

Road under-bridges (road under railway line) shall be provided at the following
level crossings, as per GAD drawings attached:

(v) Grade separated structures-

[Refer to the provision of relevant Manual]

The grade separated structures shall be provided at the locations and of the type and
length specified in paragraphs 2 (ix) and 3 of this Annex-I.

(vi) Repairs and strengthening of bridges and structures-NA

[Refer to the provision of relevant Manual and provide details]

The existing bridges and structures to be repaired/strengthened, and the nature and extent
of repairs /strengthening required are given below:

(a) Bridges

Sl. Location of bridge (km) Nature and extent of repairs /strengthening

No. to be carried out

NA
(b) ROB / RUB

Sl. Location of Nature and extent of repairs /strengthening to be

No. ROB/RUB (km) carried out

NA
(c) Overpasses/Underpasses and other structures

Sl. Location of Nature and extent of repairs /strengthening to be

No. Structure (km) carried out
154
 NA

(vii) List of Major/Minor Bridges and Structures

The following is the list of the Major/Minor Bridges and Structures has been proposed:

S.No Chainage (km) Span Type of Bridges

NA

8. Traffic Control Devices and Road Safety Works

(i) Traffic control devices and road safety works shall be provided in accordance with the
provision of relevant Manual.
(ii) Specifications of the reflective sheeting. [Refer to the provision of relevant Manual and
specify] as per IRC latest codes.
9. Roadside Furniture
(i) Roadside furniture shall be provided in accordance with the provision of relevant Manual.
Minimum provision of RoadsideFurniture details are as follows:
(A) Road Marking- min.1293.15m2
(B) Road Studs- min.1036Nos
(C) Traffic sign- min.35 Nos
(D) Direction and Place Identification Sign- min. 6 sqm
(E) Delineator-100 Nos
(F) 5th Kilometer Stone- 1 Nos
(G) Ordinary Kilometer Stone- 4 Nos.
(H) Junction Improvement : min. 01 Nos. Minor Junction

Additional requirement of road furniture like crash barrier, boards, etc as per
site condition if required has to be provided as per relevant manual/MoRT&H
latest edition.

(ii) Overhead full signboard Gantry:-NA

[Refer to the provision of relevant Manual and codes]

10. Compulsory Afforestation

[Refer to the provision of relevant Manual and as per forest department guidelines which
are required to be planted by the Contractor as compensatory afforestation.]

11. Hazardous Locations

Thrie beam crash barrier: As per Standard Design and Manual.
The safety barriers (Thrie beam crash barrier at high fill region)shall also be provided at the
following hazardous locations:
Thrie beam crash barrier
Design Chainage(km)
Sr From To Length(m) Side TCS Type
No

1 NA

Total length of crash barrier along project corridor at road level=15522+2040=17562m

New Jeresy crash barrier
155
 Design Chainage(km)
Sr From To Length(m) Side TCS Type
No
1
NA
Note : May be increased as per site requirements.

12. Special Requirement for Hill Roads-NA, Additional drain and safety features as per standard
manual for hilly roads.
[Refer to the provision of relevant Manual and provide details where relevant and
required.]

13. Change of Scope

The length of Structures and bridges specified hereinabove shall be treated as an
approximate assessment. The actual lengths as required on the basis of detailed
investigations shall be determined by the Contractor in accordance with the Specifications
and Standards. Any variations in the lengths specified in this Schedule-B shall not constitute
a Change of Scope, save and except any variations in the length arising out of a Change of
Scope expressly undertaken in accordance with the provisions of Article 13.

156
Annexure-I
Attached
(Drawing)

157
 Schedule B-1

1. The shifting of utilities and felling of trees shall be carried out by the Contractor.
The cost of the same shall be borne by the Contractor which will be reimbursed by the
Authority. Reimbursement shall be done against approved estimate of concerned electrical
and forest department. The details of utilities are as follows:

Sl.No Type of Utility Unit Quantity Location/stretch(LHS/RH

S)
A Electrical Utilities

Km NA
33 KV HT Lines
Km NA
11 KV Lines
km NA
LT Lines
A1 Electrical Poles Nos. NA

A2 Electrical cables meters NA

A3 Transformers Nos. NA

B Water/Sewage pipeline NA

B1 Sewage meters NA

B2 Water supply meters NA

B3 Tube well Nos. NA

C Felling and Removal of Nos.

Trees and transit
uptoDipo

170
 Sheet - II

Utility Shifting.

Shifting of obstructing existing utilities indicated in Schedule A to an appropriate location

in accordance with the standards and specifications of concerned Utility Owning Department is
part of the scope of work of the Contractor/Concessionaire*. The bidders may visit the site and
assess the quantum of shifting of utilities for the projects before submission of their bid. Copy of
utility relocation plan is enclosed. The specifications of concerned Utility Owning Department
shall be applicable and followed.

Notes:

(a) The type/ spacing/size/specifications of poles/towers/lines/cables to be used in shifting

work shall be as per the guidelines of utility owning department and it is to be agreed
solely between the Contractor/Concessionaire‘ and the utility owning department. No
change of scope shall be admissible and no cost shall be paid for using different
type/spacing/size/specifications in shifted work in comparison to those in the existing
work or for making any overhead crossings to underground as per requirement of utility
owning department and/or construction of project highway. The
Contractor/Concessionaire’ shall carry out joint inspection with utility owning department
and get the estimates from the utility owning department. The assistance of the Authority
is limited to giving forwarding letter on the proposal of Contractor/Concessionaire* to
utility owning department whenever asked by the Contractor/Concessionaire*. The
decision/approval of utility owning department shall be binding on the
Contractor/Concessionaire*.

(b) The supervision charges at the rates/charges applicable of the utility owning department
shall be paid directly by the Authority to the Utility Owning department as and when
Contractor/Concessionaire* furnishes demand of Utility Owning Department along with a
copy of estimated cost given by the later.

(c) The dismantled material/scrap of existing Utility to be shifted/ dismantled shall belong to
the Contractor/Concessionaire* who would be free to dispose-off the dismantled material
as deemed fit by them unless the Contractor/Concessionaire* is required to deposit the
dismantled material to utility owning department as per the norm and practice and in that
case the amount of credit for dismantled material may be availed by the
Contractor/Concessionaire* as per estimate agreed between them.

(d) The utilities shall be handed over after shifting work is completed to Utility Owning
Department to their entire satisfaction. The maintenance liability shall rest with the Utility
Owning Department after handing over process is complete as far as utility shifting works
are concerned.

171
 Schedule - C

(See Clause 2.1)

Project Facilities

1. Project Facilities
The Contractor shall construct the Project Facilities in accordance with the provisions of
this Agreement. Such Project Facilities shall include:

(a) toll plaza[s]

(b) roadside furniture;
(c) pedestrian facilities;
(d) tree plantation;
(e) truck lay-byes;
(f) bus-bays and bus shelters;
(g) rest areas;
(h) Rainwater harvesting as per MoRT&H circular no. – RW/NH-33044/14/2003- S&R(R)
Pt. II dated 03.09.2019
(i) others to be specified;
(j) Foundation & inaugural stone; and
(k) Project details boards.

2. Description of Project Facilities

Each of the Project Facilities is described below:

Sl. Project Facility Location Design Other essential

No. Requirements details

1. Truck lay bye NA As per IRC/MORTH

Standards.
2. Bus Bay and bus NA As per IRC/MORTH
shelter Standards.
3. Road side Amenities NA As per IRC/MORTH
Standards
4. Tree plantation NA As per IRC/MORTH
Standards/Forest
guidelines
5. Road side furniture NA As per IRC/MORTH
Standards.
6. Pedestrian facilities NA As per IRC/MORTH
Standards.
7. Rain water NA As per IRC/MORTH
harvesting Standards.
8. Utility Duct NA As per IRC/MORTH
Standards.
9. Foundation & NA As per IRC/MORTH
Inaugural stone Standards.
10. Project display As per site As per IRC/MORTH
board requirement. Standards.

Note: Provide adequate details of each Project Facility to ensure their design and
completion in accordance with the project-specific requirements and the provisions of the
Manual.

172
 Schedule - D

(See Clause 2.1)

Specifications and Standards

1. Construction

The Contractor shall comply with the Specifications and Standards set forth in Annex-
I of this Schedule-D for construction of the Project Highway.

2. Design Standards

The Project Highway including Project Facilities shall conform to design requirements
set out in the following documents:

[Manual of Specifications and Standards for Two Laning of Highways with paved
shoulder latest revision of (IRC: SP: 84:2019)&Manual of specification & standard for
fourlaning of widening with paved shoulder latest revision]

[Note: 1. Guidelines for the design of flexible pavement of IRC: 37: 2018 and IRC-SP : 84
2. BitumenVG-40shallbeused as binder for bituminous layers in accordance
with IRC: 53: 2010, IRC: 37:2018 and further Ministry Circular’s issued
fromMoRT&Htime to time.]
3. IRC-SP : 50, IRC-SP : 13, MoRT&H standard drawings for Box Cell Culverts
published by IRC.
4. IRC-SP : 112-2017
4. Other relevant IRC codes.

As regards, the work of utility shifting, the relevant specification, relevant rules,
regulations and act of Utility Owning Department/Agencies shall be applicable.

173
 Annex – I

(Schedule-D)

Specifications and Standards for Construction

1. Specifications and Standards

All Materials, works and construction operations shall conform to the Manual of
Specifications and Standards for [Two-Laning of Highways latest revision of
IRC:SP:73& 4 lane IRC:SP:84]&relevant MORTH specifications referred to as the
Manual, and MORTH Specifications for Road and Bridge Works. Where the
specification for a work is not given, Good Industry Practice shall be adopted to the
satisfaction of the Authority’s Engineer.

2. Deviations from the Specifications and Standards

(i) The terms “Concessionaire”, “Independent Engineer” and “Concession Agreement”

used in the Manual shall be deemed to be substituted by the terms “Contractor”,
“Authority’s Engineer” and “Agreement” respectively.

(ii) [Notwithstanding anything to the contrary contained in Paragraph 1 above, the

following Specifications and Standards shall apply to the Project Highway, and for
purposes of this Agreement, the aforesaid Specifications and Standards shall be
deemed to be amended to the extent set forth below:]

(iii) [Note 1: Deviations from the aforesaid Specifications and Standards shall be listed out
here. Such deviations shall be specified only if they are considered essential in view of
project-specific requirements.]

174
 Schedule - E

(See Clauses 2.1 and 14.2)

Maintenance Requirements

1. Maintenance Requirements

(i) The Contractor shall, at all times maintain the Project Highway in accordance with the
provisions of this Agreement, Applicable Laws and Applicable Permits.

(ii) The Contractor shall repair or rectify any Defect or deficiency set forth in Paragraph 2
of this Schedule-E within the time limit specified therein and any failure in this behalf
shall constitute non-fulfillment of the Maintenance obligations by the Contractor.
Upon occurrence of any breach hereunder, the Authority shall be entitled to effect
reduction in monthly lump sum payment as set forth in Clause 14.6 of this Agreement,
without prejudice to the rights of the Authority under this Agreement, including
Termination thereof.

(iii) All Materials, works and construction operations shall conform to the MORTH
Specifications for Road and Bridge Works, and the relevant IRC publications. Where
the specifications for a work are not given, Good Industry Practice shall be adopted.

[Specify all the relevant documents]

2. Repair/rectification of Defects and deficiencies

The obligations of the Contractor in respect of Maintenance Requirements shall

include repair and rectification of the Defects and deficiencies specified in Annex - I of
this Schedule-E within the time limit set forth therein.

3. Other Defects and deficiencies

In respect of any Defect or deficiency not specified in Annex - I of this Schedule-E, the
Authority’s Engineer may, in conformity with Good Industry Practice, specify the
permissible limit of deviation or deterioration with reference to the Specifications and
Standards, and any deviation or deterioration beyond the permissible limit shall be
repaired or rectified by the Contractor within the time limit specified by the
Authority’s Engineer.

4. Extension of time limit

Notwithstanding anything to the contrary specified in this Schedule-E, if the nature

and extent of any Defect or deficiency justifies more time for its repair or rectification
than the time specified herein, the Contractor shall be entitled to additional time in
conformity with Good Industry Practice. Such additional time shall be determined by
the Authority’s Engineer and conveyed to the Contractor and the Authority with
reasons thereof.

