COMMUNICATION AND WORKS DEPARTMENT

Punjab Building Department (Central Zone)

Bid No. …………………….

INSTALLATION OF 2-CUSIC CAPACITY TUBE WELL WITH CHAMBER

(04-NOS) AT AIKMAN ROAD, PATIALA HOUSE, DANEPUR ROAD
IN GOR-I & GOR-III, LAHORE.

Date: 28 January, 2025

EXECUTIVE ENGINEER, BUILDING DIVISION GORs, LAHORE

PWD Compound, 6-Mecload Road Lahore.
Phone No.042-99205169
 Section-I: Invitation to Bids

BIDDING DOCUMENTS FOR THE.

1. Tenders based on item rates are hereby invited, for the works mentioned below from the
contractors / firms enlisted / renewed with PEC for the current financial year in the relevant
category.

Earnest Money
Lot.# Name of Work Estimated Cost 2% of estimated T.S No & date Time limit
cost
1. Installation of 2-Cusic Capacity Tubewells
C.E.
with Chamber (4-Nos) at Aikman Road,
Rs.44,101,608/- Rs.882,100/- No.CEB(CZ)/170/W(3) 90-Days
Patiala House, Danepur Road in GOR-I and
Dated.15.12.2024
GOR-III, Lahore.

2. The prospective bidders are to submit earnest money in the form of a CDR/ Bank draft/
Cashier’s cheque of any scheduled bank at 2% of the estimated cost to the office of the
Executive Engineer, Buildings Division GORs, Lahore before the deadline for submission of
bid on website. Conditional tenders and tenders not accompanied with earnest money shall
be rejected..
3. The complete E-bids must be submitted online on e-Procurement System (EPADS)
website i.e., https://punjab.eprocure.gov.pk as per the following schedule:

E-bid Submission 28 January, 2025 @ 12:00 PM

Date & Time
E-bid Opening
28 January, 2025 @ 12:30 PM
Date & Time

4. Original Bid Security Instrument must be submitted in an envelope clearly marked with
the Bidding Document Number and Title, before the E-bid Submission deadline in the
Office of Executive Engineer, Buildings Division GORs, Lahore.
Bidders are advised to ensure uploading the Bid on E-PADS Portal, well before the
submission deadline, and not wait for the last date and time to upload the bid. Bid
submission on E-PADS Portal shall entirely be the responsibility of the bidder. The
Department shall not be held responsible for any issues thereof. For any assistance
regarding E-PADS Portal, system support email and phone numbers are provided
hereunder:
5. Bidding Documents are immediately available after date of publication.
The Department will not be responsible for any cost or expense incurred
by Bidders in connection with the preparation or delivery of E-bids. In
case of official holiday on the day of submission, next day will be treated
as closing date.

Page 2 of 53
Page 3 of 53
Para No. INDEX Page No.

GENERAL DIRECTIONS FOR THE TENDERS

1 Preparation and submission of tender. 7

2 Purchase of contract documents. 7
3 Cost of preparation and submission of tender. 7
4 Tender to include only one work 7
5 Schedule of material and equipment to be supplied by Government. 7
6 Responsibility for quality and specifications. 7
7 Inspection of site. 7
8 Rates in the bid schedule. 7-8
9 Amount of tender. 8
10 Addition and alteration in the bid schedule. 8
11 Unattested corrections. 8
12 Additional clauses. 8
13 Quantities in bid schedule for comparing tenders. 8-9
14 Earnest money. 9
15 Forfeiture of earnest money. 9
16 Signing of tender. 9
17 Sufficiency of tender. 9
18 Modification and withdrawal of tender/validity period of tender. 10
19 Tender to be in sealed cover. 10
20 Tenderer to give his address. 10
21 Presentation of tender implies acceptance of conditions. 10
22 Late tender 10
23 Opening of tender 10
24 Evaluation and comparison of tenders. 10
25 Process to be confidential. 11
26 Clarification of bids after opening tender. 11
26 A Quality Assurance Security 11
27 Rejection of tender. 11
28 Tender amount includes all taxes, duties and obligations 12
29 Notification of award. 12
30 Sighing of contract agreement. 12
31 Notifications of successful and un-successful tenderers. 12
32 Reckoning of completion period. 12
33 Contractor may obtain a copy of contract agreement his cost 12

TENDER FOR WORK

1 Tender 13-14
2 Memorandum of work. 15-16
3 Bid schedule. 17-18
GENERAL CONDITIONS OF CONTRACT
DEFINITIONS AND INTERPRETATIONS
Clause No.
1 Definitions 20-21
2 Marginal headings for information only. 21
3 Terms to include designation of corresponding posts. 21
Page 4 of 53
 CONTRACT DOCUMENTS
4 Documents mutually explanatory. 22
5 Custody of drawings 22
Classified drawings
One copy of drawings to be kept on site
Further drawings and instructions.

GENERAL OBLIGATIONS
6 Contract agreement. 23
7 Performance Guarantee/ Quality Assurance Security. 23
8 Programme of work to be furnished, 23
if so required by the Engineer-in-charge
Action when Programme not submitted in time.
9 Setting out. 24
10 Work to be executed in accordance with the specifications, 24
drawings, orders, etc.
11 Action where no specifications are provided 24
12 Work to be under directions of Engineer-in-charge 24
13 Lighting at night work 25
14 Arrangement to safeguard danger to unfinished work 25
15 Contractor to supply plant, Ladders, scaffoldings, etc 25
Contractor liable to pay damages arising from non-provision
of lights, fencing, etc.
16 Notice to be given before the work is covered up 25-26
17 Contractor’s employees
Removal of Contractor’s employees
18 Whole time qualified technical personnel for supervision of work 26
19 Opportunities for other contractors 27
20 Damage to persons and property 27
Indemnity by Government
21 Work to be open to inspection 28
Contractor or his responsible agent to be present
22 Giving of notices and payment of fees 28
Compliance of statutes, regulations, etc
Payment of income tax and other taxes
23 Cast of bonds 28
24 Change in the constitution of firm 28
25 Photographs and advertisements 28-29

ASSIGNMENT AND SUBLETTING

26 Assignment 29
27 Subletting 29

MATERIALS AND WORKMANSHIP

28 Quality of material and workmanship and tests 29

Cost of samples
Cost of tests
Cost of tests not provided for
29 Constructional materials, fittings to confirm to representative
samples approved by the Engineer-in-charge 30
Page 5 of 53
 30 Stores and equipment to be supplied by Government 30
31 Action and compensation payable in case of bad work 30-31

LABOUR

32 Application of Labour laws rules 31

33 Contractor liable for payment of compensation to injured 31
workman or in case of death to his relations
34 Use of donkeys and other animals 31-32

COMMENCEMENT, TIME AND DELAYS

35 Commencement of work 32
36 Time for completion 32
37 Extension of time for completion 32
38 No work at night or on Sunday / Public Holidays 32
39 Compensation for delay 32-33
Rate of Progress
Compensation for inadequate funding

CERTIFICATE OF COMPLETION
40 Certification of completion of work 33-34

ALTERATIONS, ADDITIONS AND OMISSIONS

41 Alterations in specifications and drawings 34

Alterations omissions, substitutions do not invalidate the contract
Extension of time in consequence of alterations
Rate of works not in bid schedule or in the estimates.
42 No compensation for alteration in or restriction of work to be carried 35
out if variation does not exceed 20%.
Variation exceeding 20%

MAINTENANCE AND DEFECTS.

43 Period of maintenance 36
Execution of works of repair etc.
Cost of execution of works of repair, etc.
Remedy on contractor’s failure to carry out work required
44 Contractor liable to make good damages, and for any 36-37
imperfection noticed during period of maintenance

ADVANCES TO CONTRACTOR

45 Secured advance on materials brought to site 37

PAYMENTS

46 Bills to be or prescribed form 37

47 Bills to be submitted monthly 37
47 (A) Payment of items with imbalance rates 37-38
48 Deduction of security deposit 38
Page 6 of 53
49 Conversion of security deposit in to profit bearing securities 38
50 Refund of security deposit 38-39

51 Payment on intermediate certificate to be regarded as advances 39

52 Final bill to be submitted within one month 39
53 Procedure for payment to firms 39
54 Sums payable by way of compensation to be considered
as reasonable compensation without reference to actual loss 39-40

VARIATION IN PRICES OF SPECIFIED MATERIALS

55 Price variation 40-42

CLAIMS OF CONTRACTOR

56 Bills to be submitted monthly 42

57 Claims for payment of extraordinary nature to be 42
referred to Government for decision
58 Time limit for unforeseen claims 42
59 Claims for compensation for the delay in the execution of works 42

REMEDIES AND POWERS

60 Action where whole of security deposit is forfeited 43

61 Work at the risk and expense of contractor 43-44
62 Contractor remains liable to pay compensation
if action not taken under clauses
Powers to take possession of or require removal of or sell
contractor’s plant, etc.
63 Contract may be rescinded and security forfeited for subletting, 45
bribing or if contractor becomes insolvent
64 Deduction of amount due to Government on any account whatsoever
to be permissible from sums payable to the contractor 45

SETTLEMENT OF DISPUTES

65 Procedure in disagreement 45
Contractor dissatisfied with the decision of the Superintending
Engineer 46
Increase in amount of claim once preferred not allowed 46
Reference to arbitration 46
Dispute for arbitration limited 46
Arbitration 47
Schedule of materials to be supplied by Government 47
Schedule of equipment to be supplied by Government 47
Names of manufacturers of specified materials for base rate 48
Contract agreement 49-50
Specimen of Bank Guarantee to be furnished by the
contractor in lieu of performance security 51-52
Specimen of Bank Guarantee for release of security deposit

Page 7 of 53
 Stereo I.B No.386 (Revised)
Stereo I.B No.389 (Revised) Agreement No.
Stereo B&R No.28 (Revised)
Stereo B&R No.29 (Revised)

GOVERNMENT OF THE PUNJAB

___________DEPARTMENT

___________ CIRCLE

___________DIVISION

__________SUB-DIVISION

PERCENTAGE / ITEM RATE TENDER AND CONTRACT FOR WORKS

1. Name of work

2. Estimated cost Rs.

(both in figures and words)

3. Time for completion

4. Amount of earnest money Rs. (in figures)

Rupees (in words)

5. Issued to
(Name of the contractor)

6. On payment of Rs.
(Both in words and figures)

Signature
(Official issuing the form)

Dated

Office stamp

Note: - The officer opening the tender shall reject the tender which does not bear the stamp and
signature of the issuing official and which is not submitted by the same contractor to whom
the tender form was issued.
(This page is to be filled in by the issuing official)

Page 8 of 53
 GENERAL DIRECTIONS FOR THE GUIDANCE OF THE TENDERERS

1. These directions are provided to assist the tenderer in preparing and submitting his tender.
The tender shall contain all information and data required to be furnished and shall be prepared
and submitted in accordance with the instructions set forth herein.

2. All necessary documents, such as copies of specifications (excluding standard

specification books etc), contract documents, including bill of quantities, estimated rates and any
other documents required in connection with the preparation of tender or execution of works,
signed by the Engineer-in-charge will accompany the tender form and the cost of such annexed
documents will be reflected in the cost of the tender form.

3. The tenderer will not be reimbursed for any costs of any kind, whatsoever, incurred in
connection with the preparation and submission of his tender.

4. No single tender shall include more than one work. A tenderer who wishes to tender for
two or more works shall submit tender for each work, separately.

5. The memorandum of work tendered for, and the schedule of materials and equipment to
be supplied by the Engineer-in-charge and the rates at which they are to be charged for (annexed
hereto) shall be filled in the office of the Engineer-in-charge before the tender form is issued. At
this stage the tenderer should ensure that the tender form so issued is complete in all respects.

6. The tenderer shall note that the ultimate responsibility for the quality of work and its
conformity with the specifications and drawings rests solely with the successful bidder whose
tender is accepted.

7. The tenderer shall at his own expense, inspect and examine the site and surroundings
and obtain for himself, on his own responsibility, all information that may be necessary for
preparing the tender and entering into contract, and shall determine and satisfy himself by such
means as he may consider necessary or desirable as to all matters pertaining to the tender. The
tenderer shall also satisfy himself before submitting his tender as to the nature of grounds,
hydrological and climatic conditions, the form and nature of the site, the nature and lay out of the
terrain, the availability of labour, water, electric power and transportation facilities in the area. The
tenderer shall specially investigate into the sources of materials to be used for the works and
satisfy himself about the quality and quantities of materials available for the completion of the
work and the means of access to the site, the accommodation he may require and, in general,
shall himself obtain all necessary information, as to the risks, contingencies and other
circumstances which may influence or affect his tender. The Engineer-in-charge shall not assume
any responsibility regarding information gathered, interpretation or deduction which the tenderer
may arrive at, from the data that may be furnished with the contract documents.

8. (a) The tenderer shall fill up the bid schedule.

(b) In case tenders are called on item rate basis, the tenderer shall quote his own unit
rate in the bid schedule on which he is willing to under take each item of work.

Page 9 of 53
9. (i) The tenderer shall work out the amount against each item of work in the bid schedule
and will indicate the total amount of his tender on which he is willing to complete the works. The
total amount worked out in the bid schedule shall be entered by the tenderer in his tender as his
tender price for the work in case of discrepancy between amounts in figures and in words the
amount in words shall prevail.
(ii) Should any discrepancy be found in the amount of pay items or if a column of amount
is found blank after filling in a unit rate, the unit rate filled by the tenderer will be extended in
working out of the amount of the tender and the total amount of the bid schedule will be adjusted
accordingly.
(iii) If a unit rate is left blank, but the amount against the item is filled, the unit rate will be
worked out on the basis of the amount divided by the quantity of the item shown in the bid schedule
(iv) If it is found that the tenderer has not entered any unit rate and amount against any of
the pay items of the bid schedule, the Engineer-in-charge shall fill in the blanks by noting the word
“Nil” in such blanks at the time of opening of the tender. Such pay items shall be deemed to be
covered by the rates of other items.
(v) If the tenderer does not accept the adjusted/corrected amount of tender according to
the above provision, his tender shall be rejected and the earnest money forfeited.

10 The tender which proposes any alteration in the works specified in the bid schedule or in
the time allowed for carrying out the works or in any other condition mentioned by the Engineer-
in-charge, will be liable to rejection. The tenderer shall sign each and every page of the tender
and contract documents, without making any alteration. All enclosures issued with the contract
documents, shall be attached with the tender duly signed by the tenderer. Any addition or
alteration made after filling the form shall be duly attested by the tenderer. Non-compliance of this
condition shall render the tender liable to rejection.