175
5. Emergency repairs/restoration

Notwithstanding anything to the contrary contained in this Schedule-E, if any Defect,

deficiency or deterioration in the Project Highway poses a hazard to safety or risk of
damage to property, the Contractor shall promptly take all reasonable measures for
eliminating or minimizing such danger.

6. Daily inspection by the Contractor

The Contractor shall, through its engineer, undertake a daily visual inspection of the
Project Highway and maintain a record thereof in a register to be kept in such form
and manner as the Authority’s Engineer may specify. Such record shall be kept in safe
custody of the Contractor and shall be open to inspection by the Authority and the
Authority’s Engineer at any time during office hours.

7. Pre-monsoon inspection / Post-monsoon inspection

The Contractor shall carry out a detailed pre-monsoon inspection of all bridges,
culverts and drainage system before [1st June] every year in accordance with the
guidelines contained in IRC: SP35. Report of this inspection together with details of
proposed maintenance works as required on the basis of this inspection shall be sent
to the Authority’s Engineer before the [10th June] every year. The Contractor shall
complete the required repairs before the onset of the monsoon and send to the
Authority’s Engineer a compliance report. Post monsoon inspection shall be done by
the [30th September] and the inspection report together with details of any damages
observed and proposed action to remedy the same shall be sent to the Authority’s
Engineer.

8. Repairs on account of natural calamities

All damages occurring to the Project Highway on account of a Force Majeure Event or
wilful default or neglect of the Authority shall be undertaken by the Authority at its
own cost. The Authority may instruct the Contractor to undertake the repairs at the
rates agreed between the Parties.

176
 Insert page

Annexure-II – Page 42

177
Table 5: Maintenance Criteria for Hill Roads

In addition to above, for hill roads the following provisions for maintenance is also to done.

Hill Roads

Hill Roads

(i) Damage to Retaining wall/ Breast wall 7 (Seven) days

(ii) Landslides requiring clearance 12(Twelve) hours

(iii) Snow requiring clearance 24(Twenty Four) hours

Note: For all tables 1 to 5 above, latest BIS & IRC standards (even those not indicated
herewith) along with MoRTH specifications shall be binding for all maintenance activities.

A. Flexible Pavement

Nature of Defect or deficiency Time limit for repair/

Rectification
(b) Granular earth shoulders, side slopes, drains and culverts
(i) Variation by more than 1 % in the prescribed slope 7(seven) days
of camber/cross fall (shall not be less than the
camber on the main carriageway)
(ii) Edge drop at shoulders exceeding 40 mm 7(seven) days
(iii) Variation by more than 15% in the prescribed side 30 (thirty) days
(embankment) slopes
(iv) Rain cuts/gullies in slope 7(seven) days
(v) Damage to or silting of culverts and side drains 7(seven) days
(vi) Desilting of drains in urban/semi- urban areas 24 (twenty four) hours
(vii) Railing, parapets, crash barriers 7(seven) days (Restore
immediately if causing safety
hazard)
(c) Road side furniture including road sign and pavement marking
(i) Damage to shape or position, poor visibility or loss 48 (forty eight) hours
of retro- reflectivity
(ii) Painting ofkmstone, railing, parapets, crash As and when required/ Once
barriers every year
(iii) Damaged/missingsignsroadrequiringreplacement 7(seven) days
(iv) Damage to road mark ups 7(seven) days
(d) Road lighting
(i) Any major failure of the system 24 (twenty four) hours
(ii) Faults and minor failures 8(eight) hours

179
(e) Trees and plantation
(i) Obstruction in a minimum head- room of 5 m above 24 (twenty four)hours
carriageway or obstruction in visibility of road signs
(ii) Removal of fallen trees from carriageway 4 (four) hours
(iii) Deterioration in health of trees and bushes Timely watering and treatment
(iv) Trees and bushes requiring replacement 30 (thirty) days
(v) Removal of vegetation affecting sight line and road 15 (fifteen) days
structures
(f) Rest area
(i) Cleaning of toilets Every 4 (four) hours

(ii) Defects in electrical, water and sanitary 24 (twenty four) hours

installations
(g) [Toll Plaza]
(h) OtherProjectFacilitiesandApproachroads
(i) Damage in approach roads, pedestrian facilities, 15 (fifteen) days
truck lay- byes, bus-bays, bus-shelters, cattle
crossings, [Traffic Aid Posts, Medical Aid Posts] and
service roads
(ii) Damaged vehicles or debris on the road 4 (four) hours
(iii) Malfunctioningof the mobile crane 4 (four) hours
Bridges
(a) Superstructure
(i) Any damage, cracks, spalling/ scaling within 48 (forty eight) hours
Temporary measures within 15 (fifteen) days or as
Permanent measures specified by the Authority’s
Engineer
(b) Foundations
(i) Scouring and/or cavitation 15(fifteen) days
(c) Piers, abutments, return walls and wing walls
(i) Cracks and damages including settlement and 30(thirty) days
tilting, spalling, scaling
(d) Bearings (metallic) of bridges
(i) Deformation, damages, tilting or shifting of 15(fifteen) days Greasing
bearings of metallic bearings once in
a year

(e) Joints
(i) Malfunctioning of joints 15(fifteen) days
(f) Other items
(i) Deforming of pads in elastomeric bearings 7 (seven) days

180
 (ii) Gathering of dirt in bearings and joints; or clogging 3 (three) days
of spouts, weep holes and vent-holes
(iii) Damage or deterioration in kerbs, parapets, 3(three) days (immediately
handrails and crash barriers within 24 hours if posing
danger to safety)

(iv) Rain-cuts or erosion of banks of the side slopes of 7 (seven) days

approaches
(v) Damage to wearing coat 15(fifteen) days
(vi) Damage or deterioration in approach slabs, 30(thirty) days
pitching, apron, toes, floor or guide bunds

(vii) Growth of vegetation affecting the structure or 15(fifteen) days

obstructing the waterway
(g) Hill Roads
(i) Damage to retaining wall/breast wall 7 (seven) days
(ii) Landslides requiring clearance 12(twelve) hours
(iii) Snow requiring clearance 24 (twenty four) hours

[Note: Where necessary, the Authority may modify the time limit for repair/rectification, or
add to the nature of Defect or deficiency before issuing the bidding document, with
theapprovalofthecompetentauthority.]

181
 Schedule - F

(See Clause 4.1 (vii)(a))

Applicable Permits

1. Applicable Permits

(i) The Contractor shall obtain, as required under the Applicable Laws, the following
Applicable Permits:

(a) Permission of the State Government for extraction of boulders from quarry;

(b) Permission of Village Panchayats and Pollution Control Board for installation
of crushers;
(c) License for use of explosives;
(d) Permission of the State Government for drawing water from river/reservoir;

(e) License from inspector of factories or other competent Authority for setting
up batching plant;
(f) Clearance of Pollution Control Board for setting up batching plant;

(g) Clearance of Village Panchayats and Pollution Control Board for setting up
asphalt plant;
(h) Permission of Village Panchayats and State Government for borrow earth; and
(i) Any other permits or clearances required under Applicable Laws.

(ii) Applicable Permits, as required, relating to environmental protection and

conservation shall have been procured by the Authority in accordance with the
provisions of this Agreement.

182
 Schedule – G

(See Clauses 7.1 and 19.2)

Annex-I

(See Clause 7.1)

Form of Bank Guarantee

[Performance Security/Additional Performance Security]

[DG(RD)&SS,

Ministry of Road Transport & Highways Transport Bhawan, New Delhi]

WHEREAS:

(A) [name and address of contractor] (hereinafter

called the “Contractor") and [name and address of the authority],
(hereinaftercalled the “Authority”) have entered into an agreement (hereinafter
called the“Agreement”) for the Reconstruction/Widening work from KM 49.00 t0
52.80 of NH-220 in the state of Jharkhand] on Engineering, Procurement and
Construction (the “EPC”) basis, subject toand in accordance with the provisions of
the Agreement

(B) The Agreement requires the Contractor to furnish a Performance Security for due
and faithful performance of its obligations, under and in accordance with the
Agreement, during the {Construction Period/ Defects Liability Period and
Maintenance Period} (as defined in the Agreement) in a sum of Rs….. cr. (Rupees
………..….. crore) (the “Guarantee Amount”).
(C) We, …………………..through our branch at …………………. (the “Bank”) have agreed to
furnish this bank guarantee (hereinafter called the“Guarantee”) by way of
Performance Security.

NOW, THEREFORE, the Bank hereby, unconditionally and irrevocably, guarantees and
affirms as follows:

1. The Bank hereby unconditionally and irrevocably guarantees the due and faithful
performance of the Contractor’s obligations during the {Construction Period/
Defects Liability Period and Maintenance Period} under and in accordance with
the Agreement, and agrees and undertakes to pay to the Authority, upon its mere
first written demand, and without any demur, reservation, recourse, contest or
protest, and without any reference to the Contractor, such sum or sums up to an
aggregate sum of the Guarantee Amount as the Authority shall claim, without the
Authority being required to prove or to show grounds or reasons for its demand
and/or for the sum specified therein.

2. A letter from the Authority, under the hand of an officer not below the rank of
[Executive Engineer,NationalHighwayDivision,Chaibasa], that the Contractor has
committed default in the due and faithful performance of all or any of its
obligations under and in accordance with the Agreement shall be conclusive, final
and binding on the Bank. The Bank further agrees that the Authority shall be the
sole judge as to whether the Contractor is in default in due and faithful

183
 performance of its obligations during and under the Agreement and its decision
that the Contractor is in default shall be final and binding on the Bank,
notwithstanding any differences between the Authority and the Contractor, or
any dispute between them pending before any court, tribunal, arbitrators or any
other authority or body, or by the discharge of the Contractor for any reason
whatsoever.

3. In order to give effect to this Guarantee, the Authority shall be entitled to act as if
the Bank were the principal debtor and any change in the constitution of the
Contractor and/or the Bank, whether by their absorption with any other body or
corporation or otherwise, shall not in any way or manner affect the liability or
obligation of the Bank under this Guarantee.

4. It shall not be necessary, and the Bank hereby waives any necessity, for the
Authority to proceed against the Contractor before presenting to the Bank its
demand under this Guarantee.

5. The Authority shall have the liberty, without affecting in any manner the liability
of the Bank under this Guarantee, to vary at any time, the terms and conditions of
the Agreement or to extend the time or period for the compliance with, fulfillment
and/ or performance of all or any of the obligations of the Contractor contained in
the Agreement or to postpone for any time, and from time to time, any of the
rights and powers exercisable by the Authority against the Contractor, and either
to enforce or forbear from enforcing any of the terms and conditions contained in
the Agreement and/or the securities available to the Authority, and the Bank shall
not be released from its liability and obligation under these presents by any
exercise by the Authority of the liberty with reference to the matters aforesaid or
by reason of time being given to the Contractor or any other forbearance,
indulgence, act or omission on the part of the Authority or of any other matter or
thing whatsoever which under any law relating to sureties and guarantors would
but for this provision have the effect of releasing the Bank from its liability and
obligation under this Guarantee and the Bank hereby waives all of its rights under
any such law.

6. This Guarantee is in addition to and not in substitution of any other guarantee or

security now or which may hereafter be held by the Authority in respect of or
relating to the Agreement or for the fulfillment, compliance and/or performance
of all or any of the obligations of the Contractor under the Agreement.

7. Notwithstanding anything contained hereinbefore, the liability of the Bank under

this Guarantee is restricted to the Guarantee Amount and this Guarantee will
remain in force for the period specified in paragraph 8 below and unless a
demand or claim in writing is made by the Authority on the Bank under this
Guarantee all rights of the Authority under this Guarantee shall be forfeited and
the Bank shall be relieved from its liabilities hereunder.

8. The Guarantee shall cease to be in force and effect on ****$. Unless a demand or
claim under this Guarantee is made in writing before expiry of the Guarantee, the
Bank shall be discharged from its liabilities hereunder.

9. The Bank undertakes not to revoke this Guarantee during its currency, except
with the previous express consent of the Authority in writing, and declares and
warrants that it has the power to issue this Guarantee and the undersigned has
full powers to do so on behalf of the Bank.

184
10. Any notice by way of request, demand or otherwise hereunder may be sent by
post addressed to the Bank at its above referred branch, which shall be deemed to
have been duly authorised to receive such notice and to effect payment thereof
forthwith, and if sent by post it shall be deemed to have been given at the time
when it ought to have been delivered in due course of post and in proving such
notice, when given by post, it shall be sufficient to prove that the envelope
containing the notice was posted and a certificate signed by an officer of the
Authority that the envelope was so posted shall be conclusive.

11. This Guarantee shall come into force with immediate effect and shall remain in
force and effect for up to the date specified in paragraph 8 above or until it is
released earlier by the Authority pursuant to the provisions of the Agreement.

Signed and sealed this ………. day of ……….., 20……… at ………..

SIGNED, SEALED AND DELIVERED

For and on behalf of the Bank by:

(Signature)

(Name)

(Designation)

(Code Number)

(Address)

NOTES:

(i) The bank guarantee should contain the name, designation and code number of
the officer(s) signing the guarantee.
(ii) The address, telephone number and other details of the head office of the Bank as
well as of issuing branch should be mentioned on the covering letter of issuing
branch.

$ Insert date being 2 (two) years from the date of issuance of this Guarantee (in accordance with Clause
7.2 of the Agreement).

185
 Annex – II

(Schedule - G)

(See Clause 19.2)

Form for Guarantee for Advance Payment

[DG(RD)&SS,

Ministry of Road Transport & Highways Transport Bhawan, New Delhi]

WHEREAS:

(A) [name and address of contractor] (hereinafter called the “Contractor") has
executed an agreement (hereinafter called the “Agreement”) with the [name and
address of the authority], (hereinafter called the “Authority”) for the
Reconstruction/Widening work from KM 49.00 t0 52.80 of NH-220 in the state of
Jharkhand] on Engineering, Procurement and Construction (the “EPC”) basis,
subject to and in accordance with the provisions of the Agreement

(B) In accordance with Clause 19.2 of the Agreement, the Authority shall make to the
Contractor an interest bearing @Bank Rate + 3% advance payment (herein after
called “Advance Payment”) equal to 10% (ten per cent) of the Contract Price; and
that the Advance Payment shall be made in two installments subject to the
Contractor furnishing an irrevocable and unconditional guarantee by a scheduled
bank for an amount equivalent to 110% (one hundred and ten percent) of such
installment to remain effective till the complete and full repayment of the
installment of the Advance Payment as security for compliance with its
obligations in accordance with the Agreement. The amount of {first/second}
installment of the Advance Payment is Rs. ------ cr. (Rupees ------ crore) and the
amount of this Guarantee is Rs. ------- cr. (Rupees ------ crore) (the “Guarantee
Amount”)$.
(C) We, …………………..through our branch at …………………. (the “Bank”) have agreed to
furnish this bank guarantee (hereinafter called the“Guarantee”) for the Guarantee
Amount.

NOW, THEREFORE, the Bank hereby, unconditionally and irrevocably, guarantees and
affirms as follows:

1. The Bank hereby unconditionally and irrevocably guarantees the due and faithful
repayment on time of the aforesaid installment of the Advance Payment under
and in accordance with the Agreement, and agrees and undertakes to pay to the
Authority, upon its mere first written demand, and without any demur,
reservation, recourse, contest or protest, and without any reference to the

$ The Guarantee Amount should be equivalent to 110% of the value of the applicable installment.

186
 Authority shall claim, without the Authority being required to prove or to show
grounds or reasons for its demand and/or for the sum specified therein.

A letter from the Authority, under the hand of an officer not below the rank of
[General Manager in the National Highways Authority of India], that the
Contractor has committed default in the due and faithful performance of all or
any of its obligations for the repayment of the installment of the Advance
Payment under and in accordance with the Agreement shall be conclusive, final
and binding on the Bank. The Bank further agrees that the Authority shall be the
sole judge as to whether the Contractor is in default in due and faithful
performance of its obligations during and under the Agreement and its decision
that the Contractor is in default shall be final and binding on the Bank,
notwithstanding any differences between the Authority and the Contractor, or
any dispute between them pending before any court, tribunal, arbitrators or any
other authority or body, or by the discharge of the Contractor for any reason
whatsoever.

2. In order to give effect to this Guarantee, the Authority shall be entitled to act as if
the Bank were the principal debtor and any change in the constitution of the
Contractor and/or the Bank, whether by their absorption with any other body or
corporation or otherwise, shall not in any way or manner affect the liability or
obligation of the Bank under this Guarantee.

3. It shall not be necessary, and the Bank hereby waives any necessity, for the
Authority to proceed against the Contractor before presenting to the Bank its
demand under this Guarantee.

4. The Authority shall have the liberty, without affecting in any manner the liability
of the Bank under this Guarantee, to vary at any time, the terms and conditions of
the Advance Payment or to extend the time or period of its repayment or to
postpone for any time, and from time to time, any of the rights and powers
exercisable by the Authority against the Contractor, and either to enforce or
forbear from enforcing any of the terms and conditions contained in the
Agreement and/or the securities available to the Authority, and the Bank shall
not be released from its liability and obligation under these presents by any
exercise by the Authority of the liberty with reference to the matters aforesaid or
by reason of time being given to the Contractor or any other forbearance,
indulgence, act or omission on the part of the Authority or of any other matter or
thing whatsoever which under any law relating to sureties and guarantors would
but for this provision have the effect of releasing the Bank from its liability and
obligation under this Guarantee and the Bank hereby waives all of its rights under
any such law.

5. This Guarantee is in addition to and not in substitution of any other guarantee or

security now or which may hereafter be held by the Authority in respect of or
relating to the Advance Payment.

187
6. Notwithstanding anything contained hereinbefore, the liability of the Bank under
this Guarantee is restricted to the Guarantee Amount and this Guarantee will
remain in force for the period specified in paragraph 8 below and unless a
demand or claim in writing is made by the Authority on the Bank under this
Guarantee all rights of the Authority under this Guarantee shall be forfeited and
the Bank shall be relieved from its liabilities hereunder.

7. The Guarantee shall cease to be in force and effect on ****.$ Unless a demand or
claim under this Guarantee is made in writing on or before the aforesaid date, the
Bank shall be discharged from its liabilities hereunder.

8. The Bank undertakes not to revoke this Guarantee during its currency, except
with the previous express consent of the Authority in writing, and declares and
warrants that it has the power to issue this Guarantee and the undersigned has
full powers to do so on behalf of the Bank.

9. Any notice by way of request, demand or otherwise hereunder may be sent by

post addressed to the Bank at its above referred branch, which shall be deemed to
have been duly authorized to receive such notice and to effect payment thereof
forthwith, and if sent by post it shall be deemed to have been given at the time
when it ought to have been delivered in due course of post and in proving such
notice, when given by post, it shall be sufficient to prove that the envelope
containing the notice was posted and a certificate signed by an officer of the
Authority that the envelope was so posted shall be conclusive.

10. This Guarantee shall come into force with immediate effect and shall remain in
force and effect up to the date specified in paragraph 8 above or until it is
released earlier by the Authority pursuant to the provisions of the Agreement.

Signed and sealed this ………. day of ……….., 20……… at ………..

SIGNED, SEALED AND DELIVERED

For and on behalf of the Bank by:

(Signature)
(Name)
(Designation)
(Code Number)
(Address)

NOTES:
(i) The bank guarantee should contain the name, designation and code number of
the officer(s) signing the guarantee.
(ii) The address, telephone number and other details of the head office of the Bank as
well as of issuing branch should be mentioned on the covering letter of issuing
branch.

$ Insert a date being 90 (ninety) days after the end of one year from the date of payment of the Advance
payment to the Contractor (in accordance with Clause 19.2 of the Agreement).

188
SCHEDULE – H

See Clauses10.1 (iv) and 19.3

Contract Price Weightages

1.1 The Contract Price for this Agreement is Rs.

Total Length- 3.8 KM

1.2 Proportions of the Contract Price for different stages of Constructionof the Project
Highway shall be as specified below:

Item Weightage in Stage for Payment Percentage

Percentage to weightage
theContract Price
1 2 3 4
Road works. 95.403 A-Reconstruction of existing road to
Two lane (TCS-1)

(1) Earthwork up to top of 0.000%

the sub-grade
(2) Sub-Base Work) Course (GSB) 23.617%
(3) Non Bituminous Base
24.282%
course (WMM)
(4) Bituminous Base Course with
prime and tack coat 28.076%
(DBM)
(5) Wearing Coat(BC) 14.707%
(6) Construction of Earthen Shoulders
0.998%
Both Side
B-Concentric widening existing road
from Single lane to intermediaten 0.000%
lane (TCS-2)

(1) Earthwork up to top of 0.107%

the sub-grade
(2) Sub-Base Work) Course (GSB) 0.572%
(3) Non Bituminous Base
0.748%
course (WMM)
(4) Bituminous Base Course with
prime and tack coat 2.967%
(DBM)
(5) Wearing Coat(BC) 0.833%
(6) Construction of Earthen Shoulders
0.043%
Both Side
C-Reconstruction of existing road to
0.000%
Two lane (TCS-3)

(1) Earthwork up to top of 0.000%

the sub-grade
(2) Sub-Base Work) Course (GSB) 0.389%

189
 (3) Non Bituminous Base
0.509%
course (WMM)
(4) Bituminous Base Course with
prime and tack coat 0.595%
(DBM)
(5) Wearing Coat(BC) 0.309%
(6) Construction of Earthen Shoulders
0.017%
Both Side
D-Reconstruction of existing road to
0.000%
Two lane (TCS-4)

(1) Earthwork up to top of 0.000%

the sub-grade
(2) Sub-Base Work) Course (GSB) 0.183%
(3) Non Bituminous Base
0.239%
course (WMM)
(4) Bituminous Base Course with
prime and tack coat 0.280%
(DBM)
(5) Wearing Coat(BC) 0.145%
(6) Construction of Earthen Shoulders
0.009%
Both Side
E-Over Existing Bridges (TCS-5) 0.000%

(1) Earthwork up to top of 0.000%

the sub-grade
(2) Sub-Base Work) Course (GSB) 0.000%
(3) Non Bituminous Base
0.000%
course (WMM)
(4) Bituminous Base Course
0.000%
(DBM)
(5) Wearing Coat(BC)
0.127%
(6) Construction of Earthen Shoulders
0.000%
Both Side
(7) Mastic asphalt 0.245%
Minor Bridges/ A.1- Widening and Repair of
Underpasses/ Minor bridges (length > 6
Overpasses m and < 60 m)
(1)Minor bridges 0.00
A.2- New Minor bridges (length
>6 and <60 m.)
(1) Foundation +Sub-Structure:
On Completion of the foundation
work including foundations for wing 0.00
and return walls, abutments, piers
up to the abutment/pier cap.

190
(2) Super-structure: 0.00
On completion of thesuper-
structure in all respects including
wearing coat, bearings, expansion
joints, hand rails, crash barriers,
road. signs & markings,tests on
completion etc. complete in all
respect.
(3) Approaches: On completion of 0.00
approaches including Retaining
walls, stone pitching, protection
works complete in all respect and fit
for use.
(4)Guide Bunds and River 0.00
Training Works:
On completion of Guide Bunds and
river Training Works complete in all
respects
(5) Diversion Road 0.00
B.1- Widening and 0.00
Repair of underpasses/
overpasses Underpasses/
Overpasses
Underpasses/Overpasses
B.2- New underpasses/ 0.00
Overpasses with RE wall
(1)Foundation +Sub-Structure : 0.00
On completion of the foundation
workincluding foundations
for wing and return walls,
abutments, piers upto
theabutment/pier cap.
(2) Super-structure: 0.00
On completion of the super-
structure in all respects including
wearing coat,bearings, expansion
joints, hand rails, crash barriers,
road signs &markings,tests on
completion etc. complete in all
respect.Wearing Coat
(a) in case of Overpass - wearing
coatincluding expansion joints
complete in all respects as specified
and
(b) in case ofunderpass- rigid
pavement including drainage facility
complete in all respects as specified
as specified.
(3) Approaches: 0.00
On completion of approaches
including
Retainingwalls/Reinforced Earth
walls, stone pitching, protection
works complete in all respect and fit

191
 for use.