11 The tenderer shall fill in the tender documents in ink: Errors, if any, shall be scored out
and corrections rewritten legibly and attested by the tenderer. Any addition or alternation made
after filling the form shall be duly attested by the tenderer. Non-compliance of this condition shall
render the tender liable to rejection. Any tender with unattested correction shall be attested by the
tenderer in the presence of other tenderers at the time of opening of the tender except that no
correction shall be permissible in the rate or amount of the bid schedule or in the tendered price
after the opening of the tender.

12 Additional clause(s) for a particular work shall be typed on separate sheets by the
Engineer-in-charge, which will be annexed to the contract documents specifying the number of
sheets(s). The tenderer shall not add or delete any additional clause(s) in the additional clause(s)
sheet(s), provided by the Engineer-in-charge.

13 The quantities mentioned in the bid schedule are estimated quantities, to be used for
preparing tenders, and the Engineer-in-charge does not expressly nor by implication agree that
the actual amount of works to be performed will correspond therewith. No payment will be made
on account of anticipated profits for work covered by the contract which is not performed, nor will
any adjustment in the unit rates set forth in the bid schedule be made because of an increase or
decrease in the actual quantities from the estimated quantities indicated therein,

Page 10 of 53
except as determined in accordance with the provisions of clause 42 of the general conditions of
contract.

14 No tender without earnest money shall be entertained. Earnest money, calculated @ 2%

of the estimated cost of the work (rounded suitably), shall be in the form of deposit at call receipt.
The earnest money of the unsuccessful tenderers shall normally be returned by the Engineer-in-
charge within a week of opening of the tenders and in any case not later than thirty
(30) days following the date set for opening of tenders except in cases where the tenders are to
be accepted by the Chief Engineer, in those cases the earnest money of only the three lowest
bidders will be retained and returned to the unsuccessful bidders not later than sixty (60) days of
opening of the tenders. In the event of the tender being accepted, a receipt for the earnest money
forwarded therewith, shall there upon be given to the contractor. The earnest money of the
successful tenderer on execution of the contract covering work will be adjusted towards the
amount of security deposit to be retained from the first amounts(s) payable to the contractor under
the contract.

15 The lowest evaluated bidder will be required to furnish the performance guarantee / quality
assurance security (wherever required) before entering into a contract. Should the lowest
evaluated bidder refuse or fail for any reason to furnish the performance guarantee / quality
assurance security, it should constitute a just cause for rejection of his tender / annulment of
award and in event of such rejection / annulment, the entire earnest money shall be forfeited to
Government, as compensation for such default.
16 (i) The tender shall be signed by the person(s) duly authorized to do so. In the event of a
tender being submitted by a firm, it shall be signed separately by each member thereof, or in the
event of the absence of any partner, it shall be signed on his behalf by a person holding a power
of attorney authorizing him to do so. Such power of attorney should be produced with the tender
and it must disclose that the firm is duly registered under the partnership Act, 1932 or any other
law in force.
(ii) The tender submitted by a joint venture of two or more firms shall be accompanied by
a document of formation of the joint venture, duly registered and authenticated by a competent
court, in which shall be stated precisely, the conditions under which it shall function, its period of
validity, the person(s) authorized to represent it and accept its obligations the participation of
several firms forming the joint venture and any other information necessary to permit a full
appraisal of its function.
(iii) A tender submitted by a corporation must bear the seal of the corporation and be
attested by its Secretary.
(iv) In all cases, the tender must be signed by an individual or individuals having powers
to legally bind the firm, joint venture, corporation or companies on whose behalf they are signing.

17 Each tenderer shall be deemed to have satisfied himself before tendering as to the
correctness and sufficiency of his tender and of the rates and prices stated in the bid schedule,
which rates and prices shall, except in so far as it is otherwise expressly provided in the contract,
cover all obligations under the contract and all matters and things necessary for the proper
completion and maintenance of the work.

Page 11 of 53
18 The tenderer may modify or withdraw his tender after submission, provided that the
modification or notice of withdrawal is received in writing by the Engineer-in-charge prior to the
prescribed deadline for submission of tenders. The tenderer’s modification or notice of withdrawal
shall be prepared, sealed, marked and delivered, with the inner envelopes additionally marked
“MODIFICATION OR WITHDRAWAL” as appropriate. No tender may be modified subsequent
to the deadline for submission of tenders. Withdrawal of a tender during the interval between the
deadline for submission of tenders and the expiration of the period of tender validity i.e. sixty (60)
days as specified by the tenderer in the form of tender may result in the forfeiture of the tender
security.

19 The tenderer shall submit the original tender documents complete in all respect and keep
a copy of the tender for his own record. The original should be sealed in an inner and an outer
envelope, duly marking the envelopes as “ORIGINAL”. The inner and outer envelopes shall (a)
be addressed to (Executive Engineer), (b) and bear the following identifications: Tender for (Name
of Contract), (Reference Number of Tender), and the words “DO NOT OPEN BEFORE (Time and
Date, set for opening)”. The inner envelopes shall indicate the name and address of the tenderer
to enable the tender to be returned unopened in case it is declared to have been received late is
otherwise unacceptable. If the outer envelope is not sealed and marked as instructed above, the
Engineer-in-charge will assume no responsibility for the misplacement or premature opening of
the tender submitted. A tender opened prematurely because of improper identification will be
rejected.

20 The tenderer shall indicate in the space provided in the tender his full and proper address
at which notices may be legally served on him and at which all correspondence in connection with
his tender and the contract is to be sent.

21 The presentation of tender implies full acceptance on the part of the tender of these
instructions and all other conditions set forth in the contract document.
22 Any tender received by the Executive Engineer (Engineer-in-charge) after the deadline for
submission of tenders prescribed in the Notice Inviting Tenders will be returned unopened to the
tenderer.

23 The Engineer-in-charge or his duly authorized officer (not below the rank of Assistant
Engineer/Sub Divisional Officers) will open tenders in the presence of intending tenderers or their
authorized agents, who may be present at the time. The officer opening the tender will announce
the names of the tenderer, tender rates and the presence of requisite tender security.

24 Promptly after the opening of Tenders, the Engineer-in-charge will undertake a detailed
evaluation of tenders. The Engineer-in-charge will determine whether each tender is substantially
responsive to the requirements of the tender documents and conforms to all the terms, conditions
and specifications of the tender documents without material deviation or reservation. If a tender
is not substantially responsive to the requirements of the tender documents, it will be rejected by
the Engineer-in-charge, and may not subsequently be made responsive by the tenderer having
corrected or withdrawn the non-confirming deviation or reservation.

Page 12 of 53
25 Except for information to be read out by the Engineer-in-charge at the time of opening
tenders in accordance with para 23 above, no information relating to the examination, clarification,
evaluation and comparison of tenders and recommendations concerning the award of contract
shall be disclosed to tenderers or other persons not officially concerned with such process. Any
effort by a tenderer to influence the process of examination, clarification, evaluation and
comparison of tenders, an in decisions concerning award of contract, may result in the rejection
of his tender.
26 To assist in the examination, evaluation and comparison of tenders, the Engineer-in-
charge may ask tenderers individually for clarification of their tenders, including breakdowns of
unit rates. The request for clarification and the response shall be in writing or by cable, but no
change in the price or substance of the tender shall be sought, offered or permitted except as
required to confirm the correction of arithmetical errors discovered by the Engineer-in-charge
during the evaluation of the tender.
26(A) In case the total tendered amount is equal to or less than 5% of the approved estimated
(DNIT) amount, the lowest bidder will have to deposit quality assurance security from the
Scheduled Bank equal to the amount of difference between approved DNIT amount and the
quoted bid amount as given below, within 15 days of issuance of notice or with in expiry period of
bid, whichever is earlier:

26 (B) Lowest evaluated bidder shall, within 15 days of receipt by him of a notice in this regard,
furnish to the tender approving authority in cash, bank draft, cashier’s cheque, payment order or
bank guarantee (valid for three months beyond completion time/extended completion time) from
any scheduled Bank of Pakistan, the amount to make up performance guarantee and / or quality
assurance security (wherever required) and specified in the tender in item (h) of Memorandum of
work. Should the lowest evaluated bidder refuse or fail for any reason to furnish the performance
guarantee and / or quality assurance security (wherever required) within the specified time, it
should constitute a just cause for rejection of his tender and in the event of such rejection the
entire earnest money shall be forfeited to government as compensation for such default.

27 The Engineer-in-charge shall have the right of rejecting all or any of the tenders without
assigning any reason thereof. The Engineer-in-charge will not be bound to award the contract to
the lowest or to any other tenderer.

Page 13 of 53
28 The unit rates and prices entered in the bid schedule will be the rates at which the
contractor will be paid (Subject to the adjustment specified in Clause 55 of the annexed
conditions) and shall be deemed to include all costs of performing the work, including income tax,
super tax, and/or other charges, duties and taxes of the Government, autonomous, semi-
autonomous and local bodies, profits and costs of accepting the general risk, liabilities and
obligations set forth in or implied from the contract.

29 Prior to the expiration of the period of tender validity (60 days) prescribed in the tender
form or any extension thereof that may have been granted by the tenderer, the Engineer-in-
charge will notify the successful tenderer by cable and confirm in writing by registered letter that
his tender has been accepted. This letter of acceptance shall name the sum which will be paid in
consideration of the execution, completion and maintenance of the works as prescribed in the
contract, (hereinafter called the contract price). The notification of award will constitute the
formation of the contract.

30. At the time, the Engineer-in-charge informs the lowest bidder in writing, bidder will provide
performance guarantee / quality assurance security (wherever required) within fifteen (15) days
from receipt of letter, failing which his bid will be rejected and bid security will be forfeited..

31 After the successful tenderer has signed the contract and furnished adequate performance
guarantee and / or quality assurance security (wherever required) the Engineer-in-charge will
notify to the unsuccessful tenderers that they were unsuccessful.

32 The completion period will be reckoned from the date of delivering the award or the
handing over of the site to the contractor, whichever is later.

33 A copy of the contract agreement may be obtained by the contractor at his own cost.

Page 14 of 53
 TENDER FOR WORK
To

The Executive Engineer,

Dear Sir,

I/We
(Name of the contractor)
the undersigned tenderer, having examined the conditions of contract, specifications, drawings,
bid schedule and addenda Nos. thereto, for the work
of
(Name of the work)
and the woks associated therewith, and having examined the site of the above named works, or
having caused the site to be visited on our behalf by my/our competent and reliable agent, and
having satisfied myself/ourselves as to all conditions under which the above named work must be
performed, hereby offer to execute, complete and maintain the whole of the above mentioned
work including its ancillary works associated therewith, in accordance with the said contract
documents, including the addenda indicated above, a tender price of Rs
(Rupees)
or such other sums as may be ascertained in accordance
with the said conditions of contract and the rates, and the prices set forth in the bid schedule.

2 As security for the due performance of the undertaking and obligations of this tender
I/We submit herewith a deposit at call receipt No.
Dated in the amount of Rs.
(Rupees)
from the Bank Branch drawn in your favour
or made payable to you as earnest money, the full value of which will be absolutely forfeited to
Government without prejudice to any other rights or remedies of the said Government, should
I/We withdraw or modify the tender within its validity period of sixty (60) days, following the date
of receipt of tender.

3. I/We understand that if my/our tender is accepted, the full value of the earnest money as
attached with the tender shall be detained by Government towards the amount of security deposit
specified in clause 48 of the said conditions of contract and item (d) of the memorandum of work.

4. Should this tender be accepted by you I/We hereby undertake:-

a) To sign all the necessary documents for entering into a contract agreement in the
form set out in the contract document within fifteen (15) days following your
notification of such acceptance.
b) To commence the work within the stipulated time named in item (f) of
memorandum hereto annexed following the date of issuance of your order to
proceed with or the handing over of the site, whichever is later and in the event of
my/our failure to do so, the entire amount of earnest money deposited by me/us
for which deposit at call receipt is enclosed herewith is to be absolutely forfeited to
the Government. On the commencement of the work, I/We hereby also agree to
abide by and fulfill all the terms or provisions of the said conditions of the contract
annexed hereto so far as applicable and in default thereof, to forfeit and pay to
Government the sums of money mentioned in the said conditions.

Page 15 of 53
 c) To complete and deliver the whole of the work comprised in the contract within the
time stipulated in item No.(g) of the memorandum hereto annexed, subject to such
extension in the time limit as may be granted under the conditions of contract.
5. I/We also agree that when materials and/or equipment for the work are provided by the
Government the rates to be paid for them shall be as provided in appendices annexed hereto.

6. I/We agree to abide by this tender for the period of sixty (60) days following the date set
for receiving of tenders and it shall remain binding upon me/us and may be accepted by you at
any time before the expiration of that period.

7. Unless and until a formal agreement is prepared and executed, this tender, together with
your written acceptance thereof, shall constitute a binding contract between us, and shall be
deemed for all purposes to be the contract agreement.

8. I/We understand that you are not bound to accept the lowest or any tender you may
receive, and that you will not defray any expenses incurred by me/us in tendering.
Thanking you,

Yours Faithfully,

(Signature of tenderer)

 Name

Dated this day Address

of __________________ 200

The above tender is hereby accepted by me on behalf of Government.

(Signature of Executive Engineer)

Division

 In case the above address is changed, the contractor will immediately notify in writing to
the Executive Engineer, his new address.

Page 16 of 53
 Memorandum of work
(To be filled in by the Government Department)
(a) General Description
(If several sub works are included, they should be detailed in a separate sheet).

(b) Estimate cost Rs.

(c) Amount of earnest money to

Accompany the tender Rs.
(to be furnished by the tenderer in the
shape of deposit at call from a scheduled
Bank of Pakistan).

(d) Percentage of security deposit to be retained from the bills.

i. On the amount of work done upto

Rs.5 million = Ten (10) percent.
ii. On the amount of work done beyond
Rs. 5 million = Five (5) percent.

(e) Minimum amount of interim running bills Rs.

(f) Mobilization period days.

(g) Time allowed to complete the work after the expiry

of mobilization period days.
(h) Amount of performance guarantee
Rs ----------- 5% of bid price in the case of bid price exceeding Rs 50 million as per General
Direction for the guidance of tenderer 26(B) read with general conditions of Contact
Clause (7) and amount of quality assurance security Rs ------- as per General Directions
for the guidance of tenderer 26(A).
(i) Period of maintenance. (after
the date of issuance of
certificate of completion)

Page 17 of 53
 “FORM D.F.R. (P.W.) 28-A”
(Referred to in Rule 7.36)
FORM OF GUARANTEE

WHEREAS a contract for work has been awarded by the Governor of the Punjab acting through
the Government of the Punjab Department (hereinafter
called the Government) to M/S (hereinafter called the contractor);

AND WHEREAS under the terms of the said contract the Government has agreed to advance a
sum of Rs. to the contractor for execution of the said work. The said amount shall
be recovered after lapse of 20% contract period or after the execution of the 20% of the work
(financial terms), whichever is earlier. The rate of recovery shall be 25% of the value of work done
in each interim pay certificate (running bill);

AND WHEREAS the Government has required the contractor to furnish a bank guarantee from
any scheduled bank for securing the payment of the sum advanced thereon:-

It is agreed as follows:-

1. I acting on behalf of (hereinafter called guarantor) hold

and firmly bind to the Government in the sum of
Rs. .(Rupees ) payable on the
same sum given as mobilization advance to the contractor.
2. The guarantor hereby undertakes to pay the said amount payable to the Government of the
Punjab on demand in case the contractor makes a default in the payment of said amount
under the terms and conditions of the contract.
3. The guarantee shall be irrevocable and shall remain in force till the sum advanced payable
thereon has been repaid in full by the contractor.
4. The liability of the guarantor shall in no case exceed the aggregate amount of
Rs. (Rupees ) payable thereon for the payment of
which the guarantor hereby undertakes to bind itself and promises to pay the whole or any
portion of this amount to the Government without making a reference to the contractor.

IN WITNESS whereof we the said guarantor have set out hands to this deed of guarantee
this Guarantor (Scheduled Bank)
2. This notification shall be applicable to future/new projects.

BY ORDER OF THE GOVERNOR OF THE PUNJAB

SECRETARY FINANCE

Page 18 of 53
 BID SCHEDULE
D.N.I.T FOR THE FOR INSTALLATION OF 2-CUSIC CAPACITY TUBE WELL WITH
CHAMBER (04-NOS) AT AIKMAN ROAD, PATIALA HOUSE, DANEPUR ROAD
IN GOR-I & GOR-III, LAHORE.
Amount of Work:- 44.102 (Million)
Earnest Money:- Rs.882,100/-
Time Limit:- 03-Months
Unit Rate Amount
Unit (To be filled in by (To be
Qty in the Contractor)
Sr.No Description of filled in by
Unit
Rate the
Rate Amount Contractor)
1 2 3 4 5 6 7
STANDARDIZED ITEM (Building Portion)
1 Excavation in foundation of building, bridges and other structures, including dabbling,
dressing, refilling around structure with excavated earth, watering and ramming lead upto
one chain (30 m) and lift upto 5 ft. (1.5 m) in ordinary soil. 2373 %o Cft
2 Providing, laying, watering and ramming brick ballast 1½" to 2"(40 mm to 50 mm) gauge
mixed with 25% sand, for floor foundation, complete in all respects.
396 % Cft
3 Pucca brick work in foundation and plinth ratio (1:6)

955 % Cft
4 P/L damp proof course of cement concrete 1:2:4 (using cement sand and shingle), i/c
bitumen coating with one coat of bitumen and one coat polythene sheets 500 gauge 1-
1/2" thick 491 % Sft
5 P/L of vertical damp proof course with cement sand plaster and bitumen coating Ratio
1:4. 1/2" thick
312 % Sft
6 Supply filling sand under floor are plugging in walls

231 % Cft

Page 19 of 53
7 Pucca brick work in ground floor ratio (1:6)

1530 % Cft
8 Reinforced cement concrete in roof slab, beams, columns lintels, girders and other
structural members laid in situ or precast laid in position, or prestressed members cast in
situ, complete in all respects 1:2:4 464 P-Cft
9 Fabrication of mild steel reinforcement for cement concrete, including cutting, bending,
laying in position, making joints and fastenings, including cost of binding wire and labour
charges for binding of steel reinforcement complete in all respect 40-Grade 1420 % Kg
10 Providing and fixing windows consisting of M.S. box section frame 2"x1½", (50x40mm)
leaves frame 1½"x1" (40x25mm) box section frame for glazing 3/8"x3/8" (10x10mm)
using 16 SWG sheet 'U' shaped rubber supported with 1"x1/8" (25x3mm) M.S. flat for
fixing 3/16" (5 mm) thick glass panes M.S. box section ½"x½" (13x13mm) of 16 SWG
for fixing 24 SWG wire gauze on outer side by means of ¾"x1/8" (20x3mm) M.S. flat
and screws including grill of M.S. flat ½"x1/8" (13x3mm) or ¼"x¼" (6x6mm) square bar
with independent frame of ½"x½" (13x13mm) box section of 16 SWG i/c all C.P. fitting
and painting 3 coats complete in all respect. 216 P-Sft
11 3/8"thick cement plaster under soffit of roof slabs only up to 20' height (1:3)
636 % Sft
12 ½”thick cement plaster 1:5 on walls
2215 % Sft
13 Dry rammed brick or stone ballast 1 1/2" to 2" gauge mix with 25% sand
222 % Cft
14 Providing and fixing marble strip of any shade for dividing Providing and fixing marble
strip of any shade for dividing Size 1½" x ¼" (40 x 6 mm)
414 P-Rft
15 1½"(40 mm) thick mosaic flooring, consisting of ½ "(13 mm) mosaic topping of one part
of cement and marble powder in the ratio of 3:1 and two parts of marble chips, laid over
1"(25 mm) thick floor of 1:2:4 cement concrete, including rubbing and polishing
complete with finishing :- 690 % Sft
16 Mosaic dado or skirting with one part of cement and marble powder in the ratio of 3:1
and two parts of marble chips, laid over ½"(13 mm) thick cement plaster 1:3, including
rubbing and polishing, complete with finishing: 1/2" thick 101 % Sft
17 Single layer of tiles 9"x4½"x1½" (225x113x40 mm) laid over 4"(100 mm) earth and 1"
(25 mm) mud plaster without Bhoosa, grouted with cement sand 1:3 on top of RCC roof
slab, provided with 34 lbs. per %Sft. or 1.72 Kg/Sq.m bitumen coating sand blinded i/c
polythene sheet 300 gauge 696 % Sft

Page 19 of 53
18 Cement pointing struck joint on walls up to 20" height 1:2 i/c cost of labour and material
for red oxide pigment in cement pointing to match with the colour of brick etc
2676 % Sft
19 ½” thick plaster 1:4 up to 20" height

765 % Sft
20 Cast iron rain water down pipe fixed in position, excluding heads and shoes, but i/c
painting and clamps 4" dia etc
52 P-Rft
21 Shoes, bends or offsets for cast iron rain water down pipe i/c fixing and painting
8 Each
22 Khurra on roof 2'x2'x6"
4 Each
23 Distempering new surface 3-coats
1856 % Sft
24 Providing and fixing mild steel chowkat of doors, windows, C.window, etc. including
holdfast, making and threading holes for hinges, etc. complete:-) M.S. angle iron 1½"x
1½"x ¼" (40x40x6 mm) welded with M.S. flat 2"x ¼" (50 mm x 6 mm)
112 P.Sft
25 Providing and fixing 1½" (40mm) thick solid flush door shutter complete in all respect.
101 P.Sft
26 Providing strong substantially built box of deodar wood 4x2½'x9" (1200x750x225 mm),
with compartments, lock compland locking arrangement, for preserving samples of
stratafrom bore hole. 4 P.Job
27 Direct rotary / reverse rotary drilling of borehole in all type soil expect shingle 20"to26"
dia 0 to 250 depth below ground level.

28 a. 0 to 250ft depth (20" to 26") 1000 P-Rft

29 b. 250 to 800ft depth (20" to 26") 2800 P-Rft
30 Providing installation of MS bail plug in tube well bore hole 10"I/d 2ft long etc 3 Each
31 Providing installation of MS bail plug in tube well bore hole 8"I/d 2ft long etc 1 Each
32 Providing istalling M.S blind pipe socket welded joints M.S reducer where necessary in
tube well bore hole i/c jointing with strainer etc complete a. 10"dia
1380 P-Rft
33 ---do--- 15"dia 960 P-Rft
34 ---do--- 12"dia 320 P-Rft
35 ---do--- 8"dia 460 P-Rft

Page 19 of 53
36 Providing and installing, brass strainer in tubewell bore hole, including sockets, special
sockets, studs, etc complete 10" dia 480 P-Rft
37 Providing and installing, brass strainer in tubewell bore hole, including sockets, special
sockets, studs, etc complete 8" dia 160 P-Rft
38 Shrouded with graded pea gravel 3/8" to 1/8" around tube well bore 6717 P-Cft
39 Testing and developing of tubewell of size 6" (150 mm) i/d and above continuously.
above 1.5 cs. Discharge 288 P-hours
40 Making foundation 3'x3'x3' of c/c 1:2:4 of bedplate of M.S sheet of 1/2"dia for fixing
turbine i/c cost of nut bolt 4 P-Job
41 Furnishing sample of water form bore hole per set of two No bottles 8 P-Set
42 Excavation of trenches in all kinds of soil, except cutting rock, for watersupply pipelines
upto 5 ft. (1.5 m) depth from ground level, including trimming, dressing sides, leveling
the beds of trenches to correct grade and cutting pits for joints, etc. complete in all
respects. 6852 %oCft
43 P/L M.S blind pipe line (5 mm) with M.S fangle welded at both ends full threaded nut
bolt washer (imported) rubber joint sheet wrapping of polythene sheet arround pipe after
bitumen coating (Jamal pipe)
44 8" dia 672 P.Rft
45 6" dia 200 P.Rft
46 Providing and fixing, sluice valve of B.S.S. quality andweight, for pipe line, with comet
jointand rubber ring, complete (including cost of jointing materials):-8" dia
4 Each
47 ---do--- 6" dia 8 Each
48 P/Air valve 2 1/2"dia quality & weight complete with jointing material, Double 4 Each
G.
Total 42001532

Page 19 of 53
 BID SCHEDULE (Contd.)

NAME OF WORK

Total tendered amount of the work

(To be filled in by the Tenderer)

Rs.

. Total cost of /item rates.

Rs.

Grand Total
Rs.

Rs.

(in words )
Rupees

Page 19 of 53
 GENERAL CONDITIONS OF CONTRACT
DEFINITIONS AND INTERPRETATIONS

Clause 1
In the contract (as herein after defined) the following words and expressions shall have the
meanings hereby assigned to them, except where the context otherwise requires: -

1) “Agent” means the person appointed by the contractor to act on his behalf in his
absence;

2) “Certificate of completion” means the certificate of completion given by the

Engineer-in-charge pursuant to clause 40 of these conditions;

3) “Contract” means the contract agreement, the documents set out therein and
includes the conditions of contract, the tender and acceptance thereof, the
specifications, the drawings, the bid schedule, schedule of rates ad the prices;

4) “Contractor” means the person or persons, firm or company whose tender has been
accepted by the Engineer-in-charge, and shall include the contractor’s duly
authorized representative, successors and assigns;

5) “Contract price” means the sum named in the tender, subject to such addition
thereto or deductions there from as may be made under the provisions of the
contract;

6) “Constructional Plant” means all appliances, or things required in or about the

execution, completion, or maintenance of the woks or temporary works, but does
not include the materials or other things intended to form or forming part of
permanent or temporary works;

7) “Drawings” means the drawing(s) referred to in the contract documents and any
modifications of such drawing(s) as may from time to time be furnished or approved
in writing by the Engineer-in-charge;

8) “Engineer-in-charge” means the Executive Engineer or any other officer who for the
time being and from time to time is in charge of the works and includes an officer
appointed by the Government to act as Engineer-in-charge for the purposes of the
contract;

9) “Government” means the Government of the Punjab;

9-a) “Item Rates” mean the rates determined on the basis of the market rates system
introduced by the Government in replacement of the Composite Schedule of Rates
1998 through Finance Department Notification No.RO (Tech) F.D.2-3/2004 dated
02.08.2004 (Annexure A).

10) “Period of maintenance” means the period during which the contractor is obliged to
guarantee the work or defined portions of work against defect and during which he

Page 20 of 53
 is obliged to perform any maintenance procedure that may be specified by the
Engineer-in-charge and shall be calculated from the date of the certificate of
completion given by the Engineer-in-charge in accordance with clause 40 hereof or
in the event of more than one certificate having been issued by the Engineer-in-
charge under the said clause from the respective dates so certified;

11) “Maintenance” means the repairs, amendment, reconstruction and includes the
rectification of defects imperfections, shrinkages and other faults except fair wear
and tear as may be required of the contractor in writing by the Engineer-in-charge
during the period of maintenance;

12) “Programme of work” means the Programme of work submitted by the contractor
and approved by the Engineer-in-charge and includes and amendment thereto
made from time to time and approved by the Engineer-in-charge;

13) “Site” means the lands and other places on, at, over, under; in or through which the
works are to be executed or carried out in pursuance of the contract or any adjacent
land, or part or street, which may be allotted or used for the purpose of carrying out
the contract or any lands or places provided by the Engineer-in-charge for the
purpose of the contract together with such other places as may be specifically
designated in or pursuant to the contract as forming part of the site;

14) “Specifications” means the specification referred to in the tender and any
modification thereof or addition thereto as may from time to time be furnished or
approved in writing by the Engineer-in-charge

15) “Temporary works” means all temporary works of every kind required in or about
the construction, completion or maintenance of the works;

16) “Works” means the works to be executed in accordance with the contract and
includes any permanent works as required for the performance of the contract.

Clause 2:
The marginal headings, the words, notes, titles and phrases used in these general
Marginal conditions and documents attached hereto, are strictly for information and direction
headings for
of the reader with regard to the contents of the said documents and shall by no
information
only means be invoked for interpretation of the said clauses nor shall they be deemed
to be part thereof or be taken into consideration in the interpretation thereof or of
the contract.
Clause 3
Terms to include The term “Executive Engineer” “Superintending Engineer” and “Chief Engineer”
designation of used in the contract and the documents attached thereto, shall respectively be
corresponding taken to include the terms “Deputy Director” “Director” and “Director General” or the
post
holder of the corresponding posts in relation to the work.