Major Bridge 0.00 A.1- Widening and repairs of 0.00

(length>60m).works Major Bridge
and (1)Foundation 0.00
ROB/RUB/elevated (2) Sub-structure 0.00
sections/ flyovers. (3) Super-structure 0.00
Including viaducts if (4) Wearing coat including 0.00
any
expansion joint
(5) Miscellaneous Items like hand 0.00
rails, crash barriers, road markings
Etc.
(6) Wing walls/return walls 0.00
(7) Guide Bunds, River Training 0.00
works etc.
A.2- New Major Bridges 0.00
(1) Foundation 0.00
(2) Sub-structure 0.00
(3) Super-structure (including 0.00
bearings)
(4) Wearing Coat including 0.00
expansion joints
(5) Miscellaneous items like hand 0.00
rails, crash barriers, road markings
etc.
(6) Wing walls/return walls 0.00
(7) Guide Bunds, River Training 0.00
works etc.
(8) Approaches(including 0.00
Retaining walls, stone pitching and
protection works)
(9) Diversion Road 0.00
B.1- Widening and repair of 0.00
(a) ROB
(b) RUB
(1) Foundation 0.00
(2) Sub-structure 0.00
(3) Super-structure 0.00
(including bearings)
(4) Wearing Coat: 0.00
(a) in case of ROB wearing
Coat including expansion joints
complete in all respects as specified
and
(b) in case of RUB-rigid pavement
under RUB including drainage
facility complete in all respects as
specified as specified.
(5) Miscellaneous Items like 0.00
handrails, crash barriers, road
192
markings etc.)
(6) Wing walls/return walls 0.00
(7) Approaches(including 0.00
Retaining walls,stone pitching
andprotection works)
B.2- NewROB/RUB 0.00
(a)ROB
(b) RUB
(1) Foundation 0.00
(2) Sub-structure 0.00
(3) Super-structure 0.00
(including bearings)
(4) Wearing Coat: 0.00
(a) in case of ROBwearingCoat
including expansionjointscomplete
in allrespects as specifiedand (b) in
case ofRUB- rigid pavementnunder
RUB includingdrainage facility
complete in allrespects as
specifiedas specified.
(5) MiscellaneousItems 0.00
likehandrails, crash barriers,road
markings etc.)
(6) Wingwalls/return walls 0.00
(7) Approaches(including 0.00
Retainingwalls/Reinforced
Earth wall,
stonepitchingandprotection works)
C.1- Widening and repair of 0.00
Elevated Section / Flyovers/
grade Separators
(1) Foundation 0.00
(2) Sub-structure 0.00
(3) Super-structure 0.00
(including bearings)
(4) Wearing 0.00
Coatincludingexpansionjoints
(5) MiscellaneousItems like 0.00
handrails, crash barriers,road
markings etc.)
(6) Wingwalls/return walls 0.00
(7) Approaches(including 0.00
Retainingwalls/Reinforced
Earth wall,
stonepitchingandprotection works)
C.2-New Elevated 0.00
Section/Flyovers
Grade Separators 0.00
(1) Foundation
(2) Sub-structure 0.00
(3) Super-structure (including 0.00
bearings)
(4) Wearing Coat including 0.00
expansion joints
193
 (5) Miscellaneous Items like hand 0.00
rails, crash barriers, road markings
etc.)
(6) Wing walls/return walls 0.00
(7) Approaches (including 0.00
Retaining walls/Reinforced
Earth wall, stone pitching and
protection works)
Other Works 4.597% (i) Toll Plaza 0.000%
a) Bus bays (ii) Road side drains 0.000%
b) Truck lay byes (iii) Road signs,
c) Rest areas markings, km stones,
d) others safety devices, and Road 40.604%
Appurtenances (km, hectometer
stones, delineators, studs etc.
(iv) Protection work, Metal W-Beam
0.000%
Crash Barrier, slop pitching etc.
(v) RE wall 0.000%
(vi) Project facilities
(a) Bus Bays-
(b) Truck lay-byes
(c) Rest areas complex 0.000%
(d) others(Black spot rectification)

(vii) Road side plantation 0.000%

(vi) Retaining wall 0.000%
(viii) Safety and traffic management
0.000%
during construction
(ix) Junction Improvement Minor
59.396%
Junction

Sheet – III

Item Weightage in Stage for payment Percentage weightage

percentage to the
Utility Shifting
Price
Electrical utilities and HT/LT line [0.00]
[0.00]
public Health Utilities (including transformers if
(Water pipe lines and any)
sewage lines)

* This is illustrative and may require modificationas per scope of work.

194
1.3 Procedure of estimating the value of work done.

1.3.1 Road works.

Procedure for estimating the value of road work done shall be as follows

Table 1.3.1

Stage of payment Percentage – Payment Procedure

weightage
A-Reconstruction of existing road to Two Unit of measurement is linear
lane (TCS-1) length. Payment of each stage
shall be made on pro rata basis on
completion of a stage in a length
(1) Earthwork up to top of 0.000% of not less than 10 (ten) percent of
the sub-grade the total length.
(2) Sub-Base Work) Course (GSB) 23.617%
(3) Non Bituminous Base
24.282%
course (WMM)
(4) Bituminous Base Course with prime and
tack coat 28.076%
(DBM)
(5) Wearing Coat(BC) 14.707%
(6) Construction of Earthen Shoulders Both Unit of measurement is linear
0.998%
Side length. Payment of each stage
B-Concentric widening existing road from shall be made on pro rata basis on
0.000% completion of a stage in a length
Single lane to intermediaten lane (TCS-2)
of not less than 10 (ten) percent of
(1) Earthwork up to top of 0.107% the total length
the sub-grade
(2) Sub-Base Work) Course (GSB) 0.572%
(3) Non Bituminous Base
0.748%
course (WMM)
(4) Bituminous Base Course with prime and
tack coat 2.967%
(DBM)
(5) Wearing Coat(BC) 0.833% Unit of measurement is linear
(6) Construction of Earthen Shoulders Both length. Payment of each stage
0.043% shall be made on pro rata basis on
Side
C-Reconstruction of existing road to Two completion of a stage in a length
0.000% of not less than 10 (ten) percent of
lane (TCS-3)
the total length
(1) Earthwork up to top of 0.000%
the sub-grade
(2) Sub-Base Work) Course (GSB) 0.389%
(3) Non Bituminous Base
0.509%
course (WMM)
(4) Bituminous Base Course with prime and Unit of measurement is linear
tack coat 0.595% length. Payment of each stage
(DBM) shall be made on pro rata basis on
(5) Wearing Coat(BC) completion of a stage in a length
0.309% of not less than 10 (ten) percent of
(6) Construction of Earthen Shoulders Both the total length
0.017%
Side
D-Reconstruction of existing road to Two 0.000%
195
lane (TCS-4)

(1) Earthwork up to top of 0.000%

the sub-grade
Unit of measurement is linear
0.183%
(2) Sub-Base Work) Course (GSB) length. Payment of each stage
(3) Non Bituminous Base shall be made on pro rate basis on
0.239% completion of a stage in a length
course (WMM)
(4) Bituminous Base Course with prime and of not less than 10 (ten) percent of
tack coat 0.280% the total length
(DBM)
(5) Wearing Coat(BC) 0.145%
(6) Construction of Earthen Shoulders Both
0.009%
Side
E-Over Existing Bridges (TCS-5) 0.000%
Unit of measurement is linear
(1) Earthwork up to top of 0.000% length. Payment of each stage
the sub-grade shall be made on pro rate basis on
completion of a stage in a length
0.000% of not less than 10 (ten) percent of
(2) Sub-Base Work) Course (GSB) the total length
(3) Non Bituminous Base
0.000%
course (WMM)
(4) Bituminous Base Course
0.000%
(DBM)
(5) Wearing Coat(BC) 0.127%
(6) Construction of Earthen Shoulders Both Unit of measurement is linear
Side 0.000% length. Payment of each stage
shall be made on pro rate basis on
(7) Mastic asphalt completion of a stage in a length
0.245% of not less than 10 (ten) percent of
the total length
@. For example, if the total length of bituminous work to be done is 100 km,
the cost per km of bituminous work shall be determined as follows:

Cost per km = P x weightage for road work x weightage for bituminous work x(1/L)
Where P= Contract Price

L = Total length in km

Similarly, the rates per km for other stages shall be worked out accordingly.

Note: The length affected due to law and order problems or litigation duringexecution
due to which the Contractor is unable to execute the work, may be deducted from the
total project length for paymentpurposes. The total length calculated here is only for
payment purposes and will not affect and referred in other clauses of the Contract
Agreement.

1.3.2 Minor Bridges and Underpasses/Overpasses.

Procedure for estimating the value of Minor bridge andUnderpasses/Overpasses shall be as
stated in table 1.3.2
Table 1.3.2

196
 Stage of payment Percentage – Payment Procedure
weightage
1 2 3
A.1- Widening and Repair of Cost of each minor bridge shall bedetermined on pro
Minor bridges (length > 6m rate basis with respect to the total linear length of the
and < 60 m) minor bridges. Payment shall be made on the
Minor bridges 0.00 completion of widening& repair works of a minor
bridge.
A.2- New Minor bridges
(length >6 and <60 m.)
(1) Foundation +Sub- 0.00 Cost of each minor bridge shall be determined on pro
Structure: On Completion of rate basis with respect to the total linear length (m) of
the foundation work the minor bridges. Payment against foundation +sub-
including foundations for structure shall be made on pro-rate basis on
wing and return walls, completion of a stage i.e. not less than25% of the
abutments, piers up to the scope of foundation + substructure of each bridge
abutment/pier cap. subject to completion of at least two foundations
along with sub-structure upto abutment/pier cap
level of each bridge.
In case where load testing is required forfoundation,
the trigger of first payment shall include load testing
also where specified.
(ii) Super-structure: On 0.00 Payment shall be made on pro-rate basis on
completion of the completion of a stage i.e. completion of super-
superstructure in all respects structure of at least one span in all respects as
includingwearing specified in the column of “Stage of Payment” in this
coat,bearings, expansion sub-clause.
joints,hand rails, crash
barriers, road signs
&markings,tests on
completion etc.complete in all
respect.
(iii) Approaches: On 0.00 Payment shall be made on pro-rate basis on
completion of approaches completion of a stage i.e. completion of approaches in
including Retaining walls, all respect as specified in the column of “Stage of
stone pitching, protection Payment” in this sub-clause.
works complete in all
respect and fit for use.
(iv) Guide Bunds and 0.00 Payment shall be made on pro-rate basis on
River Training Works: completion of a stage i.e. completion of Guide Bunds
On completion of Guide Bunds and River training Works in all respects as specified.
and river Training Works
complete in all respects
(v) Diversion Road 0.00 Payment shall be made on pro-rate basis on
completion of diversion road.
B.1-Widening and repairof 0.00 Cost of each underpass/overpass shall be determined
underpasses/overpasses on pro rate basis with respect to the total linear length
of the underpasses/overpasses. Payment shall be
made on the completion of widening & repair works
of a under pass/overpass.