Page 21 of 53
 CONTRACT DOCUMENTS
Clause 4
Except if and to the extent otherwise provided by the contract, the conditions of
Documents contract and additional conditions annexed hereto shall prevail over those of any
mutually other document forming part of the contract. Subject to the foregoing, the several
explanatory
documents forming the contract are to be taken as mutually explanatory of one
another, but in case of any error, omission, ambiguity or discrepancy is found
between these documents, the same shall be reported to the Engineer -in-charge
who shall correct such error or omission or explain and adjust the ambiguity or
discrepancy, as the case may be, and shall thereupon issue to the contractor
instructions directing in what manner the work is to be carried out. Provided always
that if in the opinion of the Engineer-in-charge compliance with any such
instructions shall involve the contractor in any expenses which by reason of any
such error, omission, ambiguity or discrepancy, the contractor did not have reasons
to anticipate, the Engineer-in-charge shall pay such additional sums as he shall
certify to be reasonable to cover such expenses. Provided further that any work
done by the contractor, which perpetuates or adds to any error, omission, ambiguity
or discrepancy, already discovered and pointed out, shall be considered to have
been done at the contractor’s own risk.

Clause 5

1) The drawings shall remain in the sole custody of the Engineer-in-charge but two
Custody of sets of the detailed or working drawings will be obtained by the contractor free of
drawings
cost from the Engineer-in-charge after acceptance of his tender. The contractor
shall provide and make at his own expense any further copies required by him. On
the completion of the contract, the contractor shall return to the Engineer-in-charge
all drawings provided to him under the contract.

2) If so instructed, the contractor shall undertake not to disclose details of classified

drawings, other than to men in his employ, and will give an undertaking to the
Classified
drawings Engineer-in-charge that these drawings are not replicated or passed on to others
or used by any other agency/person.

3) One copy of the drawings furnished to the contractor as aforesaid shall be kept by
the contractor at site and the same shall at all reasonable times also be made
One copy of
Drawing to be available for inspection and used by the Engineer-in-charge or by any of his
kept on site. superior officer, or by any other person authorized by the Engineer-in-charge in
writing.

4) The Engineer-in-charge shall supply to the contractor, from time to time during the
progress of the works, such further drawings and instructions as shall be necessary
Further for the purpose of the proper and adequate execution and maintenance of the
drawings and works, and the contractor shall carry out and be bound by the same. The contractor
instructions shall give adequate notice in writing, to the Engineer-in-charge of any such further
drawing and instructions that contractor may require for execution of works or
otherwise under the contract.

Page 22 of 53
 GENERAL OBLIGATIONS
Clause 6:

Contract The contractor shall, when called upon so to do by the Engineer-in-charge enter into and
agreement execute a contract agreement in the form annexed.

Clause 7:
In every case where performance guarantee and/ or quality assurance security has been
provided, as specified in item (h) of Memorandum of Work, contractor shall furnish/
Performance maintain the performance guarantee and/ or quality assurance security for the extended
guarantee/ period of completion under Clause 37 of the Agreement. All compensations or the sums of
Quality money payable by the contractor under the terms of this contract may be deducted from or
Assurance
paid by the sale of sufficient part of his performance guarantee and/ or quality assurance
Security
security, and in the event of his performance guarantee and/ or quality assurance security
reduced by reason of any such deduction or sale as aforesaid the contractor shall within
ten days thereafter make good in cash or other securities as aforesaid any sum or sums
which may have been deducted from, or raised by sale of performance security or any part
thereof.

The performance guarantee and/ or quality assurance security deposit lodged by a

contractor (in cash or/other form) shall be refunded to him after the expiry of three months
after the issue of the certificate of completion of the work under Clause 40 hereof by the
Engineer-in-charge or along with the final bill if it is prepared after that period on account
of some unavoidable circumstances.

Clause 8:
i. The contractor shall if so required by the Engineer-in-charge submit in writing to the
Engineer-in-charge within the period specified by him for his approval a Programme
Programme of showing the order of procedure and the method in which he proposes to carry out the
work to be works. The time and progress chart shall be prepared indirect relation t o the time period
furnished it so stated in item (g) of the memorandum hereto annexed for the completion of individual items
required by thereof and the works as a whole. It shall indicate the forecast of the date for
Engineer-in- commencement and completion of various trade processes or section of the works, and
charge
shall be amended as may be required by agreement between the Engineer-in-charge and
the contractor within the limitation of time imposed in the contract documents.
ii. The contractor shall also, whenever required by the Engineer-in-charge, furnish for his
information full particulars in writing of the organization and staff by which he proposes to
direct and administer his performance of the contract and also such further information
concerning the contractor’s arrangements for the carrying out the work and of the
constructional plants or temporary works which the contractor intends to supply, use or
construct, as the case may be.
iii. The submission to and approval by the Engineer-in-charge of such Programme, or the
furnishing of such particulars or information shall not relieve the contractor of any of his
duties or responsibilities under the contract.
iv. In the event of the non-submission of the Programme or revised/amended programme of
Action when work by the contractor for approval by the Engineer-in-charge within the period specified
Programme by the Engineer-in-charge , the contractor shall be liable to pay as compensation an
not submitted
in time
Page 23 of 53
 amount, equal to ¼ % per day or such smaller amount as the Engineer-in-charge (whose
decision in writing shall be final) may decide on the total tendered amount of the work,
subject to maximum of 2% of contract amount.

Clause 9:
The contractor shall be responsible for the true and proper setting out of the works in
Setting out relation to original points, lines and levels of reference given by the Engineer-in-charge in
writing and for the correctness (subject as above mentioned) of the position, levels,
dimensions and alignments of all parts of the works and for the provision of all necessary
instruments, appliances and labour in connection therewith. If at any time during the
progress of the work, any error shall appear or arise in the position, levels, dimensions, or
alignment or any part of the works, the contractor on being required so to do by the
Engineer-in-charge, shall at his own expense, rectify such error to the satisfaction of the
Engineer-in-charge, unless such error is based on incorrect data, supplied in writing by the
Engineer-in-charge, in which case the expenses of rectifying the same shall be borne by
the Government. The checking of any setting out or of any line or levels by the Engineer -
in-charge shall not in any way relieve the contractor of his responsibility for the correctness
thereof, and the contractor shall carefully protect and preserve all points, marks, lines
levels, bench marks, site-rails, pegs, slope stakes, batten-boards, stakes for location, and
other things used in setting out the works.

Clause 10:
The contractor shall execute the whole and every part of the works in the most substantial
Work to be and workman-like manner, and both as regards material and otherwise in every respect in
executed in
strict accordance with the specifications. The work executed by the contractor shall also
accordance
with the conform to the design(s) and/or drawings and instructions in writing relating to the work

specifications signed by the Engineer-in-charge and lodged in his office, and to which the contractor shall
drawings be entitled to have access at such office, or on the site of the work for the purpose of
orders etc.
inspection during office hours. The contractor shall, if so required; be entitled at his own
expenses to make or cause to be made copies of specifications, and of all such designs,
drawings and instructions as aforesaid.

Clause 11:
In the case of any class of work for which there is no such specification as mentioned is
Action where no para-2 of the general directions for the guidance of the tenderer annexed hereto, such
specifications work shall be carried out in accordance with the prescribed standard specifications, and in
are provided the event of there being no such specifications, in accordance with the specification
attached with the tender, if however, there is no standard specification or specifications
attached with the tender, the work shall be carried out, in all respects in accordance with
the instructions and requirements of the Engineer-in-charge

Clause 12:

Works to be All works to be executed under the contract shall be executed under the directions and
under direction subject to the approval in all respects, of the Engineer-in-charge who shall be entitled to
of Engineer-in- direct at what point or points and in what manner they are to be commenced and from time
charge to time carried on.

Page 24 of 53
 Clause 13:
i. In the event of night work being carried on, the contractor shall provide and maintain such
Lighting at good and sufficient lights as will enable the work to proceed with satisfactorily and without
night work
danger. Similarly, the approach to the site and works where the night work is being carried
out shall be efficiently lighted. All arrangements adopted for such lighting shall be to the
Watching and satisfaction of the Engineer-in-charge
lighting ii. The contractor shall in connection with the works provide and maintain at his own cost all
lights, warning lights, caution boards, attendants, guard fencing and watch men, when and
where necessary or required by the Engineer-in-
iii. Charge for the protection of the work or for the safety and convenience of the public or
others.

Clause 14:
Arrangements to
safeguard The contractor is expected to make himself acquainted with the weather conditions, etc,
danger to and make his arrangements in such a manner that unfinished work is not in danger from
unfinished work storms, floods, etc. A claim by the contractor for a loss caused by any such eventuality will
not be entertained by the Government.

Clause 15:
The contractor shall supply at his own cost all materials (except such materials, if any as
may in accordance with the contract be supplied from the departmental store)
Contractor constructional plants, tools, appliances, implements, ladders, cordage, tackles,
to supply
plant, scaffoldings and temporary works, requisite or proper for the execution of the works,
ladders, whether original, altered or substituted, and whether included in the specifications or other
scaffolding, documents forming part of the contract referred to in these conditions or not, or which may
etc. be necessary for the purpose of satisfying or complying with the requirements of the
Engineer-in-charge as any matter as to which under these conditions he is entitled to be
satisfied, or which he is entitled to require together with carriage therefore, to and from the
work. The contractor shall also supply without charge the requisite number of persons with
the means and materials necessary for the purpose of setting out works, and counting,
weighing, and assisting in measurement or examination at any time, and from time to time
of the work or materials. Failing his so doing the same may be provided by the Engineer -
in-charge at the expense of the contractor, and the expenses may be deducted from any
Contractor money due to the contractor under the contract, or from his security deposit. The

liable to pay contractor shall also provide all necessary fencing and lights required to protect the public
damages from accident, and shall be bound to bear the expenses of defense of every suit action or
arising from other proceedings at law that may be brought by any person for injuries sustained by him
non- owing to neglect in taking the above precautions and to pay any damages and costs which
provision of
lights, may be awarded in any such suit, action or proceedings to any such person, or which may
fencing etc. with the consent of the contractor be paid to compromise any claim by any such person.

Clause 16:
Notice to be The contractor shall give not less than five days notice in writing to the Engineer-in-charge
given before or his subordinates in charge of the work, before covering up or otherwise placing beyond
the work is the reach of measurement any work in order that the same may be measured, and correct
covered up.
dimensions thereof be taken before the same is so covered up or placed beyond the reach
Page 25 of 53
 of measurement and shall not cover up or place beyond the reach of measurement any
work without the consent in writing of the Engineer-in-charge or his subordinate in charge
of the work. If any work is covered up or placed beyond the reach of measurement, without
such notice having been given and consent obtained, the same shall be uncovered at the
contractor’s expenses, and no payment or allowance shall be made for such work or the
materials with which the same was executed.

Clause 17:
1) The contractor shall provide and employ on the site for the purpose of and in
connection with the execution and maintenance of the work under the contract:-
Contractor’s
employees.
(a) Only such engineer and technical assistance as are skilled and experienced in
their respective callings, and such sub-agents, foremen and leading hands as are
competent to give proper supervision of the work, they are required to supervise,
and
(b) Such skilled, semi-skilled and unskilled labour as is necessary for the proper and
timely execution and maintenance of works under the contract.

2) (i) The Engineer-in-charge shall have full powers at all times to object to the
employment and to require the contractor to remove forthwith from the site, the
Removal of agent, workman, foreman or any other person employed by the contractor or any
contractor’s
employees. sub-contractor, who in the opinion of the Engineer-in-charge misconducts himself
or is incompetent or negligent in the proper performance of his duties or whose
employment is otherwise considered by the Engineer-in-charge to be undesirable,
and the contractor shall comply with the request forthwith.

(ii) No such agent, workman, foreman or other employees after his removal from the
work by request of the Engineer-in-charge shall be re-employed or reinstated by
the contractor for the purposes of and in connection with the contract at any time,
except with the prior approval in writing of the Engineer-in-charge.

Clause 18:
(a) The contractor shall employ for each contract, whole time qualified technical
personnel to the satisfaction of the Engineer-in-charge for the supervision of the
Whole time work at the scale given below:-
qualified technical
personnel for On contracts valuing:-
supervision of work
(i) Upto Rs.7.5 Million One diploma engineer.
(ii) Exceeding Rs.7.5 Million One senior graduate engineer.
One junior graduate engineer.

(b) If the contractor fails to employ the qualified technical personnel to the above scale,
the Engineer-in-charge shall, after giving the contractor 15 days notice to this effect,
have the option to employ to make up the deficiency in the number of such persons
at the risk and cost of the contractor.

Page 26 of 53
 Clause 19:
The contractor shall in accordance with the requirements of the Engineer -in-charge
afford all reasonable opportunities for carrying out the work by any other
Opportunities contractor(s)/specialist contractor(s) executing a part of the original work or ancillary
for other to the work, employees/workmen of such contractor(s) or those of the Government,
contractors. who may be employed in execution of, or near the site of work not included in the
contract. If, however, the contractor provides any material services/assistance or
facilities to any such contractor or to the Government on the written request of the
Engineer-in-charge, he shall be paid a reasonable sum as determined by the
Engineer-in-charge or paid according to provision in bid schedule if already made
therein.

Clause 20
1) The contractor shall indemnify and keep indemnified the Government against all
Damage to losses and claims for injuries or damage caused to any person or any property
persons and whatever, (other than surface or other damage to land or crops being on the site
property suffered by tenants of occupants) which may arise out of or in consequence of the
construction and maintenance of the works and against all claims, demands,
proceedings, damages, costs, charges and expenses whatever in respect of or in
relation thereto. Provided always that nothing herein contained shall be deemed to
render the contractor liable for, or in respect of or to indemnify the Government
against any compensation or damages for or with respect to:-

a) The permanent use or occupation of land by the works or any part thereof or (save
as hereinafter provided) surface or other damage as aforesaid.
b) The right of the Government to construct the works or any part thereof on, over,
under, in or through any land.
c) Interference whether temporary or permanent with any right of light, air, way or
water, or other assessment of quasieasement which is the unavoidable result of
the construction of the works in accordance with the contract.
d) Injuries or damage to persons or property resulting from any act or neglect done or
committed during the currency of the contract of the Government, its agents,
servants or other contractors (not being employed by the contractor) or for or in
respect of any claims, demands, proceedings, damages, costs, charges, and
expenses in respect thereof or in relation, thereto.

Provided further that for the purposes of this clause the expression “the site” shall be
deemed to be limited to the Area define in the specification or shown on the drawings
in which land and crops will be disturbed or damaged as an inevitable consequence of
carrying out the works.

2) The Government will indemnify the Contractor for and against all claims, demands,
Indemnity by proceedings, damages, costs, charges and expenses in respect of the matters
the Government
referred to in the proviso to sub-clause (1) of this clause.

Note: - The limit of various departments for the application of this clause is as follows:-

1) Buildings Contracts exceeding Rs.5 Million.

2) Public Health Engineering. Contracts exceeding Rs. 5 Million.

Page 27 of 53
 3) Highways. Contracts exceeding Rs. 10 Million.
4) Irrigation. The clause would not apply.
5) Housing and Physical Planning Contract exceeding Rs. 5 Million.
The clause may be adopted in contracts of smaller amount wherever so directed by the
Chief Engineer.
Clause 21:
All works under or in the course of execution or executed in pursuance of the
Work to be open contract, shall at all time be open to inspection and supervision of the Engineer-in-
to inspection charge or his subordinate, and the contractor shall at all times during the usual
working hours and at all other times for which reasonable notice of the intention of
the Engineer-in-charge, his senior or his subordinate to visit the works shall have
Contractor or his been given to the contractor, either himself be present to receive orders and
responsible instruction or have an agent, duly accredited in writing present for that purpose.
agent to be
present. Orders given to the contractor’s agent shall be considered to have the same force
as if they have been given to the contractor himself.

Clause 22:
i. The contractor shall give all notices, and at his own cost pay all fees, required to
Giving of
notices and be given or paid by any national or state statute, ordinance or other laws any
payment of regulation or by-laws of any local or other duly constituted authority in relation to
fees. the execution of the works or of any temporary works and by the rules and
regulations of all public bodies and companies whose property or rights are affected
or may be affected in any way by the works or any temporary works.
ii. The contractor shall conform in all respects with the provisions of any such federal,
provincial and local statutes, ordinance or law as aforesaid and the regulations or
Compliance
with status by-laws of any local or other duly constituted authority, which may be applicable to
regulations the works, or to any temporary works and with such rules and regulations of Public
etc. Bodies and companies as aforesaid and shall keep the Government indemnified
against all penalties and liabilities of every kind for breach of any such statutes,
ordinance or law, regulation or by-laws.
iii. The contractor shall be responsible for the payment of all income tax, super tax and
Payment of other Government or local taxes arising out of the contract, which shall not be
income tax
and other reimbursed to him by the Government and the rates and prices stated in the bid
taxes. schedule shall be deemed to cover all such taxes.

Clause 23:
Cost of bonds. The cost of various bonds to be entered into and executed between the contractor
and the Engineer-in-charge shall be in all respects, at the expense of the contractor.

Clause 24: In the case of tender by partners, any change in the constitution of the firm, joint
Change in the venture, company or corporation shall be forthwith notified by the contractor to the
constitution Engineer-in-charge for his information.
of firm

Clause 25: Photographs of the works shall be taken by permission of the Engineer-in-charge.
Photographs and Only signs or other advertisement approved by the Engineer-in-charge may be
advertisements. displayed at or near the works. Photographs of the works shall not be published

Page 28 of 53
 without prior written approval of the Government, which shall not be unreasonably
withheld.

ASSIGNMENT AND SUB-LETTING

Clause 26:
The contractor shall not assign the contract or any part thereof or any benefit or
Assignment.
interest therein or there under without the prior written consent of the Engineer-in-
charge

Clause 27:
The contractor shall not sublet the works or any part thereof except where otherwise
provided by the contract, without the prior written consent of the Engineer-in-charge
and such consent, if given, shall not relieve the contractor from any liability or
Subletting. obligation under the contract and he shall be responsibl e for the acts, defaults and
negligence of any sub-contractor, his agents, servants or workmen as if they were
the acts, defaults or neglects of the contractor, his agents, servants or workmen.
Provided always that the provision of labour as a piecework basis shall not be
deemed to be a subletting under this clause.

MATERIAL AND WORKMANSHIP

Clause 28:

1) All materials and workmanship shall be of the respective kinds described in the
Quantity of
contract and in accordance with the instructions of the Engineer-in-charge and
materials and
workmanship shall be subjected from time to time to such tests as the Engineer-in-charge may
and tests direct at the place of manufacture or fabrication or on the site or at all or any of such
places. The contractor shall provide such assistance, instruments, machines, labour
and materials as are normally required for examining, measuring and testing any
work and the quality, weight or quantity of any material used and shall supply
samples of materials before incorporation in the works for testing, as may be
selected and required by the Engineer-in-charge.

2) All samples shall be supplied by the contractor at his own cost if the supply thereof
Cost of samples
is clearly intended by or provided for in the specifications or bill of quantities but if
not then at the cost of the Government.

3) The cost of making any test shall be borne by the contractor if such test is clearly
intended by or provided for in the specification or bill of quantities and (in the cases
only of a test under load or of a test to ascertain whether the design or any finished
Cost of tests
or partially finished work is appropriate for the purposes which it was intended to
fulfill) is particularized in the specification or bill of quantities in sufficient detail to
enable the contractor to price or allow for the same in his tender.
4) If any test is ordered by the Engineer-in-charge which in either:-
Cost of tests
etc not a) Not so intended by or provided for; or
provided for b) (in the cases above mentioned) is not so particularized; or
c) Through so intended or provided for is ordered by the Engineer-in-charge
to be carried out by an independent person at any place other than the site
or the place of manufacture or fabrication of the materials tested.

Page 29 of 53
 Then the cost of such test shall be borne by the contractor if the test shows the
workmanship or materials not to be in accordance with the provisions of the contract or the
instructions of the Engineer-in-charge but otherwise by the Government.

Clause 29:
Before any constructional material, fittings is brought to the site of work, the
Constructional
material fittings. contractor shall submit to the Engineer-in-charge representative samples of the
etc. to conform to material fittings, etc, he proposes to use. The samples after approval will be
representative retained by the Engineer-in-charge in his custody and the contractor shall be
samples approved
responsible for ensuring that materials and fittings, etc, conforming to such samples
by Engineer-in-
charge are used through out the contract, failing which the material, fittings, etc, will not be
accepted and shall be removed forthwith from the site of work if so desired by the
Engineer-in-charge.

Clause 30:
If the specification, or the estimate of the work provides for the use of any special
description of material and equipment to be supplied from the Engineer-in-charge’s
store or if it is required that the contractor shall use certain stores to be provided by
Stores to be the Engineer-in-charge (such materials, stores and equipment and the prices to be
supplied by
Government charged therefore as hereinafter mentioned being so far as practicable for the
convenience of the contractor but not so as in any way to control the meanings or
effect of this contract specified in the schedule of memorandum hereto annexed),
the contractor shall be supplied with such materials and stores as required from
time to time to be used by him for the purpose of the contract only; and the value of
the full quantity of materials and stores so supplied at the rates specified in the said
schedule or memorandum may be set off or deducted from any sums due or to
become due, to the contractor, under the contract or otherwise: or against or from
the security deposit. All materials supplied to the contractor shall remain the
absolute property of the Government, and shall not, on any account be removed
from the site of works without the written permission of the Engineer-in-charge, and
shall at all times be open to inspection of the Engineer-in-charge. Any such material
unused or in perfectly good condition at the time of the completion or termination of
the contract shall b returned to the Engineer-in-charge’s store, if by a notice in writing
under his hand he shall so require; but the contractor shall not be entitled to return
any such materials unless with such consent, and shall have no claim for
compensation on account of any such materials so supplied to him, as aforesaid
being unused by him, or for any wastage in or damage to any such materials.

Clause 31: If it shall appear to the Engineer-in-charge or to his subordinate in charge of the
work, that any work has been executed with unsound, imperfect, or unskillful
Action and
compensation workmanship or that any materials or articles provided by him for the execution of
payable in the work are unsound, or of a quality inferior to that contracted for, or otherwise not
cases of bad in accordance with the contract the contractor shall on demand in writing from the
work
Engineer-in-charge specifying the work, materials or articles complained of not
withstanding that the same may have been inadvertently passed, certified and paid

Page 30 of 53
 for, forthwith rectify, remove and reconstruct the work so specified in whole or in
part, as the case may require, or as the case may be, remove the materials or
articles so specified and provide material as originally contracted or articles at his
own proper charge and cost, and in the event of his failing to do so within a period
to be specified by the Engineer-in-charge in his demand aforesaid, then the
Engineer-in-charge may rectify or remove and re-execute the work, remove and
replace with others, the materials and articles complained of, as the case may be,
by his own workman or by other contractor and recover from the contractor towards
the cost thereof a sum equal to the sum actually incurred by the Engineer- in-charge
(whose certificate as to the amount of the work shall be final and binding on the
parties plus departmental charges on the amount so incurred equal to ten
(10) percent or such smaller amount as the Engineer-in-charge (whose decision in
writing shall be final) may decide, and deduct the same from any money due or that
becomes due to the contractor under this contract or on any account whatsoever,
due by Government to the contractor. Measures of rectification will be decided by
the Engineer-in-charge and may include additional work necessary to strengthen
or set right the unusual work carried out by the contractor.
LABOUR
Clause 32:
The contractor shall employ labour, provide all facilities and pay wages to his work
Application of
people or employees in accordance with the labour laws or enactments relating
labour laws and
rules. thereto and rules framed there under, inforce from time to time.

Clause 33:

1) In every case in which by virtue of the provision of Section 12, sub section (1) of
the workman’s Compensation Act 1923 Government is obliged to pay
Contractor liable compensation to a workman employed by the contractor in execution of the work
for payment of
compensation to Government will recover from the contractor the amount of the compensation so
injured workman paid and without prejudice to the rights of the Government under section 12, sub
or in case of death section (2) of the said Act. Government shall be at liberty to recover such amount
to his relations. or any part thereof, by deducting it from the security deposit or from any sum due
by Government to the contractor, whether under the contractor or otherwise.
2) Government shall not be bound to contest any claim made against under section
12, sub section(1) of the said Act, except on the written request of the contractor
and upon his giving to the Government full security for all costs for which
Government right become liable in consequence of contesting such claims.

Clause 34:
i. No contractor shall use donkeys or other animals with breaching of string or thin
Use of donkeys
and other rope. The breaching must be at least 75mm wide and should be of tape (Nawar).
animals.
ii. No animal suffering from sores, lameness or emaciation or which is immature shall
be used on the work.

Page 31 of 53
 COMMENCEMENT, TIME AND DELAYS
Clause 35:
The contractor shall commence the works on the site within the period named in the
memorandum, after the receipt by him of an order in writing to this effect from the
Commencement Engineer-in-charge and shall proceed with the same with due diligence and without
of work delay, except as may be expressly sanctioned or ordered by the Engineer-in-charge
or be wholly beyond the contractor’s control.

Clause 36:
Subject to any requirements in the specification as to the completion of any portion
Time for
of the works before completion of the whole, the whole of the works shall be
completion
completed within the time stated in the memorandum or such extended time as
may be allowed under clause 37 hereof.

Clause 37:
If by reasons of the amount of extra or additional work of any kind or variation of
Extension of form, quality or quantity of the works or any part thereof ordered by the Engineer -
time for in-charge, or on the ground of his having been unavoidable hindered in the
completion. execution of the work or on any other ground or other special circumstances of any
kind whatsoever, or any cause beyond the reasonable control of the contractor, the
work is delayed or impoded or the contractor prevented from whether by the
Engineer-in-charge or otherwise howsoever, or hindered in the execution or
completion of the work or any part thereof, whether such delay or impediment or
prevention or hindrance occurs before or after the time or extended time fixed for
completion the contractor shall apply in writing to the Engineer-in-charge within
thirty, days of the date of such circumstances, the full and detailed particulars of
the claim on account of which he desires an extension as aforesaid. The Engineer-
in-charge shall, if in his opinion (which shall be final) reasonable grounds shown
therefore by the contractor are such as fairly to entitle the contractor to an extension
of time for the completion of the work, authorize him from time to time in writing,
either prospectively or retrospectively, such extension of time for the completion of
the work or any part thereof, as may in his opinion be necessary or proper.

Clause 38:
Subject to any provision to the contrary contained in the contract, none of the
No work at permanent work shall save as here in after provided be carried on during the night
night or on
or on Sundays or public holidays without the permission in writing of the Engineer-
Sundays / Public
Holidays in-charge save when the work is unavoidable or absolutely necessary for the saving
of life or property or for the safety of the works in which case the contractor shall
immediately advise the Engineer-in-charge. Provided always that the provisions of
this clause shall not be applicable in the case of any work which it is customary to
carry out by rotary or double shifts.
Clause 39:

Compensation a) The time allowed for carrying out the work as entered in the tender shall be strictly
for delay. observed by the contractor. The works shall throughout the stipulated period of the
contract be proceeded with all due diligence in accordance with the programme of

Page 32 of 53
 work, as approved by the Engineer-in-charge or any amended programme of work
approved by the Engineer-in-charge from time to time (time and quality being
deemed to be the essence of the contract on the part of the contractor) and the
contractor shall pay as compensation an amount equal to one percent of the
amount of contract, subject to maximum of 10% or such smaller amount as the
Engineer-in-charge (whose decision in writing shall be final) may decide, on the
amount of the estimated cost stated in item(b) of the memorandum of work annexed
hereto for every day that the work remains un-commenced or unfinished after the
proper date.
b) In order to ensure good progress during the execution of the work the contractor
Rate of progress. shall be bound, in all cases in which time allowed for any work exceeds thirty days,
to complete each part of the work or its component, as per programme of work or
any revision or amendment to it approved by the Engineer-in-charge. In the event
of the contractor failing to comply with this condition, without sufficient reasons
acceptable to the Engineer-in-charge, he shall be liable to pay as compensation an
amount equal to one per cent or such smaller amount as the Engineer -in-charge
(whose decision in writing shall be final) may decide on the estimated cost of the
work as named in the item (b) of the memorandum hereto annexed for every day
that the due quantity of work remains incomplete. Provided always that the entire
amount of the compensation to be paid under the provisions of this clause shall not
exceed ten percent of the estimated cost stated in item (b) of the memorandum of
work annexed hereto.
c) If the total funds required for completion of contract are not provided within two
Compensation years after the stipulated date of completion, contractor may ask for finalization of
for inadequate
his contract. All recoveries due from contractor (mobilization, secured advance,
funding
machinery hire charges, etc.) will be made before finalization of contract.