B.2- New Underpasses/ 0.00

Overpasses:

197
(i) Foundation +Sub- 0.00 Cost of each Underpass/Over pass shall be
Structure: On completion determined on pro rate basis with respect to the total
of the foundation work linear length (m) of the Underpasses/Overpasses.
including foundations for Payment against foundation + substructure shall be
wing and return walls, made on pro-rate basis on completion of a stag i.e. not
abutments, piers upto the less than 25%of the scope offoundation +
abutment/pier cap. substructure. Substructure of each
Underpasses/Overpasses is subject to completion of
atleast two foundations along with sub-structure upto
abutment/pier cap level each underpass/overpass. In
case where load testing is required for foundation, the
trigger of first payment shall include load testing also
where specified.
(ii) Super-structure: 0.00 Payment shall be made on pro-rate basis on
On completion of the completion of a stage i.e. completion of super-
superstructure in all respects structure of atleast one span in all respects as
including wearing coat, specified in the column of “Stageof Payment” in
bearings, expansion joints, thissub-clause.
hand rails, crash barriers,
road signs &markings, tests
on completion etc complete in
all respect. Wearing Coat (a)
in case of Overpass - wearing
coat including expansion
joints complete in all respects
as specified and (b) in case of
underpass- rigid pavement
including drainage facility
complete in all respects as
specified as specified
(iii) Approaches: On 0.00 Payment shall be made on pro-rate basis on
completion of approaches completion of a stage i.e. completion ofapproaches in
including Retaining walls/ all respect as specified
Reinforced Earth walls,
stone pitching, protection
works complete in all
respect and fit for use

1.3.3 Major Bridge works ROB/RUB and Structures.

Procedure for estimating the value of Major Bridge works, ROB/RUB and

Structures shall be as stated in table 1.3.3:

198
 Table 1.3.3

Stage of payment Percentage Payment Procedure

weightage
1 2 3
A.1- Widening
andrepairs of Major
Bridges

(i) Foundation 0.00 (i) Foundation: Costof each Major Bridgeshall

be determined onpro rate basis withrespect to
the totallinear length (m) of the Major Bridge.
Paymentagainst foundationshall be made on
prorate basisoncompletion of a stagei.e. not
less than 25%of the scope offoundation of the
major Bridge subject tocompletion of
atleasttwo foundations of the major Bridge .In
case where loadtesting is required
forfoundation, the triggerof first payment shall
include load testingalso where specified.

(ii) Sub-structure 0.00 (ii) Sub-Structure: Payment against

Substructureshall be madeon pro-rate basis
oncompletion of a stagei.e. not less than 25%of
the scope of substructureof the majorbridge
subject tocompletion of atleast two sub-
structures ofabutments/piers upto
abutment/pier cap levelof the major bridge.
(iii) Super-structure (iii) Super-structure:Payment shall be
(including bearings) 0.00 madeon pro-rate basis oncompletion of a
stagei.e. completion ofsuper-
structureincluding bearings ofatleast one span
in allrespects as specified.
(iv) Wearing Coat (iv) Wearing Coat:Payment shall be madeon
including expansion 0.00 completion ofwearing coat including
joints expansionjointscomplete in all respectsas
specified.

(v) Miscellaneous Items 0.00 (v) Miscellaneous:Payments shall bemade on

like hand rails, crash completion ofallmiscellaneousworks like hand
barriers, road markings rails,crash barriers, roadmarkings etc.
etc. completein all respects asspecified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:Payments shall
Walls bemade on completion ofall wing
walls/returnwalls complete in allrespects as
specified
(vii) Guide Bunds, River 0.00 (vii) Guide Bunds, River Training
Training works etc works: Payment shall be made on
completionof all guide bunds/rivertraining
works etc.complete in all respectsas specified
199
(viii) Approaches (viii) Approaches:Payments shall bemade on
(including Retaining 0.00 completion
walls,stone pitching and ofbothapproachesincludingstonepitching,
protection works) protectionworks, etc. complete in
all respects asspecified
A.2- New Major Bridges

(i) Foundation 0.00 (i) Foundation: Costof each Major Bridgeshall

be determined onpro rate basis withrespect to
the totallinear length (m) of the
Major Bridge. Paymentagainstfoundationshall
be made on prorate basis oncompletion of a
stagei.e. notless than 25%of the scope
offoundation of the majorBridge subject to
completion of atleasttwo foundations of
themajor Bridge.
In case where loadtesting is required
forfoundation, the triggerof first payment shall
include load testingalso where specified
(ii) Sub-structure 0.00 (ii) Sub-Structure:. Payment against
Substructureshall be madeon pro-rate basis
oncompletion of a stagei.e. not less than 25%of
the scope of substructureof the major
Bridge subject tocompletion of atleasttwo sub-
structures
ofabutments/piersuptoabutment/pier cap
levelof the major bridge.
(iii) Super-structure 0.00 (iii) Super-structure:Payment shall be
(including bearings) madeon pro-rate basis oncompletion of a
stagei.e. completion of super-
structureincluding bearings ofatleast one span
in allrespects as specified.
(iv) Wearing Coat 0.00 (iv) Wearing Coat:Payment shall be madeon
including expansion completion ofwearing coat
joints includingexpansionjointscomplete in all
respectsas specified.
(v) Miscellaneous Items 0.00 (v) Miscellaneous:Payments shall bemade on
like hand rails, crash completion ofallmiscellaneousworks like hand
barriers, road markings rails,crash barriers, roadmarkings etc.
etc. completein all respects asspecified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:Payments shall
Walls bemade on completion ofall wing walls/return
walls complete in allrespects as specified.
(vii) Guide Bunds, River 0.00 (vii) Guide Bunds, River Trainingworks:
Training works etc. Payments shallbe made on completionof all
guide bunds/rivertraining works etc.complete
in all respectsas specified.

200
(viii) Approaches (viii) Approaches:Payments shall bemade on
(including Retaining 0.00 completion ofboth approachesincluding
walls,stone pitching and stonepitching, protectionworks, etc. complete
protection works) inall respects asspecified.

(ix)Diversion Road 0.00 Payment shall be made on pro-rate basis on

completion of diversion road.
B.1 -Widening and
repairs of
(a) ROB
(b) RUB
(i) Foundation 0.00 (i) Foundation: Costof each ROB/RUBshall be
determined on pro rate basis withrespect to
the totallinear length (m) of theROBs/RUBs.
Paymentagainst foundationshall be made on
prorate basis oncompletion of a stagei.e. not
less than 25% of the scope offoundation of
theROB/RUB subject tocompletion of
atleasttwo foundations of theROB/RUB.
In case where loadtesting is required
forfoundation, the triggerof first payment
shallinclude load testingalso where specified
(ii) Sub-structure 0.00 (ii) Sub-Structure: Payment against
Substructureshall be madeon pro-rate basis
oncompletion of a stagei.e. not less than 25%of
the scope of substructureoftheROB/RUB
subject tocompletion of atleasttwo sub-
structures of abutments/piers
uptoabutment/pier cap level
of the ROB/RUB.
(iii) Super-structure 0.00 (iii) Super-structure:
(including bearings) Payment shall be madeon pro-rate basis on
Completionof a stagei.e. completion of super-
structureincluding bearings ofatleast one span
in allrespects as specified
(iv) Wearing Coat 0.00 (iv) Wearing Coat:
including expansion Payment shall be madeon completion of (a)
joints incase of ROB- wearingcoat
in case of ROB. In case of includingexpansionjointscomplete in all
RUB, rigid pavement respectsas specified and (b) in case of RUB-
under rigidpavement under RUBincluding
RUB including drainage drainagefacility complete in allrespects as
facility as specified. specified.
(v) Miscellaneous Items 0.00 (v) Miscellaneous:
like hand rails, crash Payments shall bemade on completion
barriers, road markings ofallmiscellaneousworks like hand rails,crash
etc. barriers, roadmarkings etc. completein all
respects asSpecified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:
Walls Payments shall bemade on completion ofall
201
 wing walls/returnwalls complete in
allrespects as specified.
(vii) Approaches 0.00 (vii) Approaches:Payments shall bemade on
(includingRetaining completion ofbothapproachesincluding stone
walls, stonepitching and Pitching,protectionworks, etc. complete inall
protectionworks) respects asspecified.
B.2- New
(a) ROB
(b) RUB
(i) Foundation 0.00 (i) Foundation: Costof each ROB/RUBshall be
determined onpro rate basis wither spect to
the totallinear length (m) of theROBs/RUBs.
Payment against foundationshall be made on
pro rate basisoncompletion of a stagei.e. not
less than 25%of the scope offoundation of
theROB/RUB subject tocompletion of
atleasttwo foundations of theROB/RUB. In
case where loadtesting is required
forfoundation, the triggerof first payment
shallinclude load testingalso where specified.
(ii) Sub-structure 0.00 (ii) Sub-Structure: Payment against
Substructureshall be made
on pro-rate basis oncompletion of a stagei.e.
not less than 25%of the scope of
substructureof theROB/RUB subject
tocompletion of atleasttwo sub-structures of
abutments/piers uptoabutment/pier cap
levelof the ROB/RUB.
(iii) Super-structure 0.00 (iii) Super-structure:Payment shall be
(including bearings) madeon pro-rate basis oncompletion of a
stagei.e. completion ofsuper-
structureincluding bearings ofatleast one span
in allrespects as specified.
(iv) Wearing Coat 0.00 (iv) Wearing Coat:Payment shall be madeon
including expansion completion of (a) incase of ROB- wearingcoat
jointsin case of ROB. In includingexpansion jointscomplete in all
case ofRUB, rigid respectsas specified and (b) incase of RUB-
pavement underRUB rigidpavement under
including drainagefacility RUBincludingdrainagefacility complete in all
as specified. respects as specified
(v) Miscellaneous Items 0.00 (v) Miscellaneous:Payments shall bemade on
like hand rails, crash completion ofallmiscellaneousworks like hand
barriers, road markings rails,crash barriers, roadmarkings etc.
etc. completein all respects asspecified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:
Walls Payments shall bemade on completion ofall
wing walls/returnwalls complete in
allrespects as specified.
(vii) Approaches 0.00 (vii) Approaches:Payments shall bemade on
(includingRetaining completion ofboth approachesincluding

202
walls/Reinforced Earth stonepitching, protectionworks, etc. complete
wall, stone pitching and in all respects as
protection works) Specified.
C.1- Widening and 0.00
repairs of Elevated
Section /Flyovers/
Grade Separators
(i) Foundation 0.00 (i) Foundation: Costof each structure shallbe
determined on pro rate basis with respectto
the total linea length (m) of thestructures.
Paymentagainstfoundationshall be made on
prorate basis oncompletion of a stagei.e. not
less than 25%of the scope offoundation of
thestructure subject tocompletion of
atleasttwo foundations of the structure
In case where loadtesting is required
forfoundation, the triggerof first payment
shallinclude load testingalso where specified.

(ii) Sub- 0.00 (ii) Sub-Structure: Payment against

structure(including Substructureshall be madeon pro-rate basis
bearings) oncompletion of a stagei.e. not less than 25%of
the scope of substructureofthe structure
subject tocompletion of atleasttwo sub-
structures ofabutments/piers
uptoabutment/pier cap levelof the structure.
(iii) Super-structure 0.00 (iii) Super-structure:Payment shall be made
(including bearings) on pro-rate basis oncompletion of a stage i.e.
completion ofsuper-structureincluding
bearings ofatleast one span in allrespects as
specified
(iv) Wearing Coat 0.00 (iv) Wearing Coat:Payment shall be madeon
including expansion completion ofwearing coat
joints includingexpansionjointscomplete in all
respectsas specified.
(v) Miscellaneous Items 0.00 (v) Miscellaneous:Payments shall bemade on
like hand rails, crash completion ofallmiscellaneousworks like hand
barriers, road markings rails,crash barriers, roadmarkings etc.
etc. completein all respects as specified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:
Walls Payments shall bemade on completion ofall
wing walls/returnwalls complete in
allrespects as specified.
(vii) Approaches 0.00 (vii) Approaches:Payments shall be made on
(including Retaining completion ofbothapproachesincluding stone
walls/Reinforced Earth Pitching, protectionworks, etc. complete inall
wall, stone pitching and respects asspecified.
protection works)

203
C.2 -New Elevated 0.00
Section/Flyovers/
Grade
Separators
(i) Foundation 0.00 (i) Foundation: Cost: of each structure shallbe
determined on pro-rate basis with respectto
the total linearlength (m) of thestructures.
Paymentagainst foundationshall be made on
pro-rate basis oncompletion of a stagei.e. not
less than 25%of the scope of foundation of the
structure subject tocompletion of atleasttwo
foundations of thestructure.
In case where loadtesting is required
forfoundation, the triggerof first payment
shallinclude load testingalso where specified
(ii) Sub-structure 0.00 (ii) Sub-Structure: Payment against
Substructureshall be madeon pro-rate basis on
completion of a stagei.e. not less than 25%of
the scope of substructureofthestructure
subject tocompletion of atleasttwo sub-
structures ofabutments/piers
uptoabutment/pier cap levelof the structure.
(iii) Super-structure 0.00 (iii) Super-structure:Payment shall be
(including bearings) madeon pro-rate basis oncompletion of a
stagei.e. completion ofsuper-
structureincluding bearings ofatleast one span
in allrespects as specified.
(iv) Wearing Coat 0.00 (iv) Wearing Coat:Payment shall be madeon
including expansion completion ofwearing coat including
joints expansion jointscomplete in all respectsas
specified.
(v) Miscellaneous Items 0.00 (v) Miscellaneous:Payments shall bemade on
like hand rails, crash completion ofall miscellaneousworks like hand
barriers, road markings rails,crash barriers, roadmarkings etc.
etc. completein all respects asspecified.
(vi) Wing walls/return 0.00 (vi) Wing walls/return walls:
walls Payments shall bemade on completion ofall
wing walls/returnwalls complete in
allrespects as specified.
(vii) Approaches 0.00 (vii) Approaches:Payments shall bemade on
(including Retaining completion
walls/Reinforced Earth ofapproachesincludingstonepitching,
wall, stone pitching and protectionworks, etc. complete inall respects
protection works) asspecified.