CERTIFICATE OF COMPLETION
Clause 40:
Without prejudice to the right of the Government under any such clause(s) herein
Certification of contained, as soon as in the opinion of the Engineer-in-charge, the works shall have
completion of
work been substantially completed and shall have satisfactory passed any final test that
may be prescribed by the contract, the Engineer-in-charge will issue to the
contractor a certificate of completion in respect of the work, and the period of
maintenance of work shall commence from the date of such certificate, provided
that the Engineer-in-charge may give such a certificate with respect to any
independent part of the works before the completion of the whole of the works, and
when any such certificate is given in respect of such a part of the works, such part
shall be considered as completed and the period of maintenance of such part shall
commence from the date of such certificate. Provided also that a certificate of
completion given in accordance with the foregoing provisions of any part of the
works shall not be deemed to certify completion of any ground or surface requiring
reinstatement, unless such certificate shall expressly so state. Provided further that
no such certificate shall be given nor shall the works or any of its parts be
considered to be complete until the contractor shall have removed from the

Page 33 of 53
 premises on which the works or any such parts shall be executed, all scaffoldings,
surplus materials of all kinds and rubbish, buildings and other construction
materials of all kinds and cleaned off the dirt from all woodwork, doors, windows,
walls, floors, or other parts of any building or buildings, or road works and road
structures, water supply, sewerage or drainage works, sanitary installations, gas
and electric fittings, in, upon, or about which the works are to be executed, or which
he may have had possession for the purpose of the execution thereof, nor until the
works shall have been measured by the Engineer-in-charge whose measurements
shall be binding and conclusive against the contractor.

If the contractor shall fail to comply with the requirements of this clause as to the
removal of scaffoldings, surplus material of all kinds and rubbish as aforesaid and
cleanings of dirt on or before the date fixed for the completion of the works, the
Engineer-in-charge may at the expense of the contractor, remove such
scaffoldings or surplus materials of all kinds and rubbish and dispose of the same
as he thinks fit, and clean off such dirt as aforesaid and the contractor shall forthwith
pay the amount of all expenses so incurred, and shall have no claim in respect of
any such scaffoldings or surplus materials of all kinds as aforesaid, except for any
sum actually realized by sale thereof.

ALTERATIONS, ADDITIONS AND COMMISSIONS

Clause 41:
The Engineer-in-charge shall have power to make any alteration in, omission from,
Alternation in addition to, or substituted for, the original specification, drawing designs and
specifications
instructions that may appear to him to be necessary or advisable during the
and drawings.
progress of the work, and the contractor shall be bound to carry out the works in
accordance with any instructions which may be given to him in writing signed by
Alternations the Engineer-in-charge, and such alternations, omission, additions or substitutions
omissions or
shall not invalidate the contract, and any altered, additional or substituted work
substitution do
not invalidate which the contractor may be directed to do in manner above specified as part of
the contract. the work, shall be carried out by the contractor on the same conditions in all
respects on which he agreed to do the main work, and the same rates as are
specified in the tender (bid schedule for the main work). The time for the completion
of the work shall be extended in the proportion that the altered, additional or
substituted work bears to the original contract work and the certificate of the
Extension of Engineer-in-charge shall be conclusive as to such proportion.
time in
consequence And, if the altered, additional or substituted work includes any item of work, for
of alterations
which no rate is specified in this contract, then such items of work shall be carried
out at the item rates enforced at the time of receipt of tenders with reference to
which the tender for the work was submitted by the contractor.

If such altered, additional or substituted item(s) of work is not entered in the bid
schedule, then the contractor shall within seven days of the date of receipt of the
Rate of works
not in schedule orders to carry out the work inform the Engineer-in-charge of the rate which it is his
of rates, bid intension to charge for such items of work, and if the Engineer-in-charge does not
schedule or in
the estimates.

Page 34 of 53
 agree to this rate, or the approval to this rate (or the negotiated rate, if any), is not
communicated to the contractor within a period of thirty (30) days reckoned from
the date of receipt by the Engineer-in-charge of the proposed rate, the Engineer-
in-charge shall by a notice in writing be at liberty to cancel his order to carry out
such item of work and arrange to carry it out in such a manner as he may consider
advisable, provided always that if the contractor shall commence work or incur an
expenditure in regard thereto, before the rates shall have been determined as lastly
hereinafter mentioned, he shall do so at his own risk and cost.
No deviation from specification stipulated in the contract or additional items of work
shall be carried out by the contractor unless the rate of the substituted, altered or
additional items have been approved in writing failing which Government will not
be bound to entertain any claim on this account. The interpretation of the Engineer-
in-charge in the event of any dispute due to any ambiguity in the specification or
nomenclature shall be binding and final.

Clause 42:
If at any time after the commencement of the work, the Engineer-in-charge shall
for any reason whatsoever, not require the whole thereof as specified in the tender
No compensation (bid schedule annexed hereto) to be carried out, or increase or decrease in the
for alteration in or quantity of work included in the contract or omit any such work, or change the
restriction of
work to be carried contract or quality or kind of any such work, or change the levels, lines, position
out, if variation and dimensions of any part of the works, or require the contractor to execute
does not exceed additional work of any kind necessary for the completion of the work, the Engineer-
20% in-charge shall give notice in writing of this fact to the contractor, who shall have no
claim to any payment or compensation whatsoever on account of any profit or
advantage which he might have derived from the execution of the work in full, but
which he did not derive in consequence of the full amount of the work not having
been carried out; neither shall he have any claim for compensation by reasons of
any alteration having been made in the original specifications, drawings, designs
and instructions which shall involve any curtailment or increase of the work, as
originally contemplated; nor shall the contractor be entitled to any adjustment in the
unit rate/price or amount of the contract, if the aggregate effect of all such
alterations, additions, omissions, or adjustments (other than those arising out by
reasons of price variation under clause 55 hereof) on completion of the whole of
the works, does not exceed 20 percent of the sum named in paragraph of 1(one) of
this tender.

If, on completion of the whole of the works, it shall be found that a reduction or
increase greater than 20 percent of the sum named in paragraph 1 of the tender
results from the aggregate effect of all increases, decreases omissions or
adjustments (other than those arising out because of price variation under clause
Variation 55 hereof), as a result of the requirement of the Engineer-in-charge, the amount of
exceeding 20%
the contract price shall be adjusted by such sum(s) as may be determined by the
Engineer-in-charge and the contractor. In the event of disagreement, the Engineer-
in-charge shall fix such sum as shall, in his opinion, be reasonable and proper,
regard being had to all materials and relevant factors including the contractor’s cost
and over heads

Page 35 of 53
 MAINTENANCE AND DEFECTS.
Clause 43:
1) The period of maintenance mentioned in item (i) of the memorandum hereto
annexed shall be calculated from the date of completion of the works certified by
Period of the Engineer-in-charge in accordance with clause 40 hereof or in the event of more
maintenance than one certificate having been issued by the Engineer-in-charge under the said
clause, from the respective dates so certified, and in relation to the period of
maintenance the expression the “work” shall be construed accordingly.

2) The works shall at or as soon as practicable after expiration of the period of

maintenance be delivered to the Engineer-in-charge in as good and perfect
Execution of condition (fair wear and tear excepted) to the satisfaction of the Engineer-in-charge
work of as that in which they were at the commencement of the period of maintenance, the
repair etc. contractor shall execute all such works of repair, amendment, reconstruction,
rectification and making good of defects, imperfection, shrinkage other faults as
may be required of the contractor in writing by the Engineer-in-charge during the
period of maintenance or within fourteen days after its expiration as a result of an
inspection made by or on behalf of the Engineer-in-charge prior to its expiration.

3) All such works shall be carried out by the contractor at his own expense, if the
Cost of execution
necessity thereof shall, in the opinion of the Engineer-in-charge, be due to use of
of works of repair
etc. materials or workmanship not in accordance with the contract or to neglect or failure
on the part of the contractor to comply with any obligation expressed or implied on
the contractor’s part under the contract. If in the opinion of the Engineer- in-charge
such necessity shall be due to any other cause, the value of such work shall be
ascertained and paid for, as if it were an additional work.

4) If the contractor shall fail to do any such work as aforesaid, required by the
Engineer-in-charge, the Engineer-in-charge shall be entitled to carry out such work
Remedy of by his own workmen or by other contractor(s)and if such work is a work which the
contractor’s failure contractor should have carried out at the contractor’s own cost, shall be entitled to
to carry out work recover from the contractor towards the cost thereof a sum equal to the actual
required
expenditure so incurred by the Engineer-in-charge (whose certificate as to the
amount of the work shall be final and binding on the parties) any may deduct the
same from any moneys due or that may become due to the contractor.

Clause 44:
Contractor liable If the contractor or his work people, or servant shall break, deface, injure or destroy
to make good any part of a building in which they may be working or any building, road, road work,
damages and for road structure, water supply, sewerage and drainage works, sanitary fitting and
any imperfection
noticed during electric installation, fences, enclosures, water pipes, cables, drains, electric or
period of telephone posts or any works, trees, grass or grass land, or cultivated ground
maintenance contiguous to the premises on which the work, or any part of its is being executed,
or if any damage shall happen to the work, while in progress from any cause
whatsoever or any imperfections become apparent in it within the specified period
of maintenance in item No. (i) of the memorandum hereto annexed after a
certificate, final or otherwise of its completion shall have been given by the
Engineer-in-charge as aforesaid, the contractor shall make the same good at his

Page 36 of 53
 own expense, or in default, the Engineer-in-charge may cause the same to be
made good by other workmen, and deduct the expenses (of which the certificate of
the Engineer-in-charge shall be final) from any sums that may then, or at any time
thereafter may become due to the contractor, or from his security deposit.

ADVANCES TO CONTRACTORS

Clause 45:
Should the contractor, whose contract is for finished work require an advance on
the security of material of imperishable nature brought by him to the site, the
Secured advance Engineer-in-charge shall assess the value of such materials and the contractor may
on materials be paid an advance upto an amount not exceeding seventy five percent (the
brought to site.
decision of the Engineer-in-charge as to this percentage shall be final) of the value
of the materials assessed by the Engineer-in-charge. The materials shall remain
the property of the Government and the contractor shall not remove it from the site
without the written permission of the Engineer-in-charge. The contractor shall be
responsible for any loss to the materials due to the contractor postponing the
execution of the work or to the shortage of or misuse of the materials and against
the expenses entailed for their proper watch and safe custody.
The recovery of the amount of such advance shall be made from the contractor’s
bill for the work done, as the materials are used in the work.

PAYMENTS

Clause 46
The contractor shall submit all bills on the form prescribed by the Engineer -in-
Bills to be on charge to be had on application at the office of the Engineer-in-charge and the
prescribed form.
charges in the bills shall always be entered at the rates specified in the tender (bid
schedule) or in the case of any extra work ordered in pursuance of the conditions
and not mentioned or provided for the tender, at the rate hereinafter provided for
such works.

Clause 47:
The contractor shall submit each month on or before the date fixed by the Engineer-
in-charge a bill, on the basis of measurements carried out by the contractor through
his own staff, for all works executed in the previous month, and the Engineer-in-
charge shall take or cause to be taken the requisite measurements for the purpose
Bills to be on of having the same verified and the claim, as for as admissible adjusted, if possible,
submitted monthly.
before the expiry of ten days from presentation of the bill subject to the condition
laid down in item(s) of the memorandum of work. If the contractor does not submit
the bill within the time fixed as aforesaid, the Engineer- in-charge may depute a
subordinate to measure up the work in the presence of the contractor or otherwise
and the Engineer-in-charge may prepare a bill from such measurements, which
shall be binding on the contractor in all respects.

Clause 47-A: Payment of items with imbalance rates

If a contractor quotes such disproportionate rates in his tender which deviate from
the rates provided in the technically sanctioned estimate, the payment of items

Page 37 of 53
 whose rates are lower will be made at tendered rate(s) in full on the execution of
items (s) but the payment of item whose rates are higher shall be made at the rates
depicted in technically sanctioned estimate, on the execution of such items, the
balance payment shall be withheld by the engineer in-charge till the completion of
the work of items for which low rates have been quoted.

Clause 48:
At the time of making any payment to the contractor for the work done under this
contract, the Engineer-in-charge shall retain from the amount so payable to the
Deduction of
contractor, the amount of security deposit at the percentage rate specified in item
security deposit.
(d) of the memorandum of work annexed hereto. The earnest money of the
contractor on execution of the contract, will however, be adjusted towards the
amount of such security deposit to be retained from the amount of his first bill of the
work done by him and payable to the contractor under this contract.
All compensations of other sums of money payable by the contractor to the
Government under the terms of this contract may be deducted from the amount of
his security deposit of the contract or from any sums which may be due or may
become due to the contractor by the Government on any account whatsoever, and
in the event of his security deposit being reduced by such deductions, the
contractor shall, within ten days thereafter, make good in cash any sum or sums
which may have been deducted from his security deposit, or may be made good
through additional deductions from his bill or dues.

Clause 49:
Subject to any general or special directions given by the government to the
Conversion of contrary, if the contractor so desires and makes a written request to the Engineer-
security deposit in-charge to the effect that the amount of security deposit retained from the bills of
into profit the contractor may be converted into the recognized form of profit bearing security
bearing
at the cost of the contractor, the amount of security deposit retained from bills of
securities.
the contractor shall be deposited in any of the following banks:-
1) National Bank of Pakistan Ltd.
2) Habib Bank Ltd.
3) United Bank Ltd.
4) Muslim Commercial Bank of Pakistan Ltd.
5) Allied Bank of Pakistan Ltd.
6) The Bank of Punjab.
and pledged in the name of the Executive Engineer concerned, and on the
maturity the amount of security is retrieved back in the Public Account and
refunded to the contractor in prescribed manner.
Clause 50:

a) The amount retained as security deposits shall not be refunded to the contractor
Refund of
security deposit. before the expiry of six(6) months in the case of original works valuing upto Rs.5
million and twelve (12) months or even more, as may be determined by the
Engineer-in-charge with the prior approval of the Chief Engineer, in the case of
works valuing above Rs.5 million, after the issue of the certificate of completion of
the work under clause 40 hereof by the Engineer-in-charge provide that in case
the contractor is required by the Engineer-in-charge to rectify any imperfection,

Page 38 of 53
 damage, defects or other faults in work, etc. during the period of maintenance, the
security deposit shall not be refunded till the contractor has fulfilled his obligations
under clause 43 and 44 hereof to the satisfaction of the Engineer-in-charge.
b) Should the contractor so apply in writing to the Engineer-in-charge the amount of
security deposit will be refunded to the contractor three (3) months after the issue
of certificate of completion of work by the Engineer-in-charge under clause 40
subject to the production of bank
c) Guarantee from a scheduled band in Pakistan to the satisfaction of and in the form
suitable to the Engineer-in-charge, for the same amount covering the balance of
period of maintenance, to the effect that the contractor shall fulfill his obligations
under clause 43 and 44 of the contract.
d) Subject to the conditions stipulated in sub-clause (a) of this clause, in the case of
contracts for maintenance and repair works, the security deposits would be
refunded to the contractor after the expiry if three (3) months of the issue of
certificate of completion of work by the Engineer-in-charge .
Clause 51:
The contractor shall on submitting the bill be entitled to receive a monthly payment
proportionate to the part thereof then approved and passed by the Engineer-in-
Payment on charge, subject to the condition laid down in item(s) of the memorandum, whose
intermediate certificate certificate of such approval and passing of the sum so payable, shall be final and
to be regarded as conclusive against the contractor. But all such intermediate payments shall be
advances
regarded as payment by way of advance against the final payment only, and not as
payment for work actually done and completed and shall not preclude the requiring
of bad, unsound, imperfect or unskillful work to be removed and taken away and
reconstructed, or re-erected or be considered as an admission of the due
performance of the contract, or any part thereof in any respect, or the accruing of
any claim: nor shall it conclude, determine, or affect in any way the power of
Engineer-in-charge, under these conditions or any of them as to the final settlement
and adjustment of the accounts or otherwise, or in any other way vary or affect the
contract.

Clause 52:
The final bill shall be submitted by the contractor within one month of the date fixed
Final bill to be
submitted within for completion of the works, otherwise the Engineer-in-charge’s certificate of the
one month. measurement and of the total amounts payable for the works accordingly, shall be
final and binding on all parties.

Clause 53:
The department may refuse or suspend payment on account of a work when
Procedure for executed by a firm, or by a contract described in their tender as a firm, unless
payment to firms. receipts are signed by all the parties, or one of the partners or some other person
producing power of attorney enabling him to give actual receipts on behalf of the
firm.

Clause 54:
Sums payable by way of All sums payable by way of compensation under any of these conditions, shall be
compensation to be considered as reasonable compensation to be applied to the use of Government,
considered as reasonable
compensation without
reference to actual loss.
Page 39 of 53
 without reference to the actual loss or damage sustained, and whether or not any
damage shall have been sustained.

VARIATION IN PRICES OF SPECIFIED MATERIALS

Clause 55:
1) Where any variation (increase or decrease), to the extent of 5% or more, in the
price of any of the item mentioned in sub-clause (2) below takes place after the
acceptance of tender and before the completion of contract, the amount payable
under the contract shall be adjustable to the extent of the actual variation in the
cost of the item concerned
2) No price variation under the clause shall be admissible except in respect of the
following items:-

i) Cement
ii) Steel
a) M.S Bars (Plain and Deformed)
b) M.S. Sections.
c) High Tensile Steel wire.
d) M.S and G.I Pipes.
f) M.S & G.I Sheet
g) C.I Specials
iii) Asbestos Cement Pipes.
iv) P.V.C/ uPVC Pipes.
v) PPRC pipes
vi) HDPE Pipes
vii) R.C.C/P.C.C Pipes.
vii) Bitumen.
ix) High Speed Diesel.
x) Bricks
a) 1st Class Bricks
b) Tiles
c) Gutka
xi) Stone Aggregates
a) Stone Metal for Sub Base.
b) Stone Metal for Base Course.
c) Crushed Bajri
xii) Harrow Sand
xiii) Tiles (Ceramic and Porcelain)
xiv) Wood
xv) Aluminum Sections
xvi) Paint (interior & exterior)
xvii) Labour

Page 40 of 53
3) The base price for the purposes of calculation of the price variation shall be the
price prevalent in the month during which the last day of the submission of tender
falls.
4) The price variation under this clause shall be worked out on the basis of the price
of the item concerned as notified or placed at web site by the Finance Department,
Government of the Punjab for the particular month and particular District.
5) If no notification in respect of any of the item mentioned in sub-clause (2) is issued
under sub-clause (4) no price variation shall be admissible in respect of that item
during that month.
6) The amount payable or deductible in respect of items No.(i) to (x) of sub-clause (2)
shall be calculated on the basis of the quantity of the item actually consumed on
the work during the month.
7) The amount payable or deductible in respect of item No.(v) of sub clause (2) shall
be calculated on the basis of the actual quantity of cement and steel bars used in
the manufacture of the pipes during the month.
8) No escalation shall be allowed to the contractor in respect of the period extended
for the completion of the work due to his own fault.
9) If, under the existing codal rules, secured advance is paid on all or any of the
imperishable items in sub-clause (2) above, price variation shall be admissible on
such item(s) in respect of the quantity or quantities for which secured advance has
been paid to the contractor, however, price variation will be paid after actual
consumption of the material but rate to calculate the price variation would be period
when material was brought at site.
10) The increase or decrease in the contract price subsequent to any increase or
decrease in the cost of high speed diesel shall be calculated from the increase or
decrease in the basic price of high speed diesel using the following formula:
Increase or decrease= x VOW x (CPD-BPD) / BPD in contract price.
Where:

VOW = the value of the work for which payment has been certified by the
Engineer-in-charge, executed subsequent to such increase or decrease
in the Basic Price as shall be obtained by applying the approved unit
rates and prices entered in the measurement book.
CPD = Current price of high speed diesel, and
BPD = Basic price of high speed diesel.
Factor =0.15 for Highway / Road works &
=0.07 for Buildings and R.C.C structures &
=0.07 for Irrigation Works

11) The increase or decrease in the contract price subsequent to any increase or
decrease in the cost of labour shall be calculated from the increase or decrease in
the basic price of labour using the following formula:
Increase or decrease=□ x VOW x (CLR-BLR) / BLR in contract price.
Where:

VOW = the value of the work for which payment has been certified by the
Engineer-in-charge, executed subsequent to such increase or decrease in

Page 41 of 53
 the Basic Price as shall be obtained by applying the approved unit rates
and prices entered in the measurement book.

CLR = Current labour rates for unskilled worker

(as placed on website of Finance Department).
BLR= Basic labour rates of unskilled worker on the date of receipt of tenders
(as placed on website of Finance Department)
Factor β =0.15 both for building & road works &
Factor β =0.15 for Irrigation works

CLAIMS OF CONTRACTOR
Clause 56:
The contractor shall deliver in the office of the Engineer-in-charge on or before the
Bills to be submitted
10th day of every month during the continuance of the work covered by this contract
monthly
a return in such form as the Engineer-in-charge may from time to time prescribe
showing details of any rate, amount and work claimed as extra, and such return shall
also contain the value of such work which the contractor may consider himself to
be entitled upto the end of the previous month, which value shall be based upon
the rates and prices mentioned in the contract (bid schedule) or the rate determined
pursuant to clause 41 hereof. The contractor shall include in such monthly returns
particulars of all claims of whatsoever kind and howsoever arising, which at the date
thereof he has or may claim to have, against the Engineer-in- charge under or in
respect of, or in any manner arising out of the execution of the works, and the
contractor shall be deemed to have waived all claims not included in such return
and will have no right to enforce any claim not so included, whatsoever be the
circumstances.
Clause 57:
No claim for payment of extra ordinary nature, such as claim of a bonus for extra
labour employed in completion of the work before the expiry of the contractual
period at the request of the Engineer-in-charge or claim for compensation where
Claims for payment
the work has been temporarily brought to a stand still through no fault of the
of extra ordinary
nature. contractor, shall be allowed, unless and to the extent that the same shall have been
expressly sanctioned by the Punjab Government.

Clause 58:
Under no circumstances whatsoever shall the contractor be entitled to any
Time limit for compensation on account of the contract unless the contractor shall have submitted
unforeseen
claims claim in writing to the Engineer-in-charge within one month of the cause of such
claim occurring.

Clause 59:
No compensation shall be allowed for any delay in execution of the work on account
Claim for of water standing in borrow pits or compartment. The rates inclusive for hard or
compensation for rocky soil, excavation had, sub soil water or water standing in borrow pits, and no
delay in the
execution of work. claim for extra rate shall be entertained, unless expressly verified by Engineer -in-
charge and confirmed by Superintending Engineer.

Page 42 of 53
 REMEDIES AND POWERS
Clause 60:
In any case in which under any clause or clauses of the contract, the contractor
Action when whole shall have rendered himself liable to pay compensation amounting to whole of the
of security deposit security deposit or in the opinion of the Engineer-in-charge has abandoned the
is forfeited.
contract, or is not executing the works in accordance with the contract or is
persistently or flagrantly neglecting to carry out his obligations under the contract,
or if the contractor employs any employee of the Government in defiance to the
provisions of clause 32 thereof, the Engineer-in-charge on behalf of the
Government, may, after giving fourteen days notice in writing to the contractor,
rescind the contract (of which rescission notice in writing to the contractor under
the hand of the Engineer-in-charge shall be conclusive evidence and in which case
the security deposit of the contractor, shall stand forfeited, and be absolutely at the
disposal of Government (Engineer in-charge). And in case the contract shall be
rescinded under the provisions aforesaid):-
i. The contractor shall have no claim to compensation for any loss sustained by
him by reasons of his having purchased or procured any materials, or entered
into any engagement, or made any advances on account of or with a view to
the execution of the works or the performance of the contract.
ii. The contractor shall not be entitled to recover, or be paid any sum for any work
actually performed under this contract, unless and until the Engineer-in-charge
will have certified in writing. The performance of such work and the value
payable in respect thereof, and he shall only be entitled to be paid the value so
certified, after deducting there from the amount of aforesaid compensation and
other charges duly ascertained and certified by the Engineer-in-charge to be
payable by the contractor. But if such sum payable by the contractor for any
losses, compensation or any other charge shall exceed the sum for any work
actually performed under the contract and certified by the Engineer-in-charge,
the amount of such excess shall be deemed a debt due by the contractor to the
Government and shall be recovered accordingly.

Clause 61:
In every case in which the contract should be rescinded under clause 60 hereof
and in the opinion of the Engineer-in-charge such work should be done at the risk
and expense of the contractor without thereby avoiding the contract or relieving the
contractor from any of his obligation or liabilities under the contract or affecting the
Work at the risk rights and powers conferred on the Government or the Engineer-in-charge by the
and expense of contract, the Engineer-in-charge on behalf of the Government, after giving fourteen
the contractor
days notice in writing to the contractor, shall have powers to adopt any of the
following courses, as may in the opinion of the Engineer-in-charge be desirable:-

a) To measure up the work of the contractor and to take such part thereof, as shall
be executed out of his hands and to give it to another contractor to complete, in
which case any expenses which may be incurred in excess of the sum which
would have been paid to the original contractor, had the whole of the work been
executed by him (of the amount of which excess, the certificate

Page 43 of 53
 in writing of the Engineer-in-charge shall be final and conclusive) shall be borne
and paid by the original contractor, and may be deducted from any money due
to him by the Government, under the contract or otherwise, or from his security
deposit or from the value of the performance guarantee/ quality assurance
security given by the contractor under clause 7 hereof.
b) To employ labour paid by the department and to supply materials or
supply/arrange tools and plants to carry out the works or any part of the works,
debiting the contractor with the cost of the labour and the price of the materials
and cost of supply/arrangement, operation and maintenance of tools and plants
of the amount of which cost and price a certificate of the Engineer-in-charge
shall be final and conclusive against the contractor, plus departmental charges
on the amount so incurred equal to ten percent or such smaller amount as the
Engineer-in-charge (whose decision in writing shall be final) may be decided,
and crediting him with the value of the work done, in all respects, in the same
manner and at the same time and rates, as if it had been carried out by the
contractor under the terms of his contract, the certificate of the Engineer-in-
charge as to the value of the work done shall be final and conclusive against
the contractor.
In the event of any of the above courses mentioned in this clause being adopted by
the Engineer-in-charge, the contractor shall have no claim to compensation for any
loss sustained by him by reason of his having purchased or procured any materials,
or entered into any engagement, or made any advances on account of, be with a
view to, the execution of the works or the performance of the contract.
Note: After having approval for rescinding the contract from competent authority,
the decision regarding implementation of clause 60 and 61, separately or
simultaneously shall be discretion of the Engineer In-charge.

Clause 62:
In any case in which any of the powers, conferred upon the Engineer-in-charge by
clause 60 or by para (a) of clause 61 hereof, shall have become exercisable and
Contractor remains
liable to pay the same shall not be exercised, the non-exercise thereof shall not constitute a
compensation if waver of any of the conditions hereof, and such powers shall not withstanding be
action is not taken exercisable in the event of any future case of default by the contractor for which, by
under clauses.
any clause or clauses hereof he is declared liable to pay compensation amounting
to the whole of his security deposit and the liability of the contractor for past and
future compensation shall remain unaffected.
In the event of the Engineer-in-charge putting in force either of the power vested in
Power to take him under clause 60 or para (a) of the preceding clause, he may, if he so desires,
possession or require
removal of or sell take possession of all or any tools, constructional plants, materials and stores, in or
contractor’s plant, etc. upon the works, or the site thereof, or belonging to the contractor, or procured by
him and intended to be used for the execution of the work or any part thereof,
paying or allowing for the same in account at the contract rates, or, in case of those
not being applicable at current market rates to be certified by the Engineer - in-
charge whose certificate shall be final otherwise the Engineer-in-charge , may be
notice in writing to the contractor or his clerk of the works, foreman or other
authorized agent, require him to remove such tools, construction plants, materials,

Page 44 of 53
 or stores from the premises (within a time to be specified in such notice) and in the
event of the contractor failing to comply with any such requisition, the Engineer-in-
charge may remove them at the contractor’s expense or sell them by auction or
private sale on account of the contractor and at his risk in all respects and the
certificate of the Engineer-in-charge as to the expenses of any such removal, and
the amount of the proceeds and expenses of any such sale, shall be final and
conclusive against the contractor.