Note: (1) In case of innovate Major Bridge projects like cable suspension/cable stayed/
Extra Dozed and exceptionally long span bridges, the schedule may be modified as per
site requirements before bidding with due approval of Competent Authority.
(2) The Schedule for exclusive tunnel projects may be prepared as per site requirements
before bidding with due approval of Competent Authority.
204
1.3.4 Other works.
Procedure for estimating the value of other works done shall be as stated in table 1.3.4.

205
 Table 1.3.4
Stage of payment Percentage – weightage Payment Procedure
Others Work of construction cost
(i) Toll Plaza Unit of measurement is each completed
toll plaza. Payment of each toll plaza
0.000% shall be made on pro rate basis with
respect to the total of all toll plazas.

(ii) Road side drains 0.000% Unit of measurement is linear length in

(iii) Road signs, km. Payment shall be made on pro rate
markings, km stones, basis on completion of a stage in a length
safety devices, and Road of not less than 10 % (ten per cent) of
40.604%
Appurtenances (km, the total length.
hectometer stones,
delineators, studs etc etc.
(iv) Protection work, Metal Unit of measurement is linear length in
W-Beam Crash Barrier, km. Payment shall be made on pro rate
0.000%
slop pitching and Misc. basis on completion of the total length.
Work etc.
(v) RE Wall Unit of measurement is linear length in
km. Payment shall be made on pro rate
0.000% basis on completion of a stage in a length
of not less than 10 % (ten per cent) of
the total length.
(vi) Project facilities 0.000% Payment shall be made on pro rate basis
(a) Bus Bays- for completed facilities.
(b) Truck lay-byes
(c) Rest areas complex
(d) others(Black spot
rectification) 0.000%
(e)Over head gantry
(vii) Road side plantation

(vi) Retaining wall 0.000% Unit of measurement is linear length.

(viii) Safety and traffic Unit of measurement is linear length in
management during km. Payment shall be made on pro rate
construction 0.000% basis on completion of a stage in a length
of not less than 10 % (ten per cent) of
the total length.
(ix) Junction Payment shall be made on prorate basis
Improvement(Minor 59.396% on completion of each junction
Junction)
Payment shall be made on prorate basis
0
on completion of each junction

206
 Sheet – IV

Stage of Payment Weightage Payment procedure

(i) ) HT/LT line
[00]
Unit of measurement is as per completed activities.
Payment shall be made as per actual shifting
(including
quantity/nos./ unit/km. Utility shifting rates shall be
transformers if any)
paid after modification of rates approved in sanctioned
DPR as per tender premium/discount of civil works.

(ii) EHT crossings [**] Cost of each crossing shall be determined on pro-rata basis
with reference to total no. of crossings. Payment shall be
made for not less than 25% of thecrossings subject to a
minimum of 4 crossings.
[**] Unit of measurement is as per completed activities. Cost per
(iii) HT/ LT line
activity shall be determined on pro-rata basis as per its
(including
weightage with reference to total cost of LT/ HT line.
transformers if any)
Payment shall be made for completed activity. (The average
weightage of major activities (only for payment purpose) in
shifting work is
(i) Erection of Poles-20%
(ii) Conductor stringing including laying of cable- 30%,
(iii) DTR erection (if involved)-10% and
(iv) Chargingof line including dismantling and site
clearance-40% (with DTR) and SOB without DTR)
[**]
(iv) HT/ LT crossings Cost of each crossing shall be determined on pro-rata basis
with reference to total no. of crossings. Payment shall be
made for not less than 25% of the crossings subject to a
minimum of 10 crossings.
[**]
(v) Water pipeline Unit of measurement is as per completed activities. Cost per
activity shall be determined on pro-rata basis as per its
weightage with reference to total cost of pipe line. Payment
shall be made for completed activity. (The average
weightage of major activities (only for payment purpose)
in shifting work is laying of pipe-50%, Charging of line
including all miscellaneous works and dismantling and site
clearance-50%)
[**]
(vi) water pipeline Cost of each crossing shall be determined on pro-rata
basis with reference to total no. of crossings. Payment shall
crossings
be made for not less than 25% of the crossings subject to a
minimum of 8 crossings.
[**]
(vii) Sewage lines Unit of measurement is as per completed activities. Cost per
activity shall be determined on pro-rata basis as per its
weightage with reference to total cost of pipe line. Payment
shall be made for completed activity. (The average
weightage of major activities (only for payment purpose) in
shifting work is laying of pipe-50%, Charging of line
including all miscellaneous works and dismantling and site
clearance-50%)
207
 [**] Cost of each crossing shall be determined on pro-rata basis
(viii) Sewage
with reference to total no. of crossings. Payment shall be
line crossings
made for completed activity. (The average weightage of
major activities in shifting work is laying pipe-50%,
Charging of line including all miscellaneous works and
dismantling and site clearance-50%)

*Thisisillustrativeandmayrequiremodificationasperscopeofwork.

2. Procedure for payment for Maintenance

2.1 The cost for maintenance shall be as stated in Clause 14.1.1.

2.2 Payment for Maintenance shall be made in quarterly installments in accordance with the
provisions of Clause 19.7.

208
 Schedule - I

(See Clause 10.2 (iv))

Drawings

1. Drawings

In compliance of the obligations set forth in Clause 10.2 of this Agreement, the
Contractor shall furnish to the Authority’s Engineer, free of cost, all Drawings listed in
Annex-I of this Schedule-I.

2. Additional Drawings

If the Authority’s Engineer determines that for discharging its duties and functions
under this Agreement, it requires any drawings other than those listed in Annex-I, it
may by notice require the Contractor to prepare and furnish such drawings forthwith.
Upon receiving a requisition to this effect, the Contractor shall promptly prepare and
furnish such drawings to the Authority’s Engineer, as if such drawings formed part of
Annex-I of this Schedule-I.

209
Annex – I
(Schedule - I)

List of Drawings

[Note: The Authority shall describe in this Annex-I, all the Drawings that the Contractor is
required to furnish under Clause 10.2.]

(i) All TCS

210
 Schedule - J

(See Clause 10.3 (ii))

Project Completion Schedule

1. Project Completion Schedule

During Construction period, the Contractor shall comply with the requirements set
forth in this Schedule-J for each of the Project Milestones and the Scheduled
Completion Date. Within 15 (fifteen) days of the date of each Project Milestone, the
Contractor shall notify the Authority of such compliance along with necessary
particulars thereof.

2. Project Milestone-I

(i) Project Milestone-I shall occur on the date falling on the [35% of the Scheduled
Construction Period] 63day from the Appointed Date (the “Project Milestone- I”).

(ii) Prior to the occurrence of Project Milestone-I, the Contractor shall have commenced
construction of the Project Highway and submitted to the Authority duly and validly
prepared Stage Payment Statements for an amount not less than 10% (ten per cent)
of the Contract Price.

3. Project Milestone-II

(i) Project Milestone-II shall occur on the date falling on the [60% of the Scheduled
Construction Period] 108 day from the Appointed Date (the “Project Milestone- II”).

(ii) Prior to the occurrence of Project Milestone-II, the Contractor shall have continued
with construction of the Project Highway and submitted to the Authority duly and
validly prepared Stage Payment Statements for an amount not less than 35% (thirty
five per cent) of the Contract Price and should have started construction of all bridges

4. Project Milestone-III

(i) Project Milestone-III shall occur on the date falling on the [85% of the Scheduled
Construction Period] 153day from the Appointed Date (the “Project Milestone- III”).

(ii) Prior to the occurrence of Project Milestone-III, the Contractor shall have continued
with construction of the Project Highway and submitted to the Authority duly and
validly prepared Stage Payment Statements for an amount not less than 70% (seventy
per cent) of the Contract Price and should have started construction of all project
facilities.
5. Scheduled Completion Date
(i) The Scheduled Completion Date shall occur on the [Scheduled Construction Period]
180 day from the Appointed Date.

(ii) On or before the Scheduled Completion Date, the Contractor shall have completed
construction in accordance with this Agreement.
211
6. Extension of time

Upon extension of any or all of the aforesaid Project Milestones or the Scheduled
Completion Date, as the case may be, under and in accordance with the provisions of
this Agreement, the Project Completion Schedule shall be deemed to have been
amended accordingly.

212
 Schedule - K

(See Clause 12.1 (ii))

Tests on Completion

1. Schedule for Tests

(i) The Contractor shall, no later than 30 (thirty) days prior to the likely completion of
construction, notify the Authority’s Engineer and the Authority of its intent to subject
the Project Highway to Tests, and no later than 10 (ten) days prior to the actual date of
Tests, furnish to the Authority’s Engineer and the Authority detailed inventory and
particulars of all works and equipment forming part of Works.

(ii) The Contractor shall notify the Authority’s Engineer of its readiness to subject the
Project Highway to Tests at any time after 10 (ten) days from the date of such notice,
and upon receipt of such notice, the Authority’s Engineer shall, in consultation with
the Contractor, determine the date and time for each Test and notify the same to the
Authority who may designate its representative to witness the Tests. The Authority’s
Engineer shall thereupon conduct the Tests itself or cause any of the Tests to be
conducted in accordance with Article 12 and this Schedule-K.

2. Tests

(i) Visual and physical test: The Authority’s Engineer shall conduct a visual and physical
check of construction to determine that all works and equipment forming part thereof
conform to the provisions of this Agreement. The physical tests shall include [***].

(ii) Riding quality test: Riding quality of each lane of the carriageway shall be checked
with the help of a Network Survey Vehicle (NSV) fitted with latest equipments and the
maximum permissible roughness for purposes of this Test shall be [2,000 (two
thousand)] mm for each kilometre.

(iii) Tests for bridges: All major and minor bridges shall be subjected to the rebound
hammer and ultrasonic pulse velocity tests, to be conducted in accordance with the
procedure described in Special Report No. 17: 1996 of the IRC Highway Research
Board on Nondestructive Testing Techniques, at two spots in every span, to be chosen
at random by the Authority’s Engineer. Bridges with a span of 15 (fifteen) metres or
more shall also be subjected to load testing.

(iv) Other tests: The Authority’s Engineer may require the Contractor to carry out or cause
to be carried additional tests, in accordance with Good Industry Practice, for
determining the compliance of the Project Highway with Specifications and Standards,
except tests as specified in clause 5,but shall include measuring the reflectivity of road
markings and road signs; and measuring the illumination level (lux) of lighting using
requisite testing equipment.

(v) Environmental audit: The Authority’s Engineer shall carry out a check to determine
conformity of the Project Highway with the environmental requirements set forth in
Applicable Laws and Applicable Permits.

213
 (vi) Safety Audit: The Authority’s Engineer shall carry out, or cause to be carried out, a
safety audit to determine conformity of the Project Highway with the safety
requirements and Good Industry Practice.

3. Agency for conducting Tests

All Tests set forth in this Schedule-K shall be conducted by the Contractor or such
other agency or person as it may specify in consultation with the Authority.

4. Completion Certificate

Upon successful completion of Tests, the Authority’s Engineer shall issue the
Completion Certificate in accordance with the provisions of Article 12.

5. The Contractor will carry out tests with following equipment at his own cost in the
presence of contractor’s representative.