Clause 63:

Contract may be If the contractor shall, in defiance of the Engineer-in-charge’s instructions to the
rescinded and contrary or without his written approval, assign or sublet his contract or attempts to
security deposit for do so; or become insolvent, or commence any insolvency proceedings or make any
subletting bribing,
composition with his creditors, or attempts so to do; or if any bribe, gratuity, gift,
or if contractor
becomes insolvent loan prerequisite, reward or advantage, pecuniary or otherwise, shall either directly
or indirectly be given, promised or offered by the contractor, or his servants or agents
to any way relating to his office, or employment; or if any such officer or person
shall become in any way directly or indirectly interested in the contract; the
Engineer-in-charge may thereupon by notice in writing rescind the contract, and
the security deposit of the contractor shall thereupon stand forfeited and be
absolutely at the disposal of Government and the same consequence shall ensue
as if the contract had been rescinded under clause 60 hereof and in addition to the
contractor shall not be entitled to receive or be paid for any work therefore actually
performed under the contract.

Clause 64:
Any excess payment made to the contractor inadvertently or otherwise, under this
Deduction of amount
contract or on any account whatsoever, and any other sum found to be due to the
due to Government on
any account Government by the contractor in respect of this contract, or any other contract or
whatsoever to be work order, or on any account whatsoever, may be deducted from any sum
permissible from any whatsoever payable by Government to the contractor, either in respect of this
sums payable to the
contract or any work order or contract, or on any other account by any other
contractor
department of the Government; or recovered from the contract or as arrears of land
revenue.

SETTLEMENT OF DISPUTES
Clause 65:
In the event of any disagreement between the Engineer-in-charge and the
Procedure in dis-
contractor arising out of the contract, the matter shall first be referred to the
agreement.
Superintending Engineer for decision who shall, after making such enquiries, as he
may deem fit, give his decision in writing not later than three months after the
reference is made to him. The period for decision of the case by the Superintending
Engineer may, however, be extended by the Chief Engineer under special
conditions according to the circumstances, justification, available in each case.
The contractor shall forthwith give effect to the decision of the

Page 45 of 53
 Superintending Engineer and shall proceed with due diligence, whether arbitration
is intended or not.

If the contractor be dissatisfied with the decision of the Superintending Engineer or

Contractor dis-satisfied if his decision is not forthcoming within the stipulated or extended period/periods
with the decision of
and desires arbitration under the arbitration clause as hereinafter provided, he shall
Superintending Engineer
give notice in writing of such intention to the Superintending Engineer within a period
of twenty eight days of the receipt of the Superintending Engineer’s decision or in
case no decision is given, at the end of the period or periods within which the
Superintending Engineer was to give his decision. The said notice shall contain the
cause of action, material facts of the case and relief sought, failing which the
decision of the Superintending Engineer shall become final, conclusive and binding,
Increase in amount of and the contractor shall be deemed to have forfeited or departed from the claim in
claim once preferred excess of that allowed by the Superintending Engineer. The subsequent
not allowed
inflation/increase in the amount of claim once preferred in the said notice shall not
be allowed nor shall any other claim in respect of the same work be entertained
from the contractor at any later stage.

A reference to arbitration shall be made by the contractor in writing not later than
Reference to
three months after the completion of the work. Failure to make such a reference
arbitration
within this period shall be deemed to mean that the contractor has waived all claims
in respect of all disputes.

a) Disputes which may be referred to arbitration shall be limited to:-

i. Any question, difference, or objection, whatsoever which shall arise in any way,
Disputes for
arbitration connected with or arising out of the contract or/and
limited. ii. The meanings of the operation of any part of the contract; or/and
iii. The rights, duties and liabilities of either party to the contract; or/and
iv. Whether the contract should be terminated or has been rightly terminated and
as regards the rights and obligations of the parties as a result of such termination.
Provided that those matters for which provision has been made in the contract for
final land binding decision by the Superintending Engineer or the Engineer -in-
charge shall be excluded from arbitration.
b) “The venue of arbitration shall be in Punjab. The contractor will have to deposit 20%
of the amount of the claim up to Rs. 0.20 million and 10% of claims, exceeding Rs.
0.20 million along with the claim. This amount will be refunded after the Award has
been made Rule of the Court. Otherwise the amount deposited will be forfeited.”
c) In the event of any dispute arising in accordance with the limitations provided in sub-
clause (a) of this clause, the same shall be referred to the decisions of a sole
Arbitration arbitrator to be appointed by the Chief Engineer, in charge of the region, from among
the officers of the department not below the rank of Superintending Engineer, and
other than the Superintending Engineer in charge of the work. In case the claim
preferred is for an amount upto half a million rupees, the decision of the sole
arbitrator in such case shall be final and binding on the parties concerned.
d) In case the amount of the claim preferred is over half a million rupees, the dispute
shall be referred to the award of two arbitrators, to be appointed from the

Page 46 of 53
 Superintending Engineers of the department, other than the Superintending
Engineer in charge of the work, one to be nominated by the Chief Engineer of the
region concerned and the other by the contractor. In the case of the said two
arbitrators not agreeing, the case shall be referred to the award of an umpire who
shall be an officer of the department not below the rank of Chief Engineer to be
appointed by the Government in the administrative department. The decision of the
two arbitrators / umpire, as the case may be shall be final and binding on the parties
concerned. Where the matter involves claim for the payment of recovery or
deduction of money only, the amount, if any, awarded in the arbitration shall be
recoverable in respect of the matter so referred.

SCHEDULE SHOWING (APPROXIMATELY) MATERIALS TO BE SUPPLIED FROM

THE DEPARTMENTAL STORE FOR WORKS CONTRACTED TO BE EXECUTED
AND THE RATES AT WHICH THEY ARE TO BE CHARGED FOR
(See clause 30)

Particulars Rates at which the Place of delivery

material will be charged
to the contractor

Note: The person or firm submitting the tender should see that the rates in the above schedule
are filled up by the Executive Engineer before the issue of the form prior to the submission
of the tender.

SCHEDULE SHOWING EQUIPMENT TO BE SUPPLIED BY THE GOVERNMENT AT THE

REQUEST OF THE CONTRACTOR

(SEE CLAUSE 30)

The Equipment and/or constructional plant listed in the following table are available with the
employer and can provide to the contractor at his request, at the rental rates and places set out
therein.
(SEE CLAUSE 30)
Rentals should be exclusive of depreciation of donor financed equipment.

Page 47 of 53
 SCHEDULE SHOWING THE NAMES OF MANUFACTURERS OR SUPPLIERS
WHOSE PRICES FOR THE SPECIFIED MATERIALS AT THE PLACES SHOWN
AGAINST EACH ARE TO FORM BASIS OF PAYMENT OF PRICE VARIATION.
“(See Clause 55)”
Name of Item Price at Places which are to form basis of
Price Variation
1 2
(i) Cement
(ii) Steel
(a) M.S Bars (Plain & deformed)
(b) M.S sections

(c) High Tensile Steel wire

(d) M.S,G.I pipe & MS Seamless Pipes As per rate placed at Website by the Finance
Department, Govt. of the Punjab
(e) MS & GI Sheets
(f) CI Specials
(iii) Asbestos cement pipes
(iv) PVC/ uPVC Pipes
(v) PPRC Pipes
(vi) HDPE pipes
(vii) Cement and Steel Bars For R.C.C pipes As per item (i) & (ii) above
As per rate placed at Website by the Finance
(viii) Bitumen (Bulk & packed)
Department, Govt. of the Punjab
To be ascertained by Advisory Committee
(ix) High Speed Diesel notified by OGRA and rate placed on web site of
Finance Department.
(x) Bricks, Tiles & Gutka
(xi) Stone Aggregates (Base, Sub Base,
Crushed Bajri)
(xii) Harrow Sand As per rate placed at Website by the Finance
Department, Govt. of the Punjab
(xiii) Floor Tiles (Ceramic & porcelain)
(xiv) Wood
(xv) Aluminum Sections
(xvi) paint (Interior & Exterior)

Page 48 of 53
 GOVERNMENT OF THE PUNJAB
Department.

CONTRACT AGREEMENT

(See Clause 6)

This agreement made this day of year

BETWEEN THE GOVERNOR OF THE PUNJAB (hereinafter called the Government) as
represented by the Executive Engineer Division
On the one part and (hereinafter called the contractor) on the other part.
WHEREAS tenders have been received by the Government for the construction, completion and
maintenance of
(Name of work)
as well as possible new and ancillary works associated therewith which have to be executed in
accordance with the contract document, and the tender by the contractor for the construction,
completion and maintenance of such works has been accepted by the Government.
NOW, THEREFORE, for and in consideration of the promises, covenants and agreement
hereinafter contained and to be performed by the parties hereto, the said parties hereby covenant
and agree as follows:-

i. In consideration of the covenants and agreements to be kept and performed by the

contractor and for the faithful performance of the contract and the

ii. completion and maintenance of works embraced therein, according to the

specifications, drawings and conditions herein contained and referred to the
Government shall pay and the contractor shall receive and accept as full compensation
for everything furnished and done by the contractor under this agreement and the
tender price stipulated in the contractor’s tender at the times and in the manner
prescribed by the contract.

iii. The said work shall be started within the period specified in item No.(f) of the
memorandum of work, following the, receipt of written order of the Executive Engineer
Division to proceed with and the contractor
shall complete fully the works within the stipulated period reckoned from the
commencement of work, subject to such extensions of time (s) as may be granted
under the conditions of contract except for maintenance which shall be completed
within the period named in item (g) of the memorandum hereto annexed after issuance
of the final certificate of completion.

iv. The following documents shall be deemed to form and be read and construed as part
of this agreement:-

a) The said tender and covering letter and subsequent undertaking, if any,
b) The drawings,

Page 49 of 53
 c) The conditions of contract and additional conditions, if any,
d) The specifications;
e) The bid schedule;
f) Addendum No.1 to
(Which have been incorporated in the tender)
g) Schedule of materials to be supplied from the departmental store;
h) The scale of rates and prices;
i) The letter of acceptance; and
j) The performance guarantee.
v. All disputes or differences between the parties in connection with or arising out of this
agreement shall be settled in accordance with the provisions of relevant clause of the
conditions of contract.
IN WITNESS WHEREOF, the parties have hereunto set their respective hands and seals the
day and the year hereinbefore set forth.
Signed by Signed by
(contractor)

Executive Engineer
Division
For and on behalf of the
Governor of the Punjab.

WITNESSES

1.

2.

Page 50 of 53
 BANK GUARANTEE.
(See Clause 7)

Penal sum of bond

(express in words and figures)

KNOW ALL MEN BY THESE PRESENTS THAT Mr./MESSERS

(Name of contractor)
Whose official address is
As principal(s) (herein after referred to as principal) and the Bank of Punjab or scheduled Bank(s)
of Pakistan (hereinafter appearing in the schedule of sureties, as sureties (hereinafter some time
called the surety at the request of the principal are held and firmly bond to the Government of the
Punjab acting through the Executive Engineer
Division or his successor or assigns) a body organized and existing under
and by virtue of laws of the Government of the Punjab, in the penal sum of the amount stated
above lawful money for the payment of which sum well and truly made we bind ourselves our
heirs, executors, administrators and successors, jointly and severally, firmly by these presents.

PROVIDED THAT We, the sureties, bound ourselves in such sum jointly and severally, as
well as, severally only for the purpose of allowing a joint actions against any or all of us and for all
other purposes, each surety bond itself, jointly and severally with the principal for the payment of
such sum only as set forth opposite its name in the following schedule:-

SCHEDULE OF SURETIES

Name of bank, branch and address limit of liability

The conditions of the above obligations is such that:

WHEREAS, the tender of the above bounden principal has been accepted and he has entered
into a contract with the Executive Engineer
Division for the work
on the
(Name of work)
day of 200

AND WHEREAS, under the terms of the contract Government has required the principal to furnish
a performance guarantee to form a part of the contract.

NOW THEREFORE, it is agreed as follows:-

Page 51 of 53
1) If the above bounden principal shall well truly and faithfully perform the contract and
comply with and fulfill all the undertakings, terms and provisions thereof, and satisfy all
the obligations of the said principal arising there under, and comply with all covenants
therein contained and contained in the specifications, plan and other instruments
constituting a part of the contract, required to be performed by the said principal, in the
manner and within the time provided in the contract or any extension thereof that may
be granted by the Government with or without notice to the surety(s) and shall fully
indemnify and the Government, for all costs and damages which the Government may
suffer by reason of failure so to do, and shall fully reimburse and repay the said
Executive Engineer
Division all out-lay and expenses which may incur in making good any
such default and reasonable counsel fee incurred in the prosecution of defense of any
action arising out of or in connection with any such default, and shall pay all persons
who have contracts directly with the principal for labour and materials; if any, in
connection with the work performed under the contract or any addition in or alternation
thereto, or if the contract has not otherwise been rescinded by the Government under
the provisions of clause 60 if general conditions of contract, then this obligation shall
be null and void and of no effect, otherwise to remain in full force and effect and virtue.
2) The said surety, for value received, hereby stipulate and agree that no change in or in
respect of any matter or thing concerning the said contract on the part of the
Government or the Engineer-in-charge, extension in time, alteration in or addition to
the terms of the contract between the Government and the contractor or to the extent
and nature of the work be construed, completed and maintained there under, or the
specifications accompanying the same shall in any way affect its obligations to this
guarantee and it does hereby waive notice of any change extension in time, alteration
or addition to the terms of the contractor to the specifications.
3) The liability of the surety is irrevocable and shall in no case exceed the aggregate
amount stated on the top of this guarantee which each surety binds itself and promise
to pay the whole or any part of this amount on demand to the Executive Engineer
Division

Without question and without reference to the principal. Provided that the notice of demand
shall be given by the aforesaid Executive Engineer, in writing to the surety.

IN WITNESS WHEREOF, the above named principal and the surety have execut ed this
instrument under its seal on this day of 200
The name and corporate seal of the surety being hereto affixed and these presents duly
signed by its undersigned representatives pursuant to the authority of its Government
body.

Principal (Contractor)

Address

Sureties 1 Bank of Pakistan Ltd. Or Bank of Punjab

Branch.

Page 52 of 53