Sr. Key metrics of Equipment to be used Frequency of condition survey

No. Asset

1 Surface NetworkSurvey At least twice a year (As per survey

defectsof Vehicle (NSV) months defined for the state basis
pavement rainy season)

2 Roughness of NetworkSurvey At least twice a year (As per survey

pavement Vehicle (NSV) months defined for the state basis
rainy season)

3 Strength FallingWeight At least once a year

ofpavement Deflectometer (FWD)

4 Bridges MobileBridge At least twice a year (As per survey

Inspection Unit (MBU) months defined for the state basis
rainy season)

5 Road signs Retro-reflectometer At least twice a year (As per survey

months defined for the state basis
rainy season)

The first testing with the help of NSV shall be conducted at the time of issue
ofCompletion Certificate.

214
 Schedule - L

(See Clause 12.2)

Completion Certificate

1 I, ……………………. (Name of the Authority’s Engineer), acting as the Authority’s

Engineer, under and in accordance with the Agreement dated ………… (the
“Agreement”), for [construction of the ****section (km ** to km **) of National
Highway No. ***] (the “Project Highway”) on Engineering, Procurement and
Construction (EPC) basis through …………………. (Name of Contractor), hereby certify
that the Tests in accordance with Article 12 of the Agreement have been successfully
undertaken to determine compliance of the Project Highway with the provisions of
the Agreement, and I am satisfied that the Project Highway can be safely and reliably
placed in service of the Users thereof.
2 It is certified that, in terms of the aforesaid Agreement, all works forming part of
Project Highway have been completed, and the Project Highway is hereby declared fit
for entry into operation on this the ……… day of ……… 20….. , Scheduled Completed
Date for which was the ……… day of ………20…..

SIGNED, SEALED AND DELIVERED

For and on behalf of the Authority’s Engineer by:

(Signature)

(Name)

(Designation) (Address)

215
 Schedule - M

(See Clauses 14.6, 15.2 and 19.7)

Payment Reduction for Non-Compliance

1. Payment reduction for non-compliance with the Maintenance

Requirements

(i) Monthly lump sum payments for maintenance shall be reduced in the case of non-
compliance with the Maintenance Requirements set forth in Schedule-E.

(ii) Any deduction made on account of non-compliance with the Maintenance

Requirements shall not be paid even after compliance subsequently. The deductions
shall continue to be made every month until compliance is done.

(iii) The Authority’s Engineer shall calculate the amount of payment reduction on the
basis of weightage in percentage assigned to non-conforming items as given in
Paragraph 2.

2. Percentage reductions in lump sum payments on monthly basis

(i) The following percentages shall govern the payment reduction:

S. No. Item/Defect/Deficiency Percentage

(a) Carriageway/Pavement
(i) Potholes, cracks, other surface defects 15%
(ii) Repairs of Edges, Rutting 5%
(b) Road, Embankment, Cuttings, Shoulders
(i) Edge drop, inadequate cross fall, undulations, settlement, 10%
potholes, ponding, obstructions
(ii) Deficient slopes, raincuts, disturbed pitching, vegetation 5%
growth, pruning of trees
(c) Bridges and Culverts
(i) Desilting, cleaning. vegetation growth, damaged pitching, 20%
flooring, parapets, wearing course, footpaths, any damage to
Foundations

(ii) Any Defects in superstructures, bearings and sub-structures 10%

(iii) Painting, repairs/replacement kerbs, railings, parapets, 5%
guideposts/crash barriers
(d) Roadside Drains
(i) Cleaning and repair of drains 5%
(e) Road Furniture
(i) Cleaning, painting, replacement of road signs, delineators, road 5%
markings, 200 m/km/5th km stones

216
 (f) Miscellaneous Items
(i) Removal of dead animals, broken down/accidented vehicles, 10%
fallen trees, road blockades or malfunctioning of mobile crane
(ii) Any other Defects in accordance with paragraph 1. 5%
(g) Defects in Other Project Facilities 5%

(ii) The amount to be deducted from monthly lump-sum payment for non- compliance of
particular item shall be calculated as under:

Where,

P = Percentage of particular item/Defect/deficiency for deduction

M1 = Monthly lump-sum payment in accordance para 1.2 above of this
Schedule
M2 = Monthly lump-sum payment in accordance para 1.2 above of this
Schedule
L1 = Non-complying length L = Total length of the road,
R = Reduction (the amount to be deducted for non-compliance for a
particular item/Defect/deficiency

The total amount of reduction shall be arrived at by summation of reductions for such items/
Defects/deficiency or non-compliance.

For any Defect in a part of one kilometer, the non-conforming length shall be taken as one
kilometer.

217
 Schedule - N

(See Clause 18.1 (i))

Selection of Authority’s Engineer

1. Selection of Authority’s Engineer

(i) The provisions of the Model Request for Proposal for Selection of Technical
Consultants, issued by the Ministry of Finance in May 2009, or any substitute thereof
shall apply for selection of an experienced firm to discharge the functions and duties
of an Authority’s Engineer.

(ii) In the event of termination of the Technical Consultants appointed in accordance with
the provisions of Paragraph 1.1, the Authority shall appoint another firm of Technical
Consultants forthwith and may engage a government-owned entity in accordance
with the provisions of Paragraph 3 of this Schedule-N.

2. Terms of Reference

The Terms of Reference for the Authority’s Engineer (the “TOR”) shall substantially
conform with Annex 1 to this Schedule N.

3. Appointment of Government entity as Authority’s Engineer

Notwithstanding anything to the contrary contained in this Schedule, the Authority

may in its discretion appoint a government-owned entity as the Authority’s Engineer;
provided that such entity shall be a body corporate having as one of its primary
functions the provision of consulting, advisory and supervisory services for
engineering projects; provided further that a government-owned entity which is
owned or controlled by the Authority shall not be eligible for appointment as
Authority’s Engineer.

218
 Annex – I

(Schedule - N)

Terms of Reference for Authority’s Engineer

1. Scope

(i) These Terms of Reference (the “TOR”) for the Authority’s Engineer are being specified
pursuant to the EPC Agreement dated ........... (the “Agreement), which has been
entered into between the [name and address of the Authority] (the “Authority”) and
.......... (the “Contractor”)# for [Reconstruction/Widening work from Km 49.00 to 52.800 of
NH-220 the state of Jharkhand on EPC mode. (Job No. NH-220(AP)2023-24/346) in the state
of Jharkhand on Engineering, Procurement, Construction (EPC) basis, and a copy of
which is annexed hereto and marked as Annex-A to form part of this TOR.

# - In case the bid of Authority’s Engineer is invited simultaneously with the bid of
EPC project, then the status of bidding of EPC project only to be indicated

(ii) The TOR shall apply to construction and maintenance of the Project Highway.

2. Definitions and interpretation

(i) The words and expressions beginning with or in capital letters and not defined herein
but defined in the Agreement shall have, unless repugnant to the context, the meaning
respectively assigned to them in the Agreement.

(ii) References to Articles, Clauses and Schedules in this TOR shall, except where the
context otherwise requires, be deemed to be references to the Articles, Clauses and
Schedules of the Agreement, and references to Paragraphs shall be deemed to be
references to Paragraphs of this TOR.

(iii) The rules of interpretation stated in Article 1 of the Agreement shall apply, mutatis
mutandis, to this TOR.

3. General

(i) The Authority’s Engineer shall discharge its duties in a fair, impartial and efficient
manner, consistent with the highest standards of professional integrity and Good
Industry Practice.

(ii) The Authority’s Engineer shall perform the duties and exercise the authority in
accordance with the provisions of this Agreement, but subject to obtaining prior
written approval of the Authority before determining:

(a) any Time Extension;

(b) any additional cost to be paid by the Authority to the Contractor;
(c) the Termination Payment; or
(d) issuance of Completion Certificate or

(e) any other matter which is not specified in (a), (b), (c) or (d) above and which
creates a financial liability on either Party.
219
(iii) The Authority’s Engineer shall submit regular periodic reports, at least once every
month, to the Authority in respect of its duties and functions under this Agreement.
Such reports shall be submitted by the Authority’s Engineer within 10 (ten) days of
the beginning of every month.

(iv) The Authority’s Engineer shall inform the Contractor of any delegation of its duties
and responsibilities to its suitably qualified and experienced personnel; provided,
however, that it shall not delegate the authority to refer any matter for the Authority’s
prior approval in accordance with the provisions of Clause 18.2.

(v) The Authority’s Engineer shall aid and advise the Authority on any proposal for
Change of Scope under Article 13.

(vi) In the event of any disagreement between the Parties regarding the meaning, scope
and nature of Good Industry Practice, as set forth in any provision of the Agreement,
the Authority’s Engineer shall specify such meaning, scope and nature by issuing a
reasoned written statement relying on good industry practice and authentic
literature.

4. Construction Period

(i) During the Construction Period, the Authority’s Engineer shall review and approve
the Drawings furnished by the Contractor along with supporting data, including the
geo-technical and hydrological investigations, characteristics of materials from
borrow areas and quarry sites, topographical surveys, and the recommendations of
the Safety Consultant in accordance with the provisions of Clause 10.1 (vi). The
Authority’s Engineer shall complete such review and approval and send its
observations to the Authority and the Contractor within 15 (fifteen) days of receipt of
such Drawings; provided, however that in case of a Major Bridge or Structure, the
aforesaid period of 15 (fifteen) days may be extended upto 30 (thirty) days. In
particular, such comments shall specify the conformity or otherwise of such Drawings
with the Scope of the Project and Specifications and Standards.

(ii) The Authority’s Engineer shall review and approve any revised Drawings sent to it by
the Contractor and furnish its comments within 10 (ten) days of receiving such
Drawings.

(iii) The Authority’s Engineer shall review and approve the Quality Assurance Plan
submitted by the Contractor and shall convey its comments to the Contractor within a
period of 21 (twenty one) days stating the modifications, if any, required thereto.

220
(iv) The Authority’s Engineer shall complete the review and approve of the methodology
proposed to be adopted by the Contractor for executing the Works, and convey its
comments to the Contractor within a period of 10 (ten) days from the date of receipt
of the proposed methodology from the Contractor.

(v) The Authority’s Engineer shall grant written approval to the Contractor, where
necessary, for interruption and diversion of the flow of traffic in the existing lane(s) of
the Project Highway for purposes of maintenance during the Construction Period in
accordance with the provisions of Clause 10.4.

(vi) The Authority’s Engineer shall review the monthly progress report furnished by the
Contractor and send its comments thereon to the Authority and the Contractor within
7 (seven) days of receipt of such report.

(vii) The Authority’s Engineer shall inspect the Construction Works and the Project
Highway and shall submit a monthly Inspection Report bringing out the results of
inspections and the remedial action taken by the Contractor in respect of Defects or
deficiencies. In particular, the Authority’s Engineer shall include in its Inspection
Report, the compliance of the recommendations made by the Safety Consultant.

(viii) The Authority’s Engineer shall conduct the pre-construction review of manufacturer's
test reports and standard samples of manufactured Materials, and such other
Materials as the Authority’s Engineer may require.

(ix) For determining that the Works conform to Specifications and Standards, the
Authority’s Engineer shall require the Contractor to carry out, or cause to be carried
out, tests at such time and frequency and in such manner as specified in the
Agreement and in accordance with Good Industry Practice for quality assurance. For
purposes of this Paragraph 4 (ix), the tests specified in the IRC Special Publication-11
(Handbook of Quality Control for Construction of Roads and Runways) and the
Specifications for Road and Bridge Works issued by MORTH (the “Quality Control
Manuals”) or any modification/substitution thereof shall be deemed to be tests
conforming to Good Industry Practice for quality assurance.

(x) The Authority’s Engineer shall test check at least 50 (fifty) percent of the quantity or
number of tests prescribed for each category or type of test for quality control by the
Contractor.

(xi) The timing of tests referred to in Paragraph 4 (ix), and the criteria for acceptance/
rejection of their results shall be determined by the Authority’s Engineer in
accordance with the Quality Control Manuals. The tests shall be undertaken on a
random sample basis and shall be in addition to, and independent of, the tests that
may be carried out by the Contractor for its own quality assurance in accordance with
Good Industry Practice.

(xii) In the event that results of any tests conducted under Clause 11.10 establish any
Defects or deficiencies in the Works, the Authority’s Engineer shall require the
Contractor to carry out remedial measures.

221
(xiii) The Authority’s Engineer may instruct the Contractor to execute any work which is
urgently required for the safety of the Project Highway, whether because of an
accident, unforeseeable event or otherwise; provided that in case of any work
required on account of a Force Majeure Event, the provisions of Clause 21.6 shall
apply.

(xiv) In the event that the Contractor fails to achieve any of the Project Milestones, the
Authority’s Engineer shall undertake a review of the progress of construction and
identify potential delays, if any. If the Authority’s Engineer shall determine that
completion of the Project Highway is not feasible within the time specified in the
Agreement, it shall require the Contractor to indicate within 15 (fifteen) days the
steps proposed to be taken to expedite progress, and the period within which the
Project Completion Date shall be achieved. Upon receipt of a report from the
Contractor, the Authority’s Engineer shall review the same and send its comments to
the Authority and the Contractor forthwith.

(xv) The Authority’s Engineer shall obtain from the Contractor a copy of all the
Contractor’s quality control records and documents before the Completion Certificate
is issued pursuant to Clause 12.2.

(xvi) Authority’s Engineer may recommend to the Authority suspension of the whole or
part of the Works if the work threatens the safety of the Users and pedestrians. After
the Contractor has carried out remedial measure, the Authority’s Engineer shall
inspect such remedial measures forthwith and make a report to the Authority
recommending whether or not the suspension hereunder may be revoked.

(xvii) In the event that the Contractor carries out any remedial measures to secure the
safety of suspended works and Users, and requires the Authority’s Engineer to inspect
such works, the Authority’s Engineer shall inspect the suspended works within 3
(three) days of receiving such notice, and make a report to the Authority forthwith,
recommending whether or not such suspension may be revoked by the Authority.

(xviii) The Authority’s Engineer shall carry out, or cause to be carried out, all the Tests
specified in Schedule-K and issue a Completion Certificate, as the case may be. For
carrying out its functions under this Paragraph 4 (xviii) and all matters incidental
thereto, the Authority’s Engineer shall act under and in accordance with the
provisions of Article 12 and Schedule-K.

5. Maintenance Period

(i) The Authority’s Engineer shall aid and advise the Contractor in the preparation of its
monthly Maintenance Programme and for this purpose carry out a joint monthly
inspection with the Contractor.

(ii) The Authority’s Engineer shall undertake regular inspections, at least once every
month, to evaluate compliance with the Maintenance Requirements and submit a
Maintenance Inspection Report to the Authority and the Contractor.

222
(iii) The Authority’s Engineer shall specify the tests, if any, that the Contractor shall carry
out, or cause to be carried out, for the purpose of determining that the Project
Highway is in conformity with the Maintenance Requirements. It shall monitor and
review the results of such tests and the remedial measures, if any, taken by the
Contractor in this behalf.

(iv) In respect of any defect or deficiency referred to in Paragraph 3 of Schedule- E, the

Authority’s Engineer shall, in conformity with Good Industry Practice, specify the
permissible limit of deviation or deterioration with reference to the Specifications and
Standards and shall also specify the time limit for repair or rectification of any
deviation or deterioration beyond the permissible limit.

(v) The Authority’s Engineer shall examine the request of the Contractor for closure of
any lane(s) of the Project Highway for undertaking maintenance/repair thereof, and
shall grant permission with such modifications, as it may deem necessary, within 5
(five) days of receiving a request from the Contractor. Upon expiry of the permitted
period of closure, the Authority’s Engineer shall monitor the reopening of such
lane(s), and in case of delay, determine the Damages payable by the Contractor to the
Authority under Clause 14.5.

6. Determination of costs and time

(i) The Authority’s Engineer shall determine the costs, and/or their reasonableness, that
are required to be determined by it under the Agreement.

(ii) The Authority’s Engineer shall determine the period of Time Extension that is
required to be determined by it under the Agreement.

(iii) The Authority’s Engineer shall consult each Party in every case of determination in
accordance with the provisions of Clause 18.5.

7. Payments

(i) The Authority’s Engineer shall withhold payments for the affected works for which
the Contractor fails to revise and resubmit the Drawings to the Authority’s Engineer
in accordance with the provisions of Clause 10.2 (iv) (d).

(ii) Authority’s Engineer shall -

(a) within 10 (ten) days of receipt of the Stage Payment Statement from the
Contractor pursuant to Clause 19.4, determine the amount due to the
Contractor and recommend the release of 90 (ninety) percent of the amount
so determined as part payment, pending issue of the Interim Payment
Certificate; and

(b) within 15 (fifteen) days of the receipt of the Stage Payment Statement
referred to in Clause 19.4, deliver to the Authority and the Contractor an
Interim Payment Certificate certifying the amount due and payable to the
Contractor, after adjustments in accordance with the provisions of Clause
19.10.

223
(iii) The Authority’s Engineer shall, within 15 (fifteen) days of receipt of the Monthly
Maintenance Statement from the Contractor pursuant to Clause 19.6, verify the
Contractor’s monthly statement and certify the amount to be paid to the Contractor in
accordance with the provisions of the Agreement.

(iv) The Authority’s Engineer shall certify final payment within 30 (thirty) days of the
receipt of the final payment statement of Maintenance in accordance with the
provisions of Clause 19.16.

8. Other duties and functions

The Authority’s Engineer shall perform all other duties and functions as specified in
the Agreement.

9. Miscellaneous

(i) A copy of all communications, comments, instructions, Drawings or Documents sent

by the Authority’s Engineer to the Contractor pursuant to this TOR, and a copy of all
the test results with comments of the Authority’s Engineer thereon, shall be furnished
by the Authority’s Engineer to the Authority forthwith.

(ii) The Authority’s Engineer shall retain at least one copy each of all Drawings and
Documents received by it, including ‘as-built’ Drawings, and keep them in its safe
custody.

(iii) Within 90 (ninety) days of the Project Completion Date, the Authority’s Engineer shall
obtain a complete set of as-built Drawings, in 2 (two) hard copies and in micro film
form or in such other medium as may be acceptable to the Authority, reflecting the
Project Highway as actually designed, engineered and constructed, including an as-
built survey illustrating the layout of the Project Highway and setback lines, if any, of
the buildings and structures forming part of Project Facilities; and shall hand them
over to the Authority against receipt thereof.

(iv) The Authority’s Engineer, if called upon by the Authority or the Contractor or both,
shall mediate and assist the Parties in arriving at an amicable settlement of any
Dispute between the Parties.

(v) The Authority’s Engineer shall inform the Authority and the Contractor of any event
of Contractor’s Default within one week of its occurrence.

224
 Schedule - O
(See Clauses 19.4 (i), 19.6 (i), and 19.8 (i))
Forms of Payment Statements
1. Stage Payment Statement for Works

The Stage Payment Statement for Works shall state:

(a) the estimated amount for the Works executed in accordance with Clause 19.3
(i) subsequent to the last claim;
(b) amounts reflecting adjustments in price for the aforesaid claim;

(c) the estimated amount of each Change of Scope Order executed subsequent to
the last claim;

(d) amounts reflecting adjustment in price, if any, for (c) above in accordance
with the provisions of Clause 13.2 (iii) (a);
(e) total of (a), (b), (c) and (d) above;
(f) Deductions:

i. Any amount to be deducted in accordance with the provisions of the

Agreement except taxes;
ii. Any amount towards deduction of taxes; and
iii. Total of (i) and (ii) above.
(g) Net claim: (e) – (f) (iii);
(h) The amounts received by the Contractor upto the last claim:
i. For the Works executed (excluding Change of Scope orders);
ii. For Change of Scope Orders, and
iii. Taxes deducted

2. Monthly Maintenance Payment Statement

The monthly Statement for Maintenance Payment shall state:

(a) the monthly payment admissible in accordance with the provisions of the
Agreement;
(b) the deductions for maintenance work not done;
(c) net payment for maintenance due, (a) minus (b);
(d) amounts reflecting adjustments in price under Clause 19.12; and
(e) amount towards deduction of taxes

3. Contractor’s claim for Damages

Note: The Contractor shall submit its claims in a form acceptable to the Authority.

225
 Schedule - P

(See Clause 20.1)

Insurance

1. Insurance during Construction Period

(i) The Contractor shall effect and maintain at its own cost, from the Appointed Date till
the date of issue of the Completion Certificate, the following insurances for any loss or
damage occurring on account of Non Political Event of Force Majeure, malicious act,
accidental damage, explosion, fire and terrorism:

(a) insurance of Works, Plant and Materials and an additional sum of [15
(fifteen)] per cent of such replacement cost to cover any additional costs of
and incidental to the rectification of loss or damage including professional fees
and the cost of demolishing and removing any part of the Works and of
removing debris of whatsoever nature; and

(b) insurance for the Contractor's equipment and Documents brought onto the
Site by the Contractor, for a sum sufficient to provide for their replacement at
the Site.

(ii) The insurance under sub para (a) and (b) of paragraph 1(i) above shall cover the
Authority and the Contractor against all loss or damage from any cause arising under
paragraph 1.1 other than risks which are not insurable at commercial terms.

2. Insurance for Contractor's Defects Liability

The Contractor shall effect and maintain insurance cover of not less than 15% of the
Contract Price for the Works from the date of issue of the Completion Certificate until
the end of the Defects Liability Period for any loss or damage for which the Contractor
is liable and which arises from a cause occurring prior to the issue of the Completion
Certificate. The Contractor shall also maintain other insurances for maximum sums as
may be required under the Applicable Laws and in accordance with Good Industry
Practice.

3. Insurance against injury to persons and damage to property

(i) The Contractor shall insure against its liability for any loss, damage, death or bodily
injury, or damage to any property (except things insured under Paragraphs 1 and 2 of
this Schedule or to any person (except persons insured under Clause 20.9), which
may arise out of the Contractor's performance of this Agreement. This insurance shall
be for a limit per occurrence of not less than the amount stated below with no limit on
the number of occurrences.

The insurance cover shall be not less than: Rs. [*****]

226
(ii) The insurance shall be extended to cover liability for all loss and damage to the
Authority's property arising out of the Contractor’s performance of this Agreement
excluding:

(a) the Authority's right to have the construction works executed on, over, under,
in or through any land, and to occupy this land for the Works; and

(b) damage which is an unavoidable result of the Contractor's obligations to

execute the Works.

4. Insurance to be in joint names

The insurance under paragraphs 1 to 3 above shall be in the joint names of the
Contractor and the Authority.

227
 Schedule-Q

(See Clause 14.10)

Tests on Completion of Maintenance Period

1. Riding Quality test:

Riding quality test: Riding quality of each lane of the carriageway shall be checked
with the help of a calibrated bump integrator and the maximum permissible
roughness for purposes of this Test shall be [2,200 (two thousand and two hundred
only)] mm for each kilometer.

2. Visual and physical test:

The Authority’s Engineer shall conduct a visual and physical check of construction to
determine that all works and equipment forming part thereof conform to the provisions
of this Agreement. The physical tests shall include measurement of cracking, rutting,
stripping and potholes and shall be as per the requirement of maintenance mentioned in
Schedule-E.

228
Following circulars may be followed:
1. RW/NH-37010/4/2010-EAP (Printing) Vol. IV dated 05.03.2019
2. RW/NH-24035/4/2008-P & M/PIC Vol. II dated 23.02.2018
3. RW/NH-34066/14/2018-S&R (R&B) dated 25.06.2018.
4. RW/NH-11060/1/98-(DO-I) dated 05.11.1998
5. RW/NH-34049/01/2020-S&R (P&B) pt. dated 22.02.2023
6. NH-37015/01/2022-H (Comp. No. 208778) dated 29.02.2024

Schedule-R

(See Clause 14.10)

Taking Over Certificate

I, ……………………. (Name and designation of the Authority’s Representative) under and in

accordance with the Agreement dated ………… (the “Agreement”), for [] (the “Project
Highway”) on Engineering, Procurement and Construction (EPC) basis through ………………….
(Name of Contractor), hereby certify that the Tests on completion of
Maintenance Period in accordance with Article 14 of the Agreement have been successfully
undertaken to determine compliance of the Project Highway with the provisions of the
Agreement and I hereby certify that the Authority has taken over the Project highway from
the Contractor on this day.........

229
 SIGNED, SEALED AND DELIVERED

(Signature)

(Name and designation of Authority’s Representative)

(Address)

230
231
***** End of the Document *****

